The Heckington Fen Solar Park Order 2025

• “substation connection rights” means rights over land to— in connection with and for the purposes of facilitating Work No. 6A, install, use, support, protect, inspect, alter, remove, replace, retain, renew, improve and maintain electrical cables, earthing cables, optical fibre cables, data cables, telecommunications cables and other services, works associated with such cables including bays, ducts, protection and safety measures and equipment, and other apparatus and structures and to connect such cables and services to the National Grid Bicker Fen substation; in connection with and for the purposes of facilitating Work No. 6A, install, use, support, protect, inspect, alter, remove, replace, retain, renew, improve and maintain watercourses, public sewers and drains and drainage apparatus and equipment; remain, pass and repass on foot, with or without vehicles, plant and machinery (including rights to lay and use any temporary surface) for all purposes in connection with Work No. 6A; in connection with and for the purposes of facilitating Work No. 6A restrict and remove the erection of buildings or structures, restrict the altering of ground levels, restrict and remove the planting of trees or carrying out operations or actions (including but not limited to blasting and piling) which may obstruct, interrupt or interfere with the exercise of the rights or damage the authorised development; and remove landscaping measures. (1) Plot reference number shown on the land plans (2) Purposes for which rights over land may be acquired and restrictive covenants imposed 12Access rights and cable rights60AAccess rights and cable rights60BAccess rights and cable rights60CAccess rights and cable rights63AAccess rights and cable rights63BAccess rights and cable rights63CAccess rights63DAccess rights64Access rights66AAccess rights66BAccess rights and cable rights67AAccess rights67BAccess rights and cable rights67CAccess rights67DAccess rights68AAccess rights68BAccess rights68CAccess rights and cable rights68DAccess rights68EAccess rights68FAccess rights69Access rights and cable rights72Access rights and cable rights73AAccess rights73BAccess rights75AAccess rights75BAccess rights75CAccess rights75DAccess rights and cable rights75EAccess rights75FAccess rights75GAccess rights75HAccess rights75IAccess rights and cable rights75JAccess rights76AAccess rights76BAccess rights and cable rights89Access rights90Access rights94Access rights97Access rights99BAccess rights and cable rights99CAccess rights and cable rights99DAccess rights and cable rights99EAccess rights99FAccess rights99GSubstation connection rights99HSubstation connection rights100AAccess rights and cable rights100BAccess rights and cable rights101AAccess rights and cable rights101BAccess rights and cable rights101CAccess rights and cable rights104AAccess rights and cable rights104BAccess rights104CAccess rights104DAccess rights and cable rights104EAccess rights and cable rights107AAccess rights107BAccess rights108AAccess rights and cable rights108BAccess rights and cable rights108CAccess rights and cable rights109AAccess rights109BAccess rights124Access rights and cable rights173Access rights184Access rights and cable rights190Access rights and cable rights245Access rights and cable rights248Access rights and cable rights255Access rights and cable rights265Access rights266AAccess rights and cable rights266BAccess rights and cable rights269Access rights and cable rights273Access rights274Access rights279Access rights284Access rights and cable rights285Access rights and cable rights286Access rights and cable rights287Access rights288Access rights and cable rights289Access rights290Access rights293AAccess rights and cable rights293BAccess rights and cable rights294Access rights295Access rights and cable rights296Access rights297Access rights298Access rights301Access rights302AAccess rights and cable rights302BAccess rights303Access rights and cable rights304Access rights and cable rights307Access rights312Access rights313Access rights316Access rights and cable rights317Access rights322Access rights323Access rights and cable rights324Access rights325Access rights326Access rights329Access rights and cable rights333Access rights and cable rights334Access rights and cable rights335Access rights337Access rights338Access rights339Access rights341Access rights346Access rights and cable rights347Access rights and cable rights348Access rights and cable rights349Access rights

SCHEDULE 9 — MODIFICATION OF COMPENSATION AND COMPULSORY PURCHASE ENACTMENTS FOR THE CREATION OF NEW RIGHTS AND IMPOSITION OF NEW RESTRICTIVE COVENANTS

Compensation enactments

1

The enactments for the time being in force with respect to compensation for the compulsory purchase of land apply, with the necessary modifications as respects compensation, in the case of a compulsory acquisition under this Order of a right by the creation of a new right or the imposition of a restrictive covenant as they apply as respects compensation on the compulsory purchase of land and interests in land.

2

• (1) Without limitation on the scope of paragraph 1, the Land Compensation Act 1973⁵⁴ has effect subject to the modifications set out in sub-paragraph (2).

• (2) In section 44(1) (compensation for injurious affection), as it applies to compensation for injurious affection under section 7 (measure of compensation in case of severance) of the 1965 Act as substituted by paragraph 5—

• (a) for the words “land is acquired or taken from” substitute “a right or restrictive covenant over land is purchased from or imposed on”; and

• (b) for the words “acquired or taken from him” substitute “over which the right is exercisable or the restrictive covenant enforceable”.

3

• (1) Without limitation on the scope of paragraph 1, the 1961 Act has effect subject to the modification set out in sub-paragraph (2).

• (2) In section 5A(5A) (relevant valuation date), omit the words after “if—” and substitute—

(a) the acquiring authority enters on land for the purpose of exercising a right in pursuance of a notice of entry under section 11(1) of the 1965 Act (as modified by paragraph 5(5) of Schedule 9 to the Heckington Fen Solar Park Order 2025); (b) the acquiring authority is subsequently required by a determination under paragraph 12 of Schedule 2A to the 1965 Act (as substituted by paragraph 5(8) of Schedule 9 to the Heckington Fen Solar Park Order 2025) to acquire an interest in the land; and (c) the acquiring authority enters on and takes possession of that land, the authority is deemed for the purposes of subsection (3)(a) to have entered on that land where it entered on that land for the purpose of exercising that right.

Application of Part 1 of the 1965 Act

4

Part 1 (compulsory purchase under Acquisition of Land Act 1946) of the 1965 Act, as applied by section 125 (application of compulsory acquisition provisions) of the 2008 Act to the acquisition of land under article 17 (compulsory acquisition of land) and as modified by article 24 (modification of Part 1 of the 1965 Act), applies to the compulsory acquisition of a right by the creation of a new right under article 19 (compulsory acquisition of rights)—

• (a) with the modifications specified in paragraph 5; and

• (b) with such other modifications as may be necessary.

5

• (1) The modifications referred to in sub-paragraph (4)(a) are as follows—

• (2) References in the 1965 Act to land are, in the appropriate contexts, to be read (according to the requirements of the particular context) as referring to, or as including references to—

• (a) the right acquired or to be acquired, or the restriction imposed or to be imposed; or

• (b) the land over which the right is or is to be exercisable, or the restriction is to be enforceable.

• (3) For section 7 (measure of compensation in case of severance) of the 1965 Act substitute—

(7) In assessing the compensation to be paid by the acquiring authority under this Act, regard must be had not only to the extent (if any) to which the value of the land over which the right is to be acquired or the restrictive covenant is to be imposed is depreciated by the acquisition of the right or the imposition of the covenant but also to the damage (if any) to be sustained by the owner of the land by reason of its severance from other land of the owner, or injuriously affecting that other land by the exercise of the powers conferred by this or the special Act.

• (4) The following provisions of the 1965 Act (which state the effect of a deed poll executed in various circumstances where there is no conveyance by persons with interests in the land), that is to say—

• (a) section 9(4) (failure by owners to convey);

• (b) paragraph 10(3) of Schedule 1 (persons without power to sell their interests);

• (c) paragraph 2(3) of Schedule 2 (absent and untraced owners); and

• (d) paragraphs 2(3) and 7(2) of Schedule 4 (common land),

are modified to secure that, as against persons with interests in the land which are expressed to be overridden by the deed, the right which is to be compulsorily acquired or the restrictive covenant which is to be imposed is vested absolutely in the acquiring authority.

• (5) Section 11 (powers of entry)⁵⁵ of the 1965 Act is modified to secure that, as from the date on which the acquiring authority has served notice to treat in respect of any right or restrictive covenant, as well as the notice of entry required by subsection (1) of that section (as it applies to compulsory acquisition under article 17 (compulsory acquisition of land)), it has power, exercisable in equivalent circumstances and subject to equivalent conditions, to enter for the purpose of exercising that right or enforcing that restrictive covenant (which is deemed for this purpose to have been created on the date of service of the notice); and sections 11A (powers of entry: further notices of entry)⁵⁶, 11B (counter-notice requiring possession to be taken on specified date)⁵⁷, 12 (penalty for unauthorised entry)⁵⁸ and 13 (refusal to give possession to acquiring authority)⁵⁹ of the 1965 Act are modified correspondingly.

• (6) Section 20 (tenants at will, etc.)⁶⁰ of the 1965 Act applies with the modifications necessary to secure that persons with such interests in land as are mentioned in that section are compensated in a manner corresponding to that in which they would be compensated on a compulsory acquisition under this Order of that land, but taking into account only the extent (if any) of such interference with such an interest as is actually caused, or likely to be caused, by the exercise of the right or the enforcement of the restrictive covenant in question.

• (7) Section 22 (interests omitted from purchase) of the 1965 Act as modified by article 24(4) (modification of Part 1 of the Compulsory Purchase Act 1965) is so modified as to enable the acquiring authority, in circumstances corresponding to those referred to in that section, to continue to be entitled to exercise the right acquired or restrictive covenant imposed, subject to compliance with that section as respects compensation.

• (8) For Schedule 2A (counter notice requiring purchase of land not in notice to treat) to the 1965 Act substitute—

SCHEDULE2A (1) (1) This Schedule applies where an acquiring authority serves a notice to treat in respect of a right over, or restrictive covenant affecting, the whole or part of a house, building or factory and have not executed a general vesting declaration under section 4 of the 1981 Act as applied by article 21 (application of the 1981 Act) of the Heckington Fen Solar Park Order 2025 in respect of the land to which the notice to treat relates. (2) But see article 22(3) (acquisition of subsoil only) of the Heckington Fen Solar Park Order 2025 which excludes the acquisition of subsoil only from this Schedule. (2) In this Schedule, “house” includes any park or garden belonging to a house. (3) A person who is able to sell the house, building or factory (“the owner”) may serve a counter-notice requiring the authority to purchase the owner’s interest in the house, building or factory. (4) A counter-notice under paragraph 3 must be served within the period of 28 days beginning with the day on which the notice to treat was served. (5) On receiving a counter-notice, the acquiring authority must decide whether to— (a) withdraw the notice to treat, (b) accept the counter-notice, or (c) refer the counter-notice to the Upper Tribunal. (6) The authority must serve notice of their decision on the owner within the period of three months beginning with the day on which the counter-notice is served (“the decision period”). (7) If the authority decides to refer the counter-notice to the Upper Tribunal they must do so within the decision period. (8) If the authority does not serve notice of a decision within the decision period they are to be treated as if they had served notice of a decision to withdraw the notice to treat at the end of that period. (9) If the authority serves notice of a decision to accept the counter-notice, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in the house, building or factory. (10) On a referral under paragraph 7, the Upper Tribunal must determine whether the acquisition of the right or the imposition of the restrictive covenant would— (a) in the case of a house, building or factory, cause material detriment to the house, building or factory, or (b) in the case of a park or garden, seriously affect the amenity or convenience of the house to which the park or garden belongs. (11) In making its determination, the Upper Tribunal must take into account— (a) the effect of the acquisition of the right or the imposition of the covenant, (b) the use to be made of the right or covenant proposed to be acquired or imposed, and (c) if the right or covenant is proposed to be acquired or imposed for works or other purposes extending to other land, the effect of the whole of the works and the use of the other land. (12) If the Upper Tribunal determines that the acquisition of the right or the imposition of the covenant would have either of the consequences described in paragraph 10, it must determine how much of the house, building or factory the authority ought to be required to take. (13) If the Upper Tribunal determines that the authority ought to be required to take some or all of the house, building or factory, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in that land. (14) (1) If the Upper Tribunal determines that the authority ought to be required to take some or all of the house, building or factory, the authority may at any time within the period of six weeks beginning with the day on which the Upper Tribunal makes its determination withdraw the notice to treat in relation to that land. (2) If the acquiring authority withdraws the notice to treat under this paragraph they must pay the person on whom the notice was served compensation for any loss or expense caused by the giving and withdrawal of the notice. (3) Any dispute as to the compensation is to be determined by the Upper Tribunal.

SCHEDULE 10 — HEDGEROWS TO BE REMOVED

(1) Area	(2) Number of hedgerow and extent of removal	(3) Purpose of removal
North Kesteven District Council / Boston Borough Council (border)	Removal of that part of the hedgerow (including four goat willows and one Lombardy poplar) shown approximately within the pink area identified on sheet 6 of the important hedgerows plan.	To facilitate construction of the authorised development (Work No. 5).
Boston Borough Council	Removal of those parts of the hedgerow (including sections of hawthorn hedgerow within the drainage ditch) shown approximately within the pink area identified on sheets 7 and 8 of the important hedgerows plan.	To facilitate construction of the authorised development (Work No. 5).
Boston Borough Council	Removal of that part of the hedgerow (including a section of hawthorn) shown approximately within the pink area identified on sheet 12 of the important hedgerows plan.	To facilitate construction of the authorised development (Work No. 5A).
Boston Borough Council	Removal of that part of the hedgerow (which includes various woodland comprising oak, goat willow, silver birch, hazel, field maple, aspen, lime, ash and dogwood) shown approximately within the pink area on sheet 13 of the important hedgerows plan.	To facilitate construction of the authorised development (Work No. 5B).

SCHEDULE 11 — DOCUMENTS AND PLANS TO BE CERTIFIED

(1) Document name	(2) Applicant’s Document reference	(3) Revision number	(4) Date
book of reference	4.3	7.0	February 2024
environmental statement	6.1, 6.2, and 6.3	2.0	August 2023 (unless otherwise stated below)
	6.1.17 6.2.5 6.2.7 6.2.13 - 6.2.14 6.2.16-6.2.20 6.3.1 - 6.3.3 6.3.6 - 6.3.10 6.3.12 6.3.14 - 6.3.18	1.0	February 2023
	6.3.4.1	1.0	March 2023
	ExA.6.3.7.13-D3.V2	1.0	November 2023
	6.1.0 - 6.1.3 6.1.7 - 6.1.9 6.1.12 - 6.1.15 6.1.18 6.1.20 6.2.1 - 6.2.3 6.2.6 - 6.2.12 6.2.15 6.3.6 6.3.14	2.0	August 2023
	6.1.10 6.1.16 6.1.19 6.2.3 - 6.2.4 6.2.10	2.0	November 2023
	6.3.6.9	3.0	August 2023
	6.1.5 6.2.2 6.2.6	3.0	November 2023
	6.2.6	4.0	December 2023
	6.1.4	5.0	January 2024
	6.1.11	4.0	January 2024
	6.1.6	3.0	February 2024
ES technical note – updated information on cumulative projects	ExA.ESTN-Cumulative-D5.V4	4.0	February 2024
Appendix 8.13 – biodiversity net gain assessment report	ExA.6.3.8.13-D4.V2	2.0	January 2024
ES transport and access technical note – sensitivity of cowbridge road, bicker drove, and vicarage drove	ExA.ESTATN.D3.V1	1.0	December 2023
ES technical note – additional ecology information	ExA.ESTNE.D3.V1	1.0	December 2023
equality impact assessment	ExA.EIA-D3.V1	1.0	December 2023
ES transport and access technical note – assessment of triton knoll access track, doubletwelves drove and bicker drove	ExA.ESTATN-Access-D5.V1	1.0	February 2024
flood risk assessment	6.3.9.1	2.0	March 2023
important hedgerows plan	2.9	3.0	January 2024
interface area plan	ExA.BFInterface.D5.V1	1.0	February 2024
land and crown land plan	2.1	5.0	January 2024
outline energy storage safety management plan	7.11	3.0	January 2024
outline construction environmental management plan	7.7	6.0	February 2024
outline construction traffic management plan	7.10	5.0	February 2024
outline decommissioning and restoration plan	7.9	4.0	February 2024
outline design principles	7.1	4.0	January 2024
outline landscape ecological management plan	7.8	6.0	February 2024
outline operational environmental management plan	ExA.oOEMP-D5.V3	3.0	February 2024
outline soil management plan	7.15	3.0	February 2024
outline supply chain, employment and skills plan	7.12	4.0	February 2024
outline written scheme of investigation – evaluation	7.13	2.0	November 2023
outline written scheme of investigation – mitigation	7.14	2.0	November 2023
rights of way plan	2.3	4.0	January 2024
streets and access plans	2.7	5.0	January 2024
works plans	2.2	6.0	February 2024

SCHEDULE 12 — ARBITRATION RULES

Commencing an arbitration

1

• (1) The arbitration is deemed to have commenced when a party (“the claimant”) serves a written notice of arbitration on the other party (“the respondent”).

• (2) The primary objective of these Arbitration Rules is to achieve a fair, impartial, final and binding award on the substantive difference between the parties (save as to costs) within 4 months from the date the arbitrator is appointed pursuant to article 38 of the Order.

Time periods

2

• (1) All time periods in these Arbitration Rules are measured in days and include weekends, but not bank or public holidays.

• (2) Time periods are calculated from the day after the arbitrator is appointed which is either—

• (a) the date the arbitrator notifies the parties in writing of his/her acceptance of an appointment by agreement of the parties; or

• (b) the date the arbitrator is appointed by the Secretary of State.

Timetable

3

• (1) The timetable for the arbitration is that which is set out in sub-paragraphs (2) to (4) below unless amended in accordance with paragraph 5(3).

• (2) Within 14 days of the arbitrator being appointed, the claimant must provide both the respondent and the arbitrator with—

• (a) a written statement of claim which describes the nature of the difference between the parties, the legal and factual issues, the claimant’s contentions as to those issues, the amount of its claim or the remedy it is seeking; and

• (b) all statements of evidence and copies of all documents on which it relies, including contractual documentation, correspondence (including electronic documents), legal precedents and expert witness reports.

• (3) Within 14 days of receipt of the claimant’s statements under sub-paragraph (2) by the arbitrator and respondent, the respondent must provide the claimant and the arbitrator with—

• (a) a written statement of defence consisting of a response to the claimant’s statement of claim, its statement in respect of the nature of the difference, the legal and factual issues in the claimant’s claim, its acceptance of any elements of the claimant’s claim and its contentions as to those elements of the claimant’s claim it does not accept;

• (b) all statements of evidence and copies of all documents on which it relies, including contractual documentation, correspondence (including electronic documents), legal precedents and expert witness reports; and

• (c) any objections it wishes to make to the claimant’s statements, comments on the claimant’s expert reports (if submitted by the claimant) and explanations of the objections.

• (4) Within seven days of the respondent serving its statements under sub-paragraph (3), the claimant may make a statement of reply by providing both the respondent and the arbitrator with—

• (a) a written statement responding to the respondent’s submissions, including its reply in respect of the nature of the difference, the issues (both factual and legal) and its contentions in relation to the issues;

• (b) all statements of evidence and copies of documents in response to the respondent’s submissions;

• (c) any expert report in response to the respondent’s submissions;

• (d) any objections to the statements of evidence, expert reports or other documents submitted by the respondent; and

• (e) its written submissions in response to the legal and factual issues involved.

Procedure

4

• (1) The parties’ pleadings, witness statements and expert reports (if any) must be concise. A single pleading must not exceed 30 single-sided A4 pages using 10pt Arial font.

• (2) The arbitrator will make an award on the substantive differences based solely on the written material submitted by the parties unless the arbitrator decides that a hearing is necessary to explain or resolve any matters.

• (3) Either party may, within two days of delivery of the last submission, request a hearing giving specific reasons why it considers a hearing is required.

• (4) Within seven days of receiving the last submission, the arbitrator must notify the parties whether a hearing is to be held and the length of that hearing.

• (5) Within 10 days of the arbitrator advising the parties that a hearing is to be held, the date and venue for the hearing are to be fixed by agreement with the parties, save that if there is no agreement the arbitrator must direct a date and venue which the arbitrator considers is fair and reasonable in all the circumstances. The date for the hearing must not be less than 35 days from the date of the arbitrator’s direction confirming the date and venue of the hearing.

• (6) A decision must be made by the arbitrator on whether there is any need for expert evidence to be submitted orally at the hearing. If oral expert evidence is required by the arbitrator, then any experts attending the hearing may be asked questions by the arbitrator.

• (7) There is to be no examination or cross-examination of experts, but the arbitrator must invite the parties to ask questions of the experts by way of clarification of any answers given by the experts in response to the arbitrator’s questions. Prior to the hearing in relation to the experts—

• (a) at least 28 days before a hearing, the arbitrator must provide a list of issues to be addressed by the experts;

• (b) if more than one expert is called, they will jointly confer and produce a joint report or reports within 14 days of the issues being provided; and

• (c) the form and content of a joint report must be as directed by the arbitrator and must be provided at least seven days before the hearing.

• (8) Within 14 days of a hearing or a decision by the arbitrator that no hearing is to be held the parties may by way of exchange provide the arbitrator with a final submission in connection with the matters in dispute and any submissions on costs. The arbitrator must take these submissions into account in the award.

• (9) The arbitrator may make other directions or rulings as considered appropriate in order to ensure that the parties comply with the timetable and procedures to achieve an award on the substantive difference within four months of the date on which the arbitrator is appointed, unless both parties otherwise agree to an extension to the date for the award.

• (10) If a party fails to comply with the timetable, procedure or any other direction then the arbitrator may continue in the absence of a party or submission or document, and may make a decision on the information before the arbitrator attaching the appropriate weight to any evidence submitted beyond any timetable or in breach of any procedure or direction.

• (11) The arbitrator’s award must include reasons. The parties must accept that the extent to which reasons are given must be proportionate to the issues in dispute and the time available to the arbitrator to deliver the award.

Arbitrator’s powers

5

• (1) The arbitrator has all the powers of the Arbitration Act 1996, save where modified in this Schedule.

• (2) There must be no discovery or disclosure, except that the arbitrator is to have the power to order the parties to produce such documents as are reasonably requested by another party no later than the statement of reply, or by the arbitrator, where the documents are manifestly relevant, specifically identified and the burden of production is not excessive. Any application and orders should be made by way of a Redfern Schedule without any hearing.

• (3) Any time limits fixed in accordance with this procedure or by the arbitrator may be varied by agreement between the parties, subject to any such variation being acceptable to and approved by the arbitrator. In the absence of agreement, the arbitrator may vary the timescales or procedure—

• (a) if the arbitrator is satisfied that a variation of any fixed time limit is reasonably necessary to avoid a breach of the rules of natural justice and then;

• (b) only for such a period that is necessary to achieve fairness between the parties.

• (4) On the date the award is made, the arbitrator will notify the parties that the award is completed, signed and dated, and that it will be issued to the parties on receipt of cleared funds for the arbitrator’s fees and expenses.

Costs

6

• (1) The costs of the arbitration must include the fees and expenses of the arbitrator, the reasonable fees and expenses of any experts and the reasonable legal and other costs incurred by the parties for the arbitration.

• (2) Where the difference involves connected or interrelated issues, the arbitrator must consider the relevant costs collectively.

• (3) The final award must fix the costs of the arbitration and decide which of the parties are to bear them or in what proportion they are to be borne by the parties.

• (4) The arbitrator must award recoverable costs on the general principle that each party should bear its own costs, having regard to all material circumstances, including such matters as exaggerated claims or defences, the degree of success for different elements of the claims, claims that have incurred substantial costs, the conduct of the parties and the degree of success of a party.

Confidentiality

7

• (1) Hearings in this arbitration are to take place in public unless otherwise agreed by the arbitrator on application from one or both of the parties.

• (2) Materials, documents, awards, expert reports and any matters relating to the arbitration are confidential and must not be disclosed to any third party without prior written consent of the other party, save for any application to the courts or where disclosure is required under any legislative or regulatory requirement.

SCHEDULE 13 — PROTECTIVE PROVISIONS

PART 1 — FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS

1

For the protection of the utility undertakers referred to in this Part of this Schedule (save for Anglian Water which is protected by Part 3 of this Schedule, National Gas Transmission Plc as gas undertaker which is protected by Part 4 of this Schedule, National Grid Electricity Transmission Plc as electricity undertaker which is protected by Part 6 of this Schedule, National Grid Viking Limited which is protected by Part 10 of this Schedule, Beacon Fen Energy Park Limited which is protected by Part 11 of this Schedule, and Triton Knoll OFTO Limited which is protected by Part 12 of this Schedule) the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertakers concerned.

2

In this Part of this Schedule—

• “alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;

• “apparatus” means—in the case of an electricity undertaker, electric lines or electrical plant (as defined in the 1989 Act), belonging to or maintained by that utility undertaker;in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply;in the case of a water undertaker—mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; andany water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A of the Water Industry Act 1991⁶¹;in the case of a sewerage undertaker—any drain or works vested in the utility undertaker under the Water Industry Act 1991; andany sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act,and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

• “functions” includes powers and duties;

• “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

• “utility undertaker” means—any licence holder within the meaning of Part 1 of the Electricity Act 1989;a gas transporter within the meaning of Part 1 of the Gas Act 1986⁶²;a water undertaker within the meaning of the Water Industry Act 1991; anda sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.

Precedence of the 1991 Act in respect of apparatus in the streets

3

This part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 of the 1991 Act.

4

Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 11 (temporary closure of public rights of way), a utility undertaker is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.

No acquisition etc. except by agreement

5

Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Removal of apparatus

6

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7).

• (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

• (4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 38 (arbitration).

• (5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 38 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

• (6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

• (7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

Facilities and rights for alternative apparatus

7

• (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 38 (arbitration).

• (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

8

• (1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 6(2), the undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed.

• (2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.

• (3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

• (4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 7 apply as if the removal of the apparatus had been required by the undertaker under paragraph 6(2).

• (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

• (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

9

• (1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker the reasonable expenses incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 6(2).

• (2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal.

• (3) If in accordance with the provisions of this Part of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 38 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 6(2); and

• (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

• (5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

Expenses and costs

10

• (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 6(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—

• (a) bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

• (b) make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,

by reason or in consequence of any such damage or interruption.

• (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

• (3) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

11

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaking in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 2 — FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

12

• (1) For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.

• (2) In this Part of this Schedule—

• “electronic communications apparatus” has the same meaning as in the electronic communications code;

• “the electronic communications code” has the same meaning as in section 106 (application of the electronic communications code) of the 2003 Act;

• “electronic communications code network” means— so much of an electronic communications network or conduit system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and an electronic communications network which the Secretary of State is providing or proposing to provide;

• “electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act; and

• “operator” means the operator of an electronic communications code network.

13

The exercise of the powers of article 28 (statutory undertakers) is subject to Part 10 (undertakers’ works affecting electronic communications apparatus) of the electronic communications code.

14

• (1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—

• (a) any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

• (b) there is any interruption in the supply of the service provided by an operator,

the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.

• (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

• (3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

• (4) Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 38 (arbitration).

15

This Part of this Schedule does not apply to—

• (a) any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act; or

• (b) any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.

16

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 3 — FOR THE PROTECTION OF ANGLIAN WATER

Application

17

For the protection of Anglian Water the following provisions have effect, unless otherwise agreed in writing between the undertaker and Anglian Water.

Interpretation

18

In this Part of this Schedule—

• “alternative apparatus” means alternative apparatus adequate to enable Anglian Water to fulfil its statutory functions in a manner no less efficient than previously;

• “Anglian Water” means Anglian Water Services Limited;

• “apparatus” means—works, mains, pipes or other apparatus belonging to or maintained by Anglian Water for the purposes of water supply and sewerage;any drain or works vested in Anglian Water under the Water Industry Act 1991;any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act;any drainage system constructed for the purpose of reducing the volume of surface water entering any public sewer belonging to Anglian Water; andincludes a sludge main, disposal main or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus,and for the purpose of this definition, where words are defined by section 219 of that Act, they shall be taken to have the same meaning;

• “functions” includes powers and duties;

• “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

• “Ofwat” means The Water Services Regulation Authority;

• “plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed.

Protective works to buildings

19

The undertaker, in the case of the powers conferred by article 15 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus without the written consent of Anglian Water (such consent not to be unreasonably withheld or delayed).

Acquisition of land

20

Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Removal of apparatus

21

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that Anglian Water’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of Anglian Water to maintain that apparatus in that land must not be extinguished, until—

• (a) alternative apparatus has been constructed and is in operation to the reasonable satisfaction of Anglian Water in accordance with sub-paragraphs (2) to (8); and

• (b) facilities and rights have been secured for that alternative apparatus in accordance with paragraph 22.

• (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to Anglian Water 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Anglian Water the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed Anglian Water must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

• (4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Anglian Water and the undertaker or in default of agreement settled by arbitration in accordance with article 38 (arbitration).

• (5) Anglian Water must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 38, and after the grant to Anglian Water of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

• (6) Regardless of anything in sub-paragraph (5), if Anglian Water determines acting reasonably that there is a technical requirement for the undertaker to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker and Anglian Water gives notice in writing to the undertaker that it desires the undertaker to execute such reasonably required works, or to the extent that Anglian Water fails to proceed with that work in accordance with sub-paragraph (5), or the undertaker and Anglian Water otherwise agree, that work, instead of being executed by Anglian Water, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of Anglian Water.

• (7) If Anglian Water fails either reasonably to approve, or to provide reasons for its failure to approve along with an indication of what would be required to make acceptable, any proposed details relating to required removal works under sub-paragraph (2) within 28 days of receiving a notice of the required works from the undertaker, then such details are deemed to have been approved. For the avoidance of doubt, any such “deemed consent” does not extend to the actual undertaking of the removal works, which shall remain the sole responsibility of Anglian Water or its contractors.

• (8) Whenever alternative apparatus is to be or is being substituted for existing apparatus, the undertaker shall, before taking or requiring any further step in such substitution works, use reasonable endeavours to comply with Anglian Water’s reasonable requests for a reasonable period of time to enable Anglian Water to—

• (a) make network contingency arrangements; or

• (b) bring such matters as it may consider reasonably necessary to the attention of end users of the utility in question.

Facilities and rights for alternative apparatus

22

• (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and Anglian Water or in default of agreement settled by arbitration in accordance with article 38 (arbitration).

• (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Anglian Water than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Anglian Water as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

• (3) Such facilities and rights as are set out in this paragraph are deemed to include any statutory permits granted to the undertaker in respect of the apparatus in question, whether under the Environmental Permitting (England and Wales) Regulations 2016 or other legislation.

Retained apparatus

23

• (1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus (or any means of access to it) the removal of which has not been required by the undertaker under paragraph 21(2), the undertaker must submit to Anglian Water a plan of the works to be executed.

• (2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Anglian Water for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and Anglian Water is entitled to watch and inspect the execution of those works.

• (3) Any requirements made by Anglian Water under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it.

• (4) If Anglian Water in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 20 to 22 apply as if the removal of the apparatus had been required by the undertaker under paragraph 21(2).

• (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

• (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case must give to Anglian Water notice as soon as is reasonably practicable and a plan of those works as soon as is reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances using its best endeavours to keep the impact of those emergency works on Anglian Water’s apparatus, on the operation of its water and sewerage network and on end-users of the services Anglian Water provides to a minimum.

• (7) For the purposes of sub-paragraph (1) and without prejudice to the generality of the principles set out in that sub-paragraph, works are deemed to be in land near Anglian Water’s apparatus (where it is a pipe) if those works fall within the following distances measured from the medial line of such apparatus—

• (a) 4 metres where the diameter of the pipe is less than 250 millimetres;

• (b) 5 metres where the diameter of the pipe is between 250 and 400 millimetres; and

• (c) 8 metres where the diameter of the pipe exceeds 400 millimetres.

Expenses and costs

24

• (1) Subject to the following provisions of this paragraph, the undertaker must repay to Anglian Water all expenses reasonably incurred by Anglian Water in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in this Part of this Schedule.

• (2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule that value being calculated after removal.

• (3) If in accordance with the provisions of this Part of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 38 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Anglian Water by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

• (5) An amount which apart from this sub-paragraph would be payable to Anglian Water in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on Anglian Water any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

• (6) For the purpose of sub-paragraph (5), and for the avoidance of doubt, Anglian Water and the undertaker acknowledge that no financial benefit will exist in the event that Ofwat’s final determination of Anglian Water’s price control is set by reference to a capital maintenance allowance of apparatus at its actual age rather than the age it would have been if it had not been substituted.

25

• (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 19 and 21(2), or by reason of any subsidence resulting from such development or works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Anglian Water, or there is any interruption in any service provided, or in the supply of any goods, by Anglian Water, the undertaker must—

• (a) bear and pay the cost reasonably incurred by Anglian Water in making good such damage or restoring the supply; and

• (b) make reasonable compensation to Anglian Water for any other expenses, loss, damages, penalty or costs incurred by the undertaker,

by reason or in consequence of any such damage or interruption.

• (2) The fact that any act or thing may have been done by Anglian Water on behalf of the undertaker or in accordance with a plan approved by Anglian Water or in accordance with any requirement of Anglian Water or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1) unless Anglian Water fails to carry out and execute the works properly with due care and attention and in a skilful and professional like manner or in a manner that does not accord with the approved plan.

• (3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the unlawful or unreasonable act, neglect or default of Anglian Water, its officers, servants, contractors or agents.

• (4) Anglian Water must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made, without the consent of the undertaker (such consent not to be unreasonably withheld or delayed) who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

• (5) To the extent that Anglian Water has not used its reasonable endeavours to mitigate and minimise in whole or in part any costs, expenses, loss, demands, and penalties to which the provisions of this Part apply, that amount of such costs, expenses, loss, demands and penalties shall not be recoverable from the undertaker. If requested to do so by the undertaker, Anglian Water shall provide an explanation of how any claim has been minimised. The undertaker shall not be liable under this paragraph 25 for any claims to the extent that such claims are unreasonably incurred by Anglian Water or where Anglian Water fails to provide an explanation of how a claim has been minimised.

Cooperation

26

Where in consequence of the proposed construction of any of the authorised development, the undertaker or Anglian Water requires the removal of apparatus under paragraph 21(2) or Anglian Water makes requirements for the protection or alteration of apparatus under paragraph 23, the undertaker must use all reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of Anglian Water’s undertaking, using existing processes where requested by Anglian Water, provided it is appropriate to do so, and Anglian Water must use all reasonable endeavours to co-operate with the undertaker for that purpose.

27

Where the undertaker identifies any apparatus which may belong to or be maintainable by Anglian Water but which does not appear on any statutory map kept for the purpose by Anglian Water, it shall inform Anglian Water of the existence and location of the apparatus as soon as reasonably practicable.

28

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Anglian Water in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

29

The undertaker and Anglian Water may by written agreement substitute any period of time for those time periods set out in this Part of this Schedule.

PART 4 — FOR THE PROTECTION OF NATIONAL GAS TRANSMISSION PLC AS GAS UNDERTAKER

Application

30

• (1) For the protection of National Gas as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and National Gas.

• (2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and National Gas, where the benefit of this Order is transferred or granted to another person under article 32 (consent to transfer the benefit of the Order)—

• (a) any agreement of the type mentioned in sub-paragraph (1) has effect as if it had been made between National Gas and the transferee or grantee (as the case may be); and

• (b) written notice of the transfer or grant must be given to National Gas on or before the date of that transfer or grant.

• (3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to National Gas (but without prejudice to paragraph 38(3)(b)).

Interpretation

31

In this Part of this Schedule—

• “alternative apparatus” means appropriate alternative apparatus to the satisfaction of National Gas to enable National Gas to fulfil its statutory functions in a manner no less efficient than previously;