The Knottingley Power Plant Order 2015

• “detriment” means any damage to the waterway or any other property of CRT caused by the presence of the authorised works and, without prejudice to the generality of that meaning, includes—any obstruction of, or interference with, or hindrance or danger to, navigation or to any use of the waterway (including towing paths);the erosion of the bed or banks of the waterway, or the impairment of the stability of any works, lands or premises forming part of the waterway;the deposit of materials or the siltation of the waterway so as to damage the waterway;the pollution of the waterway;any significant alteration in the water level of the waterway, or significant interference with the supply of water thereto, or drainage of water therefrom;any harm to the ecology of the waterway (including any adverse impact on any site of special scientific interest comprised in CRT’s network);any interference with the exercise by any person of rights over CRT’s network;

• “the engineer” means an engineer appointed by CRT for the purpose in question;

• “plans” includes sections, designs, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction) and programmes;

• “practical completion” means practical completion of all of the specified work notwithstanding that items which would ordinarily be considered snagging items remain outstanding, and the expression “practically complete” and “practically completed” shall be construed accordingly;

• “protective work” means a work constructed under paragraph 6(3)(a);

• “specified work” means so much of Work Nos. 3, 6 and 8G as are situated upon, across, under, over or within 15 metres of, or may in any way affect the waterway;

• “towing path” means the towing path forming part of the waterway;

• “the waterway” means the Aire & Calder Navigation, and includes any works, lands or premises belonging to CRT, or under its management or control, and held or used by CRT in connection with that canal.

Powers requiring CRT’s consent

2

• (1) The undertaker shall not in the exercise of the powers conferred by this Order obstruct or interfere with pedestrian or vehicular access to the waterway unless such obstruction or interference with such access is with the consent of CRT.

• (2) The undertaker shall not exercise any power conferred by this Order to discharge water into the waterway under article 15 (discharge of water) or in any way interfere with the supply of water to or the drainage of water from the waterway unless such exercise is with the consent of CRT, save as to surface water discharge which will not require the consent of CRT.

• (3) The undertaker shall not exercise the powers conferred article 16 (authority to survey and investigate land) or section 11(3) of the 1965 Act, in relation to the waterway unless such exercise is with the consent of CRT.

• (4) The undertaker shall not exercise the powers conferred by section 271 or 272 of the Town and Country Planning Act 1990, as applied by Schedule 3 to this Order (streets to be stopped up), so as to divert any right of access to the waterway but such right of access may be diverted with the consent of CRT.

• (5) The consent of CRT pursuant to sub-paragraphs (1) to (4) shall not be unreasonably withheld or delayed but may be given subject to reasonable terms and conditions which in the case of article 15 (discharge of water) may include conditions—

• (a) specifying the maximum volume of water which may be discharged in any period; and

• (b) authorising CRT on giving reasonable notice (except in an emergency, when CRT may require immediate suspension) to the undertaker to require the undertaker to suspend the discharge of water or reduce the flow of water where this is necessary by reason of any operational or environmental requirement of CRT,

to the extent that any discharge of water by the undertaker is into the waterway.

Vehicles, plant and machinery

3

The undertaker shall not use any land or property of CRT forming part of the waterway for the passage or siting of vehicles, plant or machinery employed in the construction of the specified works other than—

• (a) with the consent in writing of the engineer whose consent shall not be unreasonably withheld; and

• (b) subject to compliance with such reasonable requirements as the engineer may from time to time specify—

• (i) for the prevention of detriment; or

• (ii) in order to avoid or reduce any inconvenience to CRT, its officers and agents and all other persons lawfully on such land or property, but nothing in this paragraph shall apply in relation to anything done in accordance with any approval given by CRT under paragraph 6.

Fencing

4

Where so required by the engineer the undertaker shall to the reasonable satisfaction of the engineer fence off a specified work or a protective work or take such other steps as the engineer may require to be taken for the purpose of separating a specified work or a protective work from the waterway, whether on a temporary or permanent basis or both.

Survey of waterway

5

• (1) Before the commencement of the initial construction of any part of the specified works and again following practical completion of the specified works the undertaker shall bear the reasonable cost of the carrying out by a qualified engineer (the “surveyor”), to be approved by CRT and the undertaker, of a survey including a dip-survey to measure the depth of the waterway (“the survey”) of so much of the waterway and of any land and existing works of the undertaker which may provide support for the waterway as will or may be affected by the specified works.

• (2) For the purposes of the survey the undertaker shall—

• (a) on being given reasonable notice (save in case of emergency, when immediate access shall be afforded) afford reasonable facilities to the surveyor for access to the site of the specified works and to any land and existing works of the undertaker which may provide support for the waterway as will or may be affected by the specified works; and

• (b) supply the surveyor as soon as reasonably practicable with all such information as he may reasonably require with regard to such existing works of the undertaker and to the specified works or the method of their construction.

• (3) The reasonable costs of the survey shall include the costs of any dewatering or reduction of the water level of any part of the waterway (where reasonably required) which may be effected to facilitate the carrying out of the survey and the provisions of this Schedule shall apply with all necessary modifications to any such dewatering or reduction in the water level as though the same were specified works.

• (4) Copies of the survey shall be provided to both CRT and the undertaker at no cost to CRT.

Approval of plans, protective works etc.

6

• (1) The undertaker shall before commencing construction of any specified work within the boundaries of the specified works including any temporary works supply to CRT proper and sufficient plans of that work and such further particulars available to it as CRT may within 14 days of the submission of the plans reasonably require for the approval of the engineer and shall not commence such construction of a specified work until plans of that work have been approved in writing by the engineer or settled by arbitration.

• (2) The approval of the engineer under sub-paragraph (1) shall not be unreasonably withheld or delayed, and if within 35 days after such plans (including any other particulars reasonably required under sub-paragraph (1)) have been supplied to CRT the engineer has not intimated his disapproval of those plans and the grounds of his disapproval he shall be deemed to have approved the plans as submitted.

• (3) When signifying approval of the plans the engineer may specify on land held or controlled by CRT or the undertaker and subject to such works being authorised by the order or being development permitted by an Act of Parliament or general development order made under the 1990 Act —

• (a) any protective work (whether temporary or permanent) which in the reasonable opinion of the engineer should be carried out before the commencement of a specified work to prevent detriment; and

• (b) such other requirements as may be reasonably necessary to prevent detriment; and such protective works shall be constructed by the undertaker or by CRT at the undertaker’s request with all reasonable dispatch and the undertaker shall not commence the construction of a specified work until the engineer has notified the undertaker that the protective works have been completed to the engineer’s reasonable satisfaction such consent not to be unreasonably withheld or delayed.

• (4) The undertaker shall pay to CRT a capitalised sum representing the reasonably increased or additional cost of maintaining and, when necessary, renewing any works, including any permanent protective works provided under sub-paragraph (3) above, and of carrying out any additional dredging of the waterway reasonably necessitated by the exercise of any of the powers under this Order but if the cost of maintaining the waterway, or of works of renewal of the waterway, is reduced in consequence of any such works, a capitalised sum representing such reasonable saving shall be set off against any sum payable by the undertaker to CRT under this paragraph.

• (5) In the event that the undertaker fails to complete the construction of, or part of, the specified works CRT may, if it is reasonably required in order to avoid detriment, serve on the undertaker a notice in writing requesting that construction be completed. Any notice served under this sub-paragraph shall state the works that are to be completed by the undertaker and lay out a timetable for the works’ completion. If the undertaker fails to comply with this notice within 35 days, CRT may construct any of the specified works, or part of such works, (together with any adjoining works) in order to complete the construction of, or part of, the specified works or make such works and the undertaker shall reimburse CRT all costs, fees, charges and expenses it has reasonably incurred in carrying out such works.

Design of works

7

Without prejudice to its obligations under the foregoing provisions of this Schedule the undertaker shall consult, collaborate and respond constructively to any approach, suggestion, proposal or initiative made by CRT on—

• (a) the design and appearance of the specified works, including the materials to be used for their construction; and

• (b) the environmental effects of those works;

and shall have regard to such views as may be expressed by CRT to the extent that these accord with the requirements of the local planning authority in response to such consultation pursuant in particular to the requirements imposed on CRT by section 22 (general environmental and recreational duties) of the British Waterways Act 1995 and to the interest of CRT in preserving and enhancing the environment of its waterways.

Notice of works

8

The undertaker shall give to the engineer 30 days’ notice of its intention to commence the construction of any of the specified or protective works, or, in the case of repair carried out in an emergency, such notice as may be reasonably practicable so that, in particular, CRT may where appropriate arrange for the publication of notices bringing those works to the attention of users of CRT’s network.

Lighting

9

The undertaker shall provide and maintain at its own expense in the vicinity of the specified or protective works such temporary lighting and such signal lights for the control of navigation as the engineer may reasonably require during the construction or failure of the specified or protective works.

Construction of specified works

10

• (1) Any specified or protective works shall, when commenced, be constructed—

• (a) with all reasonable dispatch in accordance with the plans approved or deemed to have been approved or settled as aforesaid and with any requirements made under paragraph 6(3) and paragraph 7;

• (b) under the supervision (if given) and to the reasonable satisfaction of the engineer;

• (c) in such manner as to cause as little detriment as is reasonably practicable;

• (d) in such manner as to cause as little inconvenience as is reasonably practicable to CRT, its officers and agents and all other persons lawfully using the waterways, except to the extent that temporary obstruction has otherwise been agreed by CRT.

• (2) Nothing in this Order shall authorise the undertaker to make or maintain any permanent works in or over the waterway so as to impede or prevent (whether by reducing the width of the waterway or otherwise) the passage of any vessel which is of a kind (as to its dimensions) for which CRT is required by section 105(1)(b) and (2) of the Transport Act 1968 to maintain the waterway.

• (3) Following the completion of the construction of the specified works the undertaker shall restore the waterway to a condition no less satisfactory than its condition immediately prior to the commencement of those works unless otherwise agreed between the undertaker and CRT.

Prevention of pollution

11

The undertaker shall not in the course of constructing a specified work or a protective work or otherwise in connection therewith do or permit anything which may result in the pollution of the waterway or the deposit of materials therein and shall take such steps as the engineer may reasonably require to avoid or make good any breach of its obligations under this paragraph.

Access to work – provision of information

12

• (1) The undertaker on being given reasonable notice shall—

• (a) at all reasonable times allow reasonable facilities to the engineer for access to a specified work during its construction; and

• (b) supply the engineer with all such information as the engineer may reasonably require with regard to a specified work or the method of constructing it.

• (2) CRT on being given reasonable notice shall—

• (a) at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by CRT under this Schedule during their construction; and

• (b) supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them and the undertaker shall reimburse CRT’s reasonable costs in relation to the supply of such information.

Alterations to the waterway

13

• (1) If during the construction of a specified work or a protective work or during a period of twenty four (24) months after the completion of those works any alterations or additions, either permanent or temporary, to the waterway are reasonably necessary in consequence of the construction of the specified work or the protective work in order to avoid detriment, and CRT gives to the undertaker reasonable notice of its intention to carry out such alterations or additions (which shall be specified in the notice), the undertaker shall pay to CRT the reasonable costs of those alterations or additions including, in respect of any such alterations or additions as are to be permanent, a capitalised sum representing the increase of the costs which may be expected to be reasonably incurred by CRT in maintaining, working and, when necessary, renewing any such alterations or additions.

• (2) If the cost of maintaining, working or renewing the waterway is reduced in consequence of any such alterations or additions a capitalised sum representing such saving shall be set off against any sum payable by the undertaker to CRT under this paragraph.

Maintenance of works

14

If at any time after the completion of a specified work or a protective work, not being a work vested in CRT, CRT gives notice to the undertaker informing it that the state of maintenance of the work appears to be such that the work is causing or likely to cause detriment, the undertaker shall, on receipt of such notice, take such steps as may be reasonably necessary to put the work in such state of maintenance as not to cause such detriment.

Repayment of CRT’s fees, etc.

15

The undertaker shall repay to CRT in accordance with CRT’s Code of Practice for Works affecting the Canal and River Trust (as amended from time to time) all fees, costs, charges and expenses reasonably incurred by CRT—

• (a) in constructing any protective works under the provisions of paragraph 6(3)(a);

• (b) in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction or repair of a specified work and any protective works;

• (c) in respect of the employment during the construction of the specified works or any protective works of any inspectors, watchmen and other persons whom it shall be reasonably necessary to appoint for inspecting, watching and lighting any waterway and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of the specified works or any protective works; and

• (d) in bringing the specified works or any protective works to the notice of users of CRT’s network.

Costs of alterations, etc.

16

Any additional expenses which CRT may reasonable incur in altering, reconstructing or maintaining the waterway under any powers existing at the date when this Order was made by reason of the existence of a specified work shall, provided that 56 days’ previous notice of the commencement of such alteration, reconstruction or maintenance has been given to the undertaker, be repaired by the undertaker to CRT.

Making good of detriment; compensation and indemnity, etc.

17

• (1) If any detriment shall be caused by the construction or failure of the specified works or the protective works if carried out by the undertaker, the undertaker (if so required by CRT) shall make good such detriment and shall pay to CRT all reasonable expenses to which CRT may be put, and compensation for any loss which CRT may sustain, in making good or otherwise by reason of the detriment.

• (2) The undertaker shall be responsible for and make good to CRT all costs, charges, damages, expenses and losses not otherwise provided for in this Schedule which may be occasioned to and reasonably incurred by CRT—

• (a) by reason of the construction of a specified work or a protective work or the failure of such a work; or

• (b) by reason of any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged upon the construction of a specified work or a protective work; and subject to sub-paragraph (4) the undertaker shall effectively indemnify and hold harmless CRT from and against all claims and demands arising out of or in connection with any of the matters referred to in paragraphs (a) and (b) (provided that, save as expressly set out in this paragraph, CRT shall not be entitled to recover any consequential losses from the undertaker).

• (3) The fact that any act or thing may have been done by CRT on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision or in accordance with any directions or awards of an arbitrator shall not (if it was done without negligence on the part of CRT or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under the provisions of this paragraph.

• (4) Nothing in sub-paragraph (2) shall impose any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the neglect or wilful default of CRT, its officers, servants, contractors or agents.

• (5) CRT shall give the undertaker reasonable notice of any such claim or demand as aforesaid and no settlement or compromise of such a claim or demand shall be made without the prior consent of the undertaker.

• (6) The aggregate cap of the undertaker’s gross liability for consequential loses shall be limited to £10,000,000 (ten million pounds) for any one occurrence or all occurrences of a series arising out of the one original cause.

Arbitration

18

Any difference arising between the undertaker and CRT under this Schedule (other than a difference as to the meaning or construction of this Schedule) shall be referred to and settled by arbitration in accordance with article 36 (arbitration) of this Order.

Capitalised sums

19

Any capitalised sum which is required to be paid under this Schedule shall be calculated by multiplying the cost of the maintenance or renewal works to the waterway necessitated as a result of the operation of the authorised development by the number of times that the maintenance or renewal works will be required during the operation of the authorised development.

Signed

Signed by authority of the Secretary of State for Energy and Climate Change

Giles Scott — Head of National Infrastructure Consents and Coal Liabilities — Department of Energy and Climate Change — 10th March 2015

Explanatory note

(This note is not part of the Order)

EXPLANATORY NOTE

This Order grants development consent for, and authorises Knottingley Power Limited to construct, operate and maintain a combined cycle gas turbine power plant located in east Knottingley, Yorkshire, together with associated development comprising the diversion of the existing 400 kV overhead line to connect the power plant to the grid gas pipeline and cooling water pipelines together with all necessary and associated development. For the purposes of the development Knottingley Power Limited is authorised by the Order compulsorily or by agreement to purchase land and rights in land to use land, as well as to override easements and other rights. The Order also provides a defence in proceedings in respect of statutory nuisance and to discharge water. The Order imposes requirements in connection with the development for which it grants development consent.

A copy of the plans and book of reference referred to in this Order and certified in accordance with article 35 (certification of plans etc.) of this Order may be inspected free of charge at Knottingley Library at Knottingley Sports Centre, Hill Top, Pontefract Road, Knottingley, WF11 8EE, and at the offices of Wakefield Council at Wakefield One, Burton Street, Wakefield, WF1 2EB, North Yorkshire County Council at County Hall, Northallerton, North Yorkshire, DL7 8AD, and Selby District Council at Access Selby, 8-10 Market Cross, Selby, YO8 4JS.

Footnotes

Editorial notes