The Network Rail (Tinsley Chord) Order 2015

• “apparatus” means— in the case of an electricity undertaker, electric lines or electrical plan (as defined in the Electricity Act 1989[^f00052]), belonging to or maintained by that undertaker; in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply; in the case of a water undertaker, mains, pipes or other apparatus belonging to or maintained by that undertaker for the purposes of water supply; and in the case of a sewerage undertaker— any drain or works vested in the undertaker under the Water Industry Act 1991; and any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act, and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

• “functions” includes powers and duties;

• “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

• “undertaker” means— any licence holder within the meaning of Part 1 of the Electricity Act 1989; a gas transporter within the meaning of Part 1 of the Gas Act 1986[^f00053]; a water undertaker within the meaning of the Water Industry Act 1991; and a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991, for the area of the authorised works, and in relation to any apparatus, means the undertaker to whom it belongs or by whom it is maintained.

4

Regardless of any provision in this Order or anything shown on the works and land plan, the promoter must not acquire any apparatus otherwise than by agreement.

5

• (1) If, in the exercise of the powers conferred by this Order, the promoter acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Schedule and any right of an undertaker to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the undertaker in question.

• (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the promoter requires the removal of any apparatus placed in that land, it must give to the undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus) the promoter must, subject to sub-paragraph (3), afford to the undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the promoter and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the promoter, or the promoter is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the undertaker in question must, on receipt of a written notice to that effect from the promoter, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

• (4) Any alternative apparatus to be constructed in land of the promoter under this Schedule is to be constructed in such manner and in such line or situation as may be agreed between the undertaker in question and the promoter or in default of agreement settled by arbitration in accordance with article 43 (arbitration).

• (5) The undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 43, and after the grant to the undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the promoter to be removed under the provisions of this Schedule.

• (6) Regardless of anything in sub-paragraph (5), if the promoter gives notice in writing to the undertaker in question that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the promoter, that work, instead of being executed by the undertaker, must be executed by the promoter without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the undertaker.

• (7) Nothing in sub-paragraph (6) authorises the promoter to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

6

• (1) Where, in accordance with the provisions of this Schedule, the promoter affords to an undertaker facilities and rights for the construction and maintenance in land of the promoter of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the promoter and the undertaker in question or in default of agreement settled by arbitration in accordance with article 43 (arbitration).

• (2) In settling those terms and conditions in respect of alternative apparatus to be constructed in or along any tramroad of the promoter, the arbitrator must—

• (a) give effect to all reasonable requirements of the promoter for ensuring the safety and efficient operation of the mentioned tramroad and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of the promoter or the traffic on the authorised tramroad; and

• (b) so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed in or along the authorised tramroad for which the alternative apparatus is to be substituted.

• (3) If the facilities and rights to be afforded by the promoter in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the promoter to that undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

7

• (1) Not less than 28 days before starting the execution of any works of the type referred to in paragraph 5(2) that are near to, or will or may affect, any apparatus the removal of which has not been required by the promoter under paragraph 5(2), the promoter must submit to the undertaker in question a plan, section and description of the works to be executed.

• (2) Those works are to be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the undertaker is entitled to watch and inspect the execution of those works.

• (3) Any requirements made by an undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

• (4) If an undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the promoter, reasonably requires the removal of any apparatus and gives written notice to the promoter of that requirement, paragraphs 1 to 6 apply as if the removal of the apparatus had been required by the promoter under paragraph 5(2).

• (5) Nothing in this paragraph precludes the promoter from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

• (6) The promoter is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

8

• (1) Subject to the following provisions of this paragraph, the promoter must repay to an undertaker the reasonable expenses incurred by the undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus (including costs or compensation payable in connection with the acquisition of land for that purpose) which may be required in consequence of the execution of any such works as are referred to in paragraph 5(2).

• (2) The value of any apparatus removed under the provisions of this Schedule is to be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.

• (3) If in accordance with the provisions of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the promoter or, in default of agreement, is not determined by arbitration in accordance with article 43 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

• (5) An amount which apart from this sub-paragraph would be payable to an undertaker in respect of works by virtue of sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

9

• (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraph 5(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of an undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any undertaker, the promoter must—

• (a) bear and pay the cost reasonably incurred by that undertaker in making good such damage or restoring the supply; and

• (b) make reasonable compensation to that undertaker for any other expenses, loss, damages, penalty or costs incurred by the undertaker,

by reason or in consequence of any such damage or interruption.

• (2) Nothing in sub-paragraph (1) imposes any liability on the promoter with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of any undertaker, its officers, servants, contractors or agents.

• (3) An undertaker must give the promoter reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the promoter which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

10

Nothing in this Schedule affects the provisions of any enactment or agreement regulating the relations between the promoter and an undertaker in respect of any apparatus laid or erected in land belonging to the promoter on the date on which this Order is made.

Signed

Signed by authority of the Secretary of State for Transport

Martin Woods — Head of the Transport and Works Act Orders Unit — Department for Transport — 25th November 2015

Explanatory note

(This note is not part of the Order)

EXPLANATORY NOTE

This Order authorises South Yorkshire Passenger Transport Executive (“the Executive”) and Network Rail Infrastructure Limited acting either together or individually (referred to in this Order as (“the promoter”) to construct and operate the Tinsley Chord. The Tinsley Chord is a tramroad which will connect the Supertram and Network Rail systems and will be used by tram-trains.

For these purposes the Order confers powers on Network Rail, compulsorily or by agreement, to acquire land and rights in land and to use land.

The Order contains protective provisions for the benefit of the Environment Agency and undertakers affected by the works authorised by the Order.

A copy of the book of reference, the sections and the works and land plan mentioned in this Order and certified in accordance with article 40 (certification of plans etc.) of this Order may be inspected free of charge during working hours at the offices of the Executive at 11 Broad Street West, Sheffield, South Yorkshire, S1 2BQ and at the offices of Network Rail Infrastructure Limited at 1 Eversholt Street, London, NW1 2DN.

Footnotes

[^f00001]: S.I. 2006/1466, amended by S.I. 2010/439, S.I. 2011/556, S.I. 2011/2085, S.I. 2012/147, S.I. 2012/1658, S.I. 2012/2590 and S.I. 2013/755.

[^f00002]: 1992 c. 42. Section 1 was amended by the Planning Act 2008 (c. 29), Schedule 2, paragraphs 51 and 52; section 5 was amended by S.I. 2012/1659.

[^f00003]: 1961 c. 33.

[^f00004]: 1965 c. 56.

[^f00005]: 1988 c. xxvii.

[^f00006]: 1989 c. xix.

[^f00007]: 1990 c. 8.

[^f00008]: 1981 c. 67. The definition of “owner” was amended by paragraph 9 of Schedule 15 to the Planning and Compensation Act 1991 c. 34. There are other amendments to section 7 which are not relevant to this Order.

[^f00009]: 1845 c. 20.

[^f00010]: Section 103 was amended by the Statute Law Revision Act 1892 (c. 19), Part 3 of Schedule 7 to the Justices of the Peace Act 1949 (c. 101) and section 46 of the Criminal Justice Act 1982 (c. 48).

[^f00011]: Section 145 was amended by the Statute Law Revision Act 1892 (c. 19) and Part 2 of Schedule 12 to the Transport Act 1962 (c. 46).

[^f00012]: 1839 c. 45.

[^f00013]: 1842 c. 55.

[^f00014]: 1889 c. 57.

[^f00015]: 1991 c. 56. Section 106 was amended by sections 35(1) and (8) and 43(2) of, and Schedule 2 to, the Competition and Service (Utilities) Act 1992 (c. 43), sections 36(2) and 99 of the Water Act 2003 (c. 37) and paragraph 16(1) of Schedule 3 to the Flood and Water Management Act 2010 (c. 29).

[^f00017]: 1991 c. 57.

[^f00018]: 1979 c. 46.

[^f00019]: 1981 c. 67.

[^f00020]: 1981 c. 66.

[^f00021]: Section 11 was amended by section 34(1) of, and Schedule 4 to, the Acquisition of Land Act 1981 (c. 67), section 3 of, and part 1 of Schedule 1 to, the Housing (Consequential Provisions) Act 1985 (c. 71), section 14 of, and paragraph 12(1) of Schedule 5 to, the Church of England (Miscellaneous Provisions) Measure 2006 (No. 1) and S.I. 2009/1307.

[^f00022]: Section 10 was amended by section 4 of, and paragraph 13(2) of Schedule 2 to, the Planning (Consequential Provisions) Act 1990 (c. 11) and S.I. 2009/1307.

[^f00023]: Section 13 was amended by sections 62(3) and 139 of, and paragraph 27 and 28 of Schedule 13, and part 3 of Schedule 23, to the Tribunals, Courts and Enforcement Act 2007 (c. 15).

[^f00024]: Section 8 was amended by S.I. 2009/1307.

[^f00025]: Section 11 was amended by section 34(1) of, and Schedule 4 to, the Acquisition of Land Act 1981 (c. 67), section 3 of, and part 1 of Schedule 1 to, the Housing (Consequential Provisions) Act 1985 (c. 71), section 14 of, and paragraph 12(1) of Schedule 5 to, the Church of England (Miscellaneous Provisions) Measure 2006 (2006 No 1) and S.I. 2009/1307.

[^f00026]: Section 90(2A) was inserted by section 16(1) of the Transport and Works Act 1992 (c. 42).

[^f00027]: 1993 c. 43.

[^f00028]: 1985 c. 67.

[^f00029]: 1994 c. 22.

[^f00030]: 1981 c. 14.

[^f00031]: 1985 c. 67.

[^f00032]: 1996 c. 16.

[^f00033]: 2003 c. 20.

[^f00034]: 1990 c. 43.

[^f00035]: Section 79(1) was amended by section 2(2) of the Noise and Statutory Nuisance Act 1993, section 120 of, and paragraph 2(a) of Schedule 17 and paragraph 89(2) of Schedule 22 to, the Environment Act 1995, sections 101(2) and 102(2) of the Clean Neighbourhoods and Environment Act 2005 (c. 16) and sections 109(2), 110(2), 111(2) and 112(2)(a) of the Public Health etc. (Scotland) Act 2008 (asp. 5).

[^f00036]: Section 61 was amended by Schedule 7 to the Building Act 1984 (c. 55), paragraph 15(3) of Schedule 15 to the Environmental Protection Act 1990 (c. 43), Schedule 24 to the Environment Act 1995 and paragraph 10 of Schedule 6 to the Building (Scotland) Act 2003 (asp. 8).

[^f00037]: 1974 c. 40.

[^f00038]: 1978 c. 30.

[^f00039]: 1973 c. 26.

[^f00040]: Section 58(1) was amended by section 16(3) of, and Schedule 5 to, the Compulsory Purchase (Vesting Declarations) Act 1981 (c. 66), section 4 of, and paragraph 29(1) of Schedule 2 to, the Planning (Consequential Provisions) Act 1990 (c. 11) and S.I. 2009/1307.

[^f00041]: S.I. 2015/1876

[^f00042]: Section 11 was amended by section 34(1) of, and Schedule 4 to, the Acquisition of Land Act 1981 (c. 67), section 3 of, and part 1 of Schedule 1 to, the Housing (Consequential Provisions) Act 1985 (c. 71), section 14 of, and paragraph 12(1) of Schedule 5 to, the Church of England (Miscellaneous Provisions) Measure 2006 (No. 1) and S.I. 2009/1307.

[^f00043]: Section 12 was amended by section 56(2) of, and part 1 of Schedule 9 to, the Courts Act 1971 (c. 23).

[^f00044]: Section 13 was amended by sections 62(3), 139(4) to (9) and 146 of, and paragraphs 27 and 28 of Schedule 13 and part 3 of Schedule 23 to, the Tribunals, Courts and Enforcement Act 2007 (c. 15).

[^f00045]: Section 20 was amended by paragraph 4 of Schedule 15 to the Planning and Compensation Act 1991 and S.I. 2009/1307.

[^f00046]: 2003 c. 21.

[^f00047]: 1980 c. 66.

[^f00048]: Section 272 to 274 were amended by paragraph 103(1) and (2) of Schedule 17 to the Communications Act 2003 (c. 21).

[^f00049]: Section 279(3) was amended by paragraph 103(1) and (2), and section 280 was amended by paragraph 104, of Schedule 17 to the Communications Act 2003. Sections 280 and 282 were amended by S.I. 2009/1307.

[^f00050]: 1991 c. 57.

[^f00051]: S.I. 2009/3344.

[^f00052]: 1989 c. 29.

[^f00053]: 1986 c. 44. A new section 7 was substituted by section 5 of the Gas Act 1995 (c. 45), and was further amended by section 76 of the Utilities Act 2000 (c. 27).

Editorial notes

[^key-ff5007c55d25ba99dfdfa4bebb0bd029]: Art. 1 in force at 16.12.2015, see art. 1

[^key-4f7b29f5f28603425ea9fb47f0774715]: Art. 2 in force at 16.12.2015, see art. 1

[^key-7caae793d7d099c08dc204f582744562]: Art. 3 in force at 16.12.2015, see art. 1

[^key-1381aeeb3b417b241036197f6738c67d]: Art. 4 in force at 16.12.2015, see art. 1

[^key-c2465f483267989bd45d7609c5c9bae0]: Art. 5 in force at 16.12.2015, see art. 1

[^key-4e45c37c53ea536ff917bc07bc06e75c]: Art. 6 in force at 16.12.2015, see art. 1

[^key-c3a6b0674ce65d588a1a89f7bd21a626]: Art. 7 in force at 16.12.2015, see art. 1

[^key-ee7a0e8751b098f123b32b0fbdaeb683]: Art. 8 in force at 16.12.2015, see art. 1

[^key-864b24ba15de7af85210f826cacf0541]: Art. 9 in force at 16.12.2015, see art. 1

[^key-0aabe858545442ca1642d65cbb6a9dc3]: Art. 10 in force at 16.12.2015, see art. 1

[^key-8be2d82a65b77ea455bcdec4dc96e033]: Art. 11 in force at 16.12.2015, see art. 1

[^key-488f51fe531919f40ddd3901ca248346]: Art. 12 in force at 16.12.2015, see art. 1

[^key-5412ac79b9684deaff6a2ecef37a4be4]: Art. 13 in force at 16.12.2015, see art. 1

[^key-a80feb0ce7580e94f0a646116a237e26]: Art. 14 in force at 16.12.2015, see art. 1

[^key-a85c35b9d6259bd4804854b768001b55]: Art. 15 in force at 16.12.2015, see art. 1

[^key-0691707a379cbb56247b83a2a23d39e3]: Art. 16 in force at 16.12.2015, see art. 1

[^key-619d614889a30b15f42d3e7cbdc52f14]: Art. 17 in force at 16.12.2015, see art. 1

[^key-7d9b6f03b0c09aafe6859221fb7fce0b]: Art. 18 in force at 16.12.2015, see art. 1

[^key-596a09c59d11057f446c342ae5abb8e9]: Art. 19 in force at 16.12.2015, see art. 1

[^key-c79571cfa91ff53e3cc3246a42a7df2f]: Art. 20 in force at 16.12.2015, see art. 1

[^key-7796007f649d51b71ef6e67af4d6c30c]: Art. 21 in force at 16.12.2015, see art. 1

[^key-ae5c25ef0f75ad8e14291380477422e4]: Art. 22 in force at 16.12.2015, see art. 1

[^key-4b0db287aa92451964cd3d3eeec7a69b]: Art. 23 in force at 16.12.2015, see art. 1

[^key-09545b6b6fd2828ea8ee8a68dc0ee029]: Art. 24 in force at 16.12.2015, see art. 1

[^key-2a0cd746f7251df76c51ba9da902ec23]: Art. 25 in force at 16.12.2015, see art. 1

[^key-dd452670ff3239cce1e3da5b04262a0d]: Art. 26 in force at 16.12.2015, see art. 1

[^key-eb7a29dc013f2c427c007202105d7baf]: Art. 27 in force at 16.12.2015, see art. 1

[^key-c2c754f3f4d96336752994f12e3bdcb0]: Art. 28 in force at 16.12.2015, see art. 1

[^key-6ce6a1392a11438015ed1b9df1b82357]: Art. 29 in force at 16.12.2015, see art. 1

[^key-40a6fe01245f210d6c377759cd5f05d6]: Art. 30 in force at 16.12.2015, see art. 1

[^key-c446d4ff003dd409111fd877e68810c4]: Art. 31 in force at 16.12.2015, see art. 1

[^key-2f156d47b8ef0965d49d5a1337681671]: Art. 32 in force at 16.12.2015, see art. 1

[^key-568fe7553a5782c4ddd1aae96468f966]: Art. 33 in force at 16.12.2015, see art. 1

[^key-e93bbe9e1f4bd99e342ab85e8b6a63ea]: Art. 34 in force at 16.12.2015, see art. 1

[^key-99e5bd0c2f17e712486661bc3e25bbfe]: Art. 35 in force at 16.12.2015, see art. 1

[^key-19eb67ae630b3f995d1e8568143818e8]: Art. 36 in force at 16.12.2015, see art. 1

[^key-0b1b2b54f280e459d51da1a5400973da]: Art. 37 in force at 16.12.2015, see art. 1

[^key-943f6d4b71b00f8df31f5c6e25ef97df]: Art. 38 in force at 16.12.2015, see art. 1

[^key-aa34137e4923783798b6053a9dbeb4aa]: Art. 39 in force at 16.12.2015, see art. 1

[^key-6a2e4f1468e7124f2dd4fc2e55c1e2b8]: Art. 40 in force at 16.12.2015, see art. 1

[^key-9e6b097c6a37188a280ab72ceff1043b]: Art. 41 in force at 16.12.2015, see art. 1

[^key-8d91546ad210096b20e55d154d5159c1]: Art. 42 in force at 16.12.2015, see art. 1

[^key-11e2fdcee3a51e4dcf00e726b03cf399]: Art. 43 in force at 16.12.2015, see art. 1

[^key-f04b3ec5aef2f309cf7190b86ec02890]: Sch. 4 para. 1 in force at 16.12.2015, see art. 1

[^key-60551d64a39eed950569bb40564815fa]: Sch. 4 para. 2 in force at 16.12.2015, see art. 1

[^key-24dec6a83a8da414cacce58705f147bc]: Sch. 4 para. 3 in force at 16.12.2015, see art. 1

[^key-a5fd36aff4aae379b187a1ec800de9a3]: Sch. 4 para. 4 in force at 16.12.2015, see art. 1

[^key-469772157590b2e102a6119826f38970]: Sch. 4 para. 5 in force at 16.12.2015, see art. 1

[^key-88c992bbd65fb96a224314525ab1adfd]: Sch. 4 para. 6 in force at 16.12.2015, see art. 1

[^key-a453291ddb1b8164464a46b36c5300c7]: Sch. 4 para. 7 in force at 16.12.2015, see art. 1

[^key-b6e08516ef482bb35c95f0fcf6c0e890]: Sch. 4 para. 8 in force at 16.12.2015, see art. 1

[^key-43285d2f2a414b5ddd12ed696f00dc78]: Sch. 4 para. 9 in force at 16.12.2015, see art. 1

[^key-cb7bc50fc4d3573846100b1866491668]: Sch. 7 para. 1 in force at 16.12.2015, see art. 1

[^key-b33880ee7de7c9ffcf1d9eb7bdecd622]: Sch. 7 para. 2 in force at 16.12.2015, see art. 1

[^key-625bd01c4885ed528efbea2e168bfb9e]: Sch. 7 para. 3 in force at 16.12.2015, see art. 1

[^key-576ae68c8bd598eddb8e6a6f306ce843]: Sch. 7 para. 4 in force at 16.12.2015, see art. 1

[^key-d240236bc705b747f0cde22a2271d264]: Sch. 7 para. 5 in force at 16.12.2015, see art. 1

[^key-6f00967b2d317b38de6bc0dd2e0506fb]: Sch. 8 para. 1 in force at 16.12.2015, see art. 1

[^key-2eaa3fb15a6895e7b1792bb744f2aa98]: Sch. 8 para. 2 in force at 16.12.2015, see art. 1

[^key-0acb39a576a132c170b6008f6621a2b0]: Sch. 8 para. 3 in force at 16.12.2015, see art. 1

[^key-a6ffeba42755abb25b10e5d8b9ede140]: Sch. 8 para. 4 in force at 16.12.2015, see art. 1

[^key-ca04f18192697cdd494c4299ac20e6f9]: Sch. 8 para. 5 in force at 16.12.2015, see art. 1

[^key-418f78732c24c018ff9140abb00e1965]: Sch. 8 para. 6 in force at 16.12.2015, see art. 1

[^key-1a8235f9fb176e1c58ba7e6cb418ed6d]: Sch. 8 para. 7 in force at 16.12.2015, see art. 1

[^key-0f663bbb382cdde37026b3e5d41dee60]: Sch. 8 para. 8 in force at 16.12.2015, see art. 1

[^key-06bbf4c277acbef145a54bdc2977a5aa]: Sch. 8 para. 9 in force at 16.12.2015, see art. 1

[^key-8ee4ae2f3f5975887b8baaf21292ea4b]: Sch. 8 para. 10 in force at 16.12.2015, see art. 1

[^key-aa0be19179f3129a13a0c3707cf79a62]: Sch. 8 para. 11 in force at 16.12.2015, see art. 1

[^key-420b551032ea23d599764ec78cdfeadd]: Sch. 8 para. 12 in force at 16.12.2015, see art. 1

[^key-bebd292d9a11d37824440a4525b40c23]: Sch. 8 para. 13 in force at 16.12.2015, see art. 1

[^key-c1671d051f4ebe5fd101ee1b4edbe074]: Sch. 9 para. 1 in force at 16.12.2015, see art. 1

[^key-5478306cbe843e46ef37dac5c308cf12]: Sch. 9 para. 2 in force at 16.12.2015, see art. 1

[^key-c727a2d8b4fa2472ad5c21131990066e]: Sch. 9 para. 3 in force at 16.12.2015, see art. 1

[^key-7b62efa7ec2ba1b56206732437684cbc]: Sch. 9 para. 4 in force at 16.12.2015, see art. 1

[^key-31580015a6d04526997cd1a51381162a]: Sch. 9 para. 5 in force at 16.12.2015, see art. 1

[^key-624cdf080cddd9adc9889492cb6fcda3]: Sch. 9 para. 6 in force at 16.12.2015, see art. 1

[^key-ddde384707c34aa63990e6712e34e9d0]: Sch. 9 para. 7 in force at 16.12.2015, see art. 1

[^key-0830b8248a52a9643b0c5cfeec835007]: Sch. 9 para. 8 in force at 16.12.2015, see art. 1

[^key-4e1ffa3a4db23c10b5a43f73bde9c4a3]: Sch. 9 para. 9 in force at 16.12.2015, see art. 1

[^key-5d09755f8578cecfbb6e38d33a1546a4]: Sch. 9 para. 10 in force at 16.12.2015, see art. 1

[^key-bdf0ed1813312bb8eaae4e367d5776b2]: Sch. 1 in force at 16.12.2015, see art. 1

[^key-a85d138cb03ade0c561f5a1361c8fec2]: Sch. 2 in force at 16.12.2015, see art. 1

[^key-09346136142bfae3c8a478660420035c]: Sch. 3 in force at 16.12.2015, see art. 1

[^key-e655998cf3a8c2c8535b456edf8a4fcd]: Sch. 5 in force at 16.12.2015, see art. 1

[^key-869e7bc9d76991b8db3bb69cde39423e]: Sch. 6 in force at 16.12.2015, see art. 1

[^key-18f6c1a9904a1cd11955c6b48c13213a]: Words in art. 8(8) substituted (1.1.2017) by The Environmental Permitting (England and Wales) Regulations 2016 (S.I. 2016/1154), reg. 1(1), Sch. 29 para. 100 (with regs. 1(3), 77-79, Sch. 4)