The Network Rail (Leeds to Micklefield Enhancements) Order 2024

Without affecting any provision in this Order or anything shown on the deposited plans Network Rail must not acquire any apparatus other than by agreement.

6

• (1) If, in the exercise of the powers conferred by this Order, Network Rail acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of an undertaker to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the undertaker in question.

• (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, Network Rail requires the removal of any apparatus placed in that land, it must give to the undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed.

• (3) Any alternative apparatus to be constructed in land of Network Rail under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the undertaker in question and Network Rail within 21 days of the service of a notice under sub-paragraph (2) or in default of agreement settled by arbitration in accordance with article 52 (arbitration).

• (4) In any case where alternative apparatus is to be provided or constructed under sub-paragraph (2), or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus, Network Rail must, subject to sub- paragraph (5), afford to the undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of Network Rail and for the subsequent maintenance of that apparatus.

• (5) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of Network Rail, or Network Rail is unable to afford such facilities and rights as are mentioned in sub-paragraph (4) in the land in which the alternative apparatus or part of such apparatus is to be constructed, the undertaker in question must, on receipt of a written notice to that effect from Network Rail, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

• (6) The undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 52 (arbitration), and after the grant to the undertaker of any such facilities and rights as are referred to in sub-paragraph (4) or (5), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by Network Rail to be removed under the provisions of this Part of this Schedule.

• (7) Without affecting anything in sub-paragraph (6), if Network Rail gives notice in writing to the undertaker in question that it desires itself to execute any work to which this sub-paragraph applies, that work, instead of being executed by the undertaker, must be executed by Network Rail without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the undertaker.

• (8) Sub-paragraph (7) applies to any part of any work necessary in connection with construction of alternative apparatus, or the removal of apparatus required to be removed, as will take place in any land of Network Rail.

• (9) Nothing in sub-paragraph (7) authorises Network Rail to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

7

• (1) Where, in accordance with the provisions of this Part of this Schedule, Network Rail affords to an undertaker facilities and rights for the construction and maintenance in land of Network Rail of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between Network Rail and the undertaker in question or in default of agreement settled by arbitration in accordance with article 52 (arbitration).

• (2) In settling those terms and conditions in respect of the alternative apparatus to be constructed in or along any railway of Network Rail, the arbitrator must—

• (a) give effect to all reasonable requirements of Network Rail for ensuring the safety and efficient operation of the railway and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of Network Rail or the traffic on the railway; and

• (b) so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed in or along the railway for which the alternative apparatus is to be substituted.

• (3) If the facilities and rights to be afforded by Network Rail in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by Network Rail to that undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

8

• (1) Not less than 28 days before starting the execution of any of the authorised works that are near to, or will or may affect, any apparatus the removal of which has not been required by Network Rail under paragraph 6(2), Network Rail must submit to the undertaker in question a plan, section and description of the works to be executed.

• (2) Those works are to be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and an officer of the undertaker is entitled to watch and inspect the execution of those works.

• (3) Any requirements made by the undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description are submitted to it under sub-paragraph (1).

• (4) If an undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by Network Rail, reasonably requires the removal of any apparatus and gives written notice to Network Rail of that requirement, paragraphs 1 to 7 apply as if the removal of the apparatus had been required by Network Rail under paragraph 6(2).

• (5) Nothing in this paragraph precludes Network Rail from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

• (6) Network Rail is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

9

If in consequence of the exercise of the powers conferred by this Order the access to any apparatus is materially obstructed Network Rail must provide such alternative means of access to such apparatus as will enable the undertaker to maintain or use the apparatus no less effectively than was possible before such obstruction.

10

• (1) Subject to the following provisions of this paragraph, Network Rail must repay to an undertaker the reasonable expenses incurred by that undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 6(2).

• (2) The value of any apparatus removed under the provisions of this Part of this Schedule is to be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.

• (3) If in accordance with the provisions of this Part of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by Network Rail or, in default of agreement, is not determined by arbitration in accordance with article 52 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the undertaker in question by virtue of sub-paragraph (1), is to be reduced by the amount of that excess.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus must not be treated as placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

• (5) An amount which apart from this sub-paragraph would be payable to an undertaker in respect of works by virtue of sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

• (6) Any dispute as to whether a financial benefit is conferred in accordance with sub-paragraph (5) or as to the amount of such financial benefit which cannot be agreed is to be determined in accordance with article 52 (arbitration).

11

• (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 6(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of an undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any undertaker, Network Rail must—

• (a) bear and pay the cost reasonably incurred by that undertaker in making good such damage or restoring the supply; and

• (b) make reasonable compensation to that undertaker for any other expenses, loss, damages, penalty or costs incurred by the undertaker,

by reason or in consequence of any such damage or interruption.

• (2) Nothing in sub-paragraph (1) imposes any liability on Network Rail with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an undertaker, its officers, servants, contractors or agents.

• (3) An undertaker must give Network Rail reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of Network Rail, which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

12

Nothing in this Part of this Schedule affects the provision of any enactment or agreement regulating the relations between Network Rail and an undertaker in respect of any apparatus laid or erected in land belonging to Network Rail on the date on which this Order is made.

PART 2 — FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

13

• (1) For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between Network Rail and the operator.

• (2) In this Part of this Schedule—

• “electronic communications apparatus” has the same meaning as in the electronic communications code;

• “the electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act⁷⁹;

• “electronic communications code network” means— so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and an electronic communications network which the Secretary of State is providing or proposing to provide;

• “electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act;

• “infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7(2) of that code; and

• “operator” means the operator of an electronic communications code network.

14

• (1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised works or their construction, or of any subsidence resulting from any of those works—

• (a) any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

• (b) there is any interruption in the supply of the service provided by an operator,

15

This Part of this Schedule does not apply to—

• (a) any apparatus in respect of which the relations between Network Rail and an operator are regulated by the provisions of Part 3 of the 1991 Act; or

• (b) any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised works.

16

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between Network Rail and an operator in respect of any apparatus laid or erected in land belonging to Network Rail on the date on which this Order is made.

PART 3 — FOR THE PROTECTION OF LEAD LOCAL FLOOD AUTHORITIES

17

• (1) The following provisions of this Part of this Schedule apply for the protection of the lead local flood authority unless otherwise agreed in writing between Network Rail and the lead local flood authority.

• (2) In this Part of this Schedule—

• “construction” includes execution, placing, altering, replacing, relaying and removal and “construct” and “constructed” are to be construed accordingly;

• “drainage work” means any watercourse and includes any land which provides or is expected to provide flood storage capacity for any ordinary watercourse and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage or flood defence;

• “lead local flood authority” means in relation to an ordinary watercourse the lead local flood authority concerned within the meaning of section 23 of the Land Drainage Act 1991⁸⁰;

• “ordinary watercourse” has the meaning given by the Land Drainage Act 1991; “plans” includes sections, drawings, specifications and method statements; and

• “specified work” means so much of any work or operation authorised by this Order as is in, on, under, over or within 16 metres of a drainage work or is otherwise likely to affect any drainage work.

18

• (1) Before beginning to construct any specified work, Network Rail must submit to the lead local flood authority plans of the specified work and such further particulars available to it as the lead local flood authority may within 28 days of the submission of the plans reasonably require.

• (2) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by the lead local flood authority, or determined under paragraph 25.

• (3) Any approval of the lead local flood authority required under this paragraph—

• (a) must not be unreasonably withheld or delayed;

• (b) is deemed to have been given if it is neither given nor refused within 2 months of the submission of the plans for approval and, in the case of a refusal, accompanied by a statement of the grounds of refusal; and

• (c) may be given subject to such reasonable requirements as the lead local flood authority may make for the protection of any drainage work.

• (4) The lead local flood authority must use its reasonable endeavours to respond to the submission of any plans before the expiration of the period mentioned in sub-paragraph (3)(b).

19

Without limitation on the scope of paragraph 18, the requirements which the lead local flood authority may make under that paragraph include conditions requiring Network Rail at its own expense to construct such protective works, whether temporary or permanent, during the construction of the specified works (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary—

• (a) to safeguard any drainage work against damage; or

• (b) to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased,

by reason of any specified work.

20

• (1) Subject to sub-paragraph (2), any specified work, and all protective works required by the lead local flood authority under paragraph 19, must be constructed—

• (a) without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under this Part of this Schedule; and

• (b) to the reasonable satisfaction of the lead local flood authority,

and an officer of the lead local flood authority is entitled to watch and inspect the construction of such works.

• (2) Network Rail must give to the lead local flood authority not less than 14 days’ notice in writing of its intention to commence construction of any specified work and notice in writing of its completion not later than 7 days after the date on which it is brought into use.

• (3) If any part of a specified work or any protective work required by the lead local flood authority is constructed otherwise than in accordance with the requirements of this Part of this Schedule, the lead local flood authority may by notice in writing require Network Rail at Network Rail’s own expense to comply with the requirements of this Part of this Schedule.

• (4) Subject to sub-paragraph (5), if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (3) is served upon Network Rail, it has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, the lead local flood authority may execute the works specified in the notice and any expenditure incurred by it in so doing is recoverable from Network Rail.

• (5) In the event of any dispute as to whether sub-paragraph (3) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the lead local flood authority must not except in emergency exercise the powers conferred by sub-paragraph (4) until the dispute has been finally determined.

21

• (1) Subject to sub-paragraph (3) Network Rail must from the commencement of the construction of the specified works maintain in good repair and condition and free from obstruction any drainage work which is situated within the limits of deviation or on land held by Network Rail for the purposes of or in connection with the specified works, whether or not the drainage work is constructed under the powers conferred by this Order or is already in existence.

• (2) If any such drainage work which Network Rail is liable to maintain is not maintained to the reasonable satisfaction of the lead local flood authority, the lead local flood authority may by notice in writing require Network Rail to repair and restore the work, or any part of such work, or (if Network Rail so elects and the lead local flood authority in writing consents, such consent not to be unreasonably withheld or delayed), to remove the work and restore the site to its former condition, to such extent and within such limits as the lead local flood authority reasonably requires.

• (3) This paragraph does not apply to—

• (a) drainage works which are vested in the lead local flood authority, or which the lead local flood authority or another person is liable to maintain and is not precluded by the powers of the Order from doing so; or

• (b) any obstruction of a drainage work for the purposes of a work or operation authorised by this Order and carried out in accordance with the provisions of this Part of this Schedule.

22

If by reason of the construction of any specified work or of the failure of any such work the efficiency of any drainage work for flood defence purposes is impaired, or that drainage work is otherwise damaged, such impairment or damage must be made good by Network Rail to the reasonable satisfaction of the lead local flood authority and if Network Rail fails to do so, the lead local flood authority may make good the impairment or damage and recover from Network Rail the expense reasonably incurred by it in so doing.

23

• (1) Network Rail must pay all costs, charges and expenses which the lead local flood authority may reasonably incur or have to pay—

• (a) in the examination or approval of plans under this Part of this Schedule; and

• (b) in the inspection of the construction of the specified works or any protective works required by the lead local flood authority under this Part of this Schedule.

24

The fact that any work or thing has been executed or done by Network Rail in accordance with a plan approved or deemed to be approved by the lead local flood authority, or to its satisfaction, or in accordance with any directions or award of an arbitrator, does not relieve Network Rail from any liability under the provisions of this Part of this Schedule.

25

Any dispute arising between Network Rail and the lead local flood authority under this Part of this Schedule, if the parties agree, is to be determined by arbitration under article 52 (arbitration).

PART 4 — FOR THE PROTECTION OF NORTHERN POWERGRID

26

For the protection of Northern Powergrid the following provisions have effect, unless otherwise agreed in writing between Network Rail and Northern Powergrid.

27

In this part of this Schedule—

• “the 1991 Act” means the New Roads and Street Works Act 1991;

• “alternative apparatus” means alternative apparatus adequate to enable Northern Powergrid to fulfil its statutory functions in a manner not less efficient than previously;

• “apparatus” means electric lines or electrical plant (as defined in the Electricity Act 1989), belonging to or maintained by Northern Powergrid and includes any structure in which apparatus is or is to be lodged or which will give or gives access to apparatus;

• “functions” includes powers and duties;

• “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

• “Northern Powergrid” means Northern Powergrid (Yorkshire) Plc (Company No. 04112320) whose registered office is at Lloyds Court, 78 Grey Street, Newcastle-Upon-Tyne, NE1 6AF (“Northern Powergrid”).

28

This Part of this Schedule does not apply to apparatus in respect of which the relations between Network Rail and Northern Powergrid are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.

Apparatus in stopped up highways

29

• (1) Where a street is stopped up under article 10 (stopping up of streets) or article 17 (replacement and closure of level crossings) if Northern Powergrid has any apparatus in that street or accessed via that street Northern Powergrid is entitled to the same rights in respect of that apparatus as it enjoyed immediately before the stopping up, subject to the provisions of this paragraph, as if this Order had not been made.

• (2) Regardless of the temporary stopping up streets under the powers conferred by article 12 (temporary stopping up of streets), Northern Powergrid is entitled at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that street.

Acquisition of land

30

• (1) Regardless of any provision in this Order or anything shown on the land plans, Network Rail must not acquire any apparatus or land owned by Northern Powergrid or override any easement used by Northern Powergrid otherwise than by agreement with Northern Powergrid, such agreement not to be unreasonably withheld or delayed.

• (2) Network Rail must not in the exercise of the powers conferred by this Order prevent pedestrian or vehicular access to any Northern Powergrid property or apparatus, unless preventing such access is with the consent of Northern Powergrid.

• (3) Network Rail must not under the powers of this Order acquire or use or acquire new rights over any Northern Powergrid property, or extinguish any existing rights of Northern Powergrid in respect of any third party property, except with the consent of Northern Powergrid.

• (4) Where Northern Powergrid is asked to give its consent pursuant to this paragraph, such consent must not be unreasonably withheld or delayed but may be given subject to reasonable conditions.

Removal of apparatus

31

• (1) If, in the exercise of the powers conferred by this Order, Network Rail acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that Northern Powergrid’s apparatus is relocated or diverted, that apparatus must not be removed under this Part, and any right of Northern Powergrid to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of Northern Powergrid in accordance with sub-paragraphs (2) to (7).

• (2) If, for the purpose of constructing any works in, on or under any land purchased, held, appropriated or used under this Order, Network Rail requires the removal of any apparatus placed in that land, Network Rail must give to Northern Powergrid 56 days advance written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order Northern Powergrid reasonably needs to remove any of its apparatus) Network Rail must, subject to sub-paragraph (3), afford to Northern Powergrid the necessary facilities and rights for the construction of alternative apparatus in other land of Network Rail and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of Network Rail, or Network Rail is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed—

• (a) Network Rail must in the first instance use all reasonable endeavours to acquire all necessary land interests or rights as Northern Powergrid may reasonably require for the relocation and construction of alternative apparatus and must use reasonable endeavours to procure all necessary rights to access and maintain Northern Powergrid’s apparatus and alternative apparatus thereafter the terms of such access and maintenance to be agreed by Northern Powergrid (acting reasonably); and

• (b) in the event Network Rail is not able to procure the necessary land interests or rights referred to in sub-paragraph 3(a) Northern Powergrid must, on receipt of a written notice to that effect from Network Rail, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for Northern Powergrid to use its compulsory purchase powers to this end unless it elects to do so.

• (4) Any alternative apparatus to be constructed in land of Network Rail under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Northern Powergrid and Network Rail or in default of agreement settled by arbitration in accordance with article 52 (arbitration).

• (5) Northern Powergrid must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 52 (arbitration), and after the grant to Northern Powergrid of any such facilities and rights as are referred to in subparagraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by Network Rail to be removed under the provisions of this Part of this Schedule.

• (6) Regardless of anything in sub-paragraph (5), if Network Rail gives notice in writing to Northern Powergrid that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by Network Rail, that work, instead of being executed by Northern Powergrid, may be executed Network Rail or a contractor of Network Rail approved by Northern Powergrid but only with the prior written consent of Northern Powergrid (which must not be unreasonably withheld or delayed and subject to any such conditions as are reasonable and proper to protect the apparatus and ensure compliance with Northern Powergrid’s licence conditions) in accordance with plans and in a position agreed between Northern Powergrid and Network Rail or, in default of agreement, determined by arbitration in accordance with article 52 (arbitration), without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of Northern Powergrid.

• (7) Nothing in sub-paragraph (6) authorises Network Rail to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 3000 millimetres of the apparatus unless otherwise agreed with Northern Powergrid.

Facilities and rights for alternative apparatus

32

• (1) Where, in accordance with the provisions of this Part of this Schedule, Network Rail affords to Northern Powergrid facilities and rights for the construction and maintenance in land of Network Rail of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between Network Rail and Northern Powergrid or in default of agreement settled by arbitration in accordance with article 52 (arbitration).

• (2) If the facilities and rights to be afforded by Network Rail in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Northern Powergrid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by Network Rail to Northern Powergrid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus

33

• (1) Not less than 42 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by Network Rail under paragraph 31 (2), Network Rail must submit to Northern Powergrid a plan, section and description of the works to be executed.

• (2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Northern Powergrid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and Northern Powergrid is entitled to watch and inspect the execution of those works.

• (3) Any requirements made by Northern Powergrid under sub-paragraph (2) must be made within a period of 42 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

• (4) If Northern Powergrid in accordance with sub-paragraph (3) and in consequence of the works proposed by Network Rail, reasonably requires the removal of any apparatus and gives written notice to Network Rail of that requirement, paragraphs 31 to 32 apply as if the removal of the apparatus had been required by Network Rail under paragraph 31(2).

• (5) Nothing in this paragraph precludes Network Rail from submitting at any time or from time to time, but in no case less than 35 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

• (6) Network Rail is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to Northern Powergrid notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Expenses and costs

34

• (1) Subject to the following provisions of this paragraph, Network Rail must pay to Northern Powergrid an amount equal to the cost reasonably incurred by Northern Powergrid—

• (a) in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 6(2); and

• (b) in assessing and preparing a design for its apparatus to address and accommodate the proposals of Network Rail whether or not Network Rail proceeds to implement those proposals or alternative or none at all,

provided that if it so prefers Northern Powergrid may abandon apparatus that Network Rail does not seek to remove in accordance with paragraph 31(2) having first decommissioned such apparatus.

• (2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal and, if the apparatus removed under the provisions of this Part of this Schedule has no value, no sum is to be deducted from the amount payable under sub-paragraph (1).

• (3) If in accordance with the provisions of this Part of this Schedule)—

• (a) apparatus of better type, of greater capacity or of greater dimension is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimension; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by Network Rail, or, in default of agreement, is not determined by arbitration (pursuant to article 52 (arbitration)) to be necessary, then, if it involves cost in the execution of works exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this paragraph would be payable to Northern Powergrid by virtue of sub-paragraph (1) is to be reduced by the amount of that excess save where it is not possible in the circumstances to obtain the existing type, capacity, or dimensions of apparatus, or to place the apparatus at the existing depth, in which case full costs shall be borne by Network Rail.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

Indemnity

35

• (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in this Order, or in consequence of the construction, use, maintenance or failure of any of the authorised development by or on behalf of Network Rail or in consequence of any act or default of Network Rail (or any person employed or authorised by it) in the course of carrying out such works, including without limitation works carried out by Network Rail under this Schedule any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Northern Powergrid, or there is any interruption in any service provided by Northern Powergrid, or as a consequence Northern Powergrid becomes liable to pay any amount to a third party Network Rail must—

• (a) bear and pay the cost reasonably incurred by Northern Powergrid in making good such damage or restoring the supply; and

• (b) indemnify Northern Powergrid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from Northern Powergrid, by reason or in consequence of any such damage or interruption or Northern Powergrid becoming liable to any third party.

• (2) Nothing in sub-paragraph (1) imposes any liability on Network Rail with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of Northern Powergrid, its officers, servants, contractors or agents, and nor does sub-paragraph (1) impose any liability on Network Rail in respect of consequential losses.

• (3) Northern Powergrid must give Network Rail reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of Network Rail which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

• (4) Northern Powergrid must use its reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands and penalties to which the indemnity under sub- paragraph (1) applies. If requested to do so by Network Rail, Northern Powergrid must provide an explanation of how the claim has been minimised. Network Rail is only liable under sub- paragraph (1) for claim reasonably incurred by Northern Powergrid.

Co-operation

36

Where in consequence of the proposed construction of any of the authorised development, Network Rail or Northern Powergrid requires the removal of apparatus or Northern Powergrid makes requirements for the protection or alteration of apparatus, Network Rail shall use its reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the need to ensure the safe and efficient operation of Northern Powergrid’s undertaking taking into account the Network Rail’s desire for the efficient and economic execution of the authorised development and Network Rail and Northern Powergrid shall use reasonable endeavours to co- operate with each other for those purposes.

Access

37

If in consequence of the powers conferred by this Order the access to any apparatus or alternative apparatus is materially obstructed, Network Rail shall provide such alternative means of access to such apparatus or alternative apparatus as will enable Northern Powergrid to maintain or use the said apparatus no less effectively than was possible before such obstruction.

Signed

Signed by authority of the Secretary of State for Transport

Natasha Kopala — Head of the Transport and Works Act Orders Unit — Department for Transport — 27th November 2024

Explanatory note

(This note is not part of the Order)

EXPLANATORY NOTE

This Order authorises Network Rail Infrastructure Limited to construct works on part of the upgrade to the Transpennine Leeds to Micklefield route. The Order authorises the acquisition of land and rights in land, extinguishment of rights and the use of land, for the purposes of the works and confers powers in connection with the construction and operation of the railway.

Copies of the deposited plans, the deposited sections and the book of reference referred to in the Order may be inspected, on request, at the offices of Network Rail Infrastructure Limited at Network Rail National Records Centre, Unit 5, Audax Road, Clifton Moor, York, YO30 4US.

Footnotes