Legalize / United Kingdom / Statutory-Instrument

The Hirwaun Generating Station Order 2015

Type Statutory-Instrument

Publication 2015-07-23

Last updated 2017-12-28

State In force

Department King's Printer of Acts of Parliament

Source legislation.gov.uk

PDF Download

articles Not indexed

Reform history JSON API

Archaeology

11

(1) With the exception of the bat mitigation structure forming part of numbered work 2E(g) of the authorised development which may commence, each of numbered work 1 and the remainder of numbered work 2 of the authorised development is not to commence until a written scheme of investigation covering that numbered work has been submitted to and approved by the relevant planning authority.

(2) The written scheme of investigation is to be a technical document that outlines the aim and objectives and methods to be employed during a scheme of archaeological investigation work.

(3) The scheme must identify areas where field work or a watching brief are required, and the measures to be taken to protect, record or preserve any significant archaeological remains that may be found.

(4) Any archaeological works or watching brief carried out under the scheme must be by a suitably qualified person or body approved by the relevant planning authority.

(5) Any archaeological works or watching brief must be carried out in accordance with the approved scheme.

Construction environment management plan

12

(1) No numbered work of the authorised development is to commence other than the bat mitigation structure forming part of numbered work 2E(g) of the authorised development until a construction environment management plan covering that numbered work has been submitted to and approved by the relevant planning authority.

(2) All construction works must be undertaken in accordance with the approved construction environment management plan.

Construction traffic

13

(1) No numbered work of the authorised development other than tree felling and the bat mitigation structure forming part of numbered work 2E(g) of the authorised development is to commence until a construction traffic management plan covering that numbered work has been submitted to and approved by the relevant planning authority in consultation with Welsh Government Transport. The construction management plan is to detail the proposals for the movement of construction traffic and abnormal indivisible loads associated with the authorised development and is to include—

(a) construction vehicle routing plans at 1:2,500 scale for all traffic including abnormal indivisible loads showing—

(i) swept path analysis from the point of entry onto the highway network to the Order land;

(ii) highway mitigation in respect of any identified constraints on vehicle movements such as embargo periods, route traffic sensitivity, temporary road works and other highway restrictions to be developed following consultation with the South Wales Trunk Road Agent, and, where relevant, referring to supporting HD19/03 safety audit documentation (as contained within the Design Manual for Roads and Bridges Volume 5 Section 2 Part 2 and as amended or replaced); and

(iii) land ownership boundaries for any required holding areas, passing areas and layover areas;

(b) evidence of appropriate trial runs that demonstrate the suitability of the route from the point of entry onto the trunk road network to the Order land for the proposed types of abnormal indivisible loads;

(c) site access plans at 1:2,500 scale that include supporting HD19/03 safety audit documentation (as contained within the Design Manual for Roads and Bridges Volume 5 Section 2 Part 2 and as amended or replaced);

(d) proposals for the management of junctions to and crossings of the public highway during delivery of abnormal indivisible loads;

(e) proposals for the scheduling and timing of movements of delivery vehicles, to be developed following consultation with the Welsh Government and potentially affected undertakers, and, in relation to any abnormal indivisible loads, details of vehicle parameters, number of vehicles in convoy size, dimensions (width, length, height) and weight (total vehicle with load and axel loading);

(f) details of escorts for abnormal indivisible loads highlighting where and when along the route private vehicles, banksman and Police vehicles escorts will be used (including emergency contingencies);

(g) proposals for temporary warning signs and banksman for abnormal indivisible loads, including provision of plan drawings and associated traffic signs schedule highlighting locations along the route where temporary traffic management (including cones and temporary signs) needs to be deployed;

(h) a methodology for undertaking a conditions survey of Main Avenue, Fourth Avenue and any other land identified during the trial runs that may have a constraining impact on the abnormal indivisible load movements including the timescales for undertaking the surveys and the method(s) of reporting the findings to the relevant planning authority, comprehensive photographs and potential compensation arrangements;

(i) details of any temporary or permanent improvements to highways;

(j) proposals for the making good of any incidental damage to highways by construction traffic associated with the authorised development including street furniture, structures, drainage features, highway verge and carriageway surfaces;

(k) proposals for traffic management controls (such as temporary signals), diversion routes and signage required during any of the activities, operations or works set out in Schedule 4; and

(l) proposals for the notification of occupiers of land adjacent to the construction traffic route of the scheduling and timing of abnormal indivisible load movements from the point of exit from the trunk road network to the Order land.

(2) The construction traffic management plan must be implemented as approved.

(3) During the operation or decommissioning of numbered work 2 no abnormal indivisible loads must be transported into or out of the Order land without the prior written approval of the relevant planning authority in consultation with Welsh Government Transport.

Construction hours

14

(1) No construction work, or the delivery or removal of materials, is to take place outside the hours of—

(a) 0700 and 1830 hours on weekdays (excluding public holidays); and

(b) 0700 and 1300 hours on Saturdays and public holidays.

(2) Sub-paragraph (1) does not prevent outside such hours construction works, or the delivery or removal of materials, being carried out with the prior written approval of the relevant planning authority.

Control of noise during operational phase

15

(1) Following the date of final commissioning of numbered work 2, site-attributable noise attributable to numbered work 2 during the operational phase must be limited at all times of day to the noise levels set out below in Table 3 measured at the coordinates set out below in Table 3—

Noise Limit Sound Pressure Level, LAeq, 5mins dB	Coordinates	Coordinates
Noise Limit Sound Pressure Level, LAeq, 5mins dB	X	Y
52	293820.1	206257.2
52	293738.8	206173.6
53	293622.9	206319
54	293741.2	206353.3

(2) Noise measurements at each of the identified locations must be undertaken in accordance with BS 7445. Measurements should be undertaken with the power plant running at base load. A single LAeq 5min measurement will be required at each identified location during the day, evening and night time periods identified as follows — daytime (0700hrs to 1900hrs), evening (1900hrs to 2300hrs) and night time (2300hrs to 0700hrs).

(3) Records of the noise measurements referred to in paragraph (2) at each location referred to in paragraph (1) must be retained by the undertaker for twelve months and provided to the relevant planning authority or any other person within three working days of a request (although the undertaker is not be required to respond to more than one request per person per month).

(4) Any complaint made to the undertaker in relation to a breach of paragraph (1) must be—

(a) acknowledged by the undertaker within three working days of the date of the complaint;

(b) investigated within seven working days of the date of the acknowledgement referred to in sub-paragraph (a); and

(c) a response provided within seven working days of the date of completion of period for the investigation referred to in sub-paragraph (b).

(5) Any subsequent complaint by person from whom the undertaker has previously investigated a complaint under paragraph (4) must be referred by the undertaker to the relevant planning authority (although only one complaint per person per month must be referred).

Control of artificial light emissions

16

(1) With the exception of the bat mitigation structure forming part of numbered work 2E(g) of the authorised development which may commence, the remainder of numbered work 2 of the authorised development is not to commence until, after consultation with the relevant planning authority, a written scheme for the management and mitigation of artificial light emissions which is in accordance with the outline lighting strategy in so far as it relates to the authorised development has been submitted to and approved by the relevant planning authority in consultation with the Brecon Beacons National Park Authority.

(2) The approved scheme for the management and mitigation of artificial light emissions must be implemented before and maintained during the operation of the relevant numbered work.

Decommissioning strategy

17

(1) Subject to obtaining the necessary consents, unless otherwise agreed with the relevant planning authority, within twenty four months of the site ceasing to be used for the purposes of electricity generation (either actively generating electricity or being available to generate electricity on a standby basis), a scheme for the demolition and removal of numbered work 2 must be submitted to the relevant planning authority.

(2) The demolition and removal of numbered work 2 must be implemented in accordance with the approved scheme.

Amendments to approved details

18

(1) With respect to any plans, details, schemes or matters which require approval by the relevant planning authority pursuant to any other requirement (the “Plans, Details or Schemes”), the undertaker may submit to the relevant planning authority for approval any amendments to the Plans, Details or Schemes and following any such approval by the relevant planning authority the Plans, Details or Schemes are to be taken to include the amendments approved pursuant to this sub-paragraph (1).

(2) Approval under requirement sub-paragraph (1) must not be given except where it has been demonstrated to the satisfaction of the relevant planning authority that the subject-matter of the approval sought does not give rise to any materially new or materially different environmental effects in comparison with the authorised development as approved (as identified in the environmental statement).

Date of final commissioning and cessation

19

(1) The undertaker must notify the relevant planning authority of the date of final commissioning as soon as reasonably practicable and in any event within three months after the occurrence of that date.

(2) The undertaker must notify the relevant planning authority of the date the authorised development permanently ceases to generate power on a commercial basis as soon as reasonably practicable and in any event within three months after the occurrence of that date.

Provision of details to the Ministry of Defence

20

Numbered work 2 of the authorised development is not to commence until the following details for that numbered work have been provided to the Ministry of Defence Geographic Centre—

(a) location of the authorised development;

(b) proposed date of commencement;

(d) the height above ground of the tallest structure forming part of the authorised development; and

(e) the maximum extension height of the tallest structure anticipated to be within the Order land during construction of the authorised development.

Operational Limits

21

(1) In any calendar year the operation of the gas turbine generators comprised in numbered work 2A must not exceed 1500 hours in total.

(2) Within three months of the end of a calendar year, the undertaker must submit a written report to the relevant planning authority detailing the actual total number of hours of operation of the gas turbine generators comprised in numbered work 2A.

(3) For the purposes of this requirement, “operation of the gas turbine generators” means the duration in which any energy is exported at the settlement metering point, being the point at which a supply to the transmission system from the authorised development is measured.

SCHEDULE 3 — STREETS SUBJECT TO PERMANENT ALTERATION OF LAYOUT

(1) Area	(2) Street subject to alteration of layout	(3) Description of alteration
In the District of Rhondda Cynon Taf	Main Avenue	The lowering of the levels of the kerb between the points marked D and E on the rights of way, streets and access plan to provide a permanent access to numbered work 2.
In the District of Rhondda Cynon Taf	Main Avenue	The lowering of the levels of the kerb between the points marked F and G on the rights of way, streets and access plan to provide a permanent access north to numbered work 2.
In the District of Rhondda Cynon Taf	Main Avenue	The lowering of the levels of the kerb between the points marked F and G on the rights of way, streets and access plan to provide a permanent access south to numbered work 2.
In the District of Rhondda Cynon Taf	Fourth Avenue	The lowering of the levels of the kerb between the points marked I and J on the rights of way, streets and access plan to provide a permanent access to numbered work 2.
In the District of Rhondda Cynon Taf	Rhigos Road (north and south sides)	The lowering of the levels of the kerb between the points marked L and M on the rights of way, streets and access plan to provide a permanent access to numbered work 2.

SCHEDULE 4 — ACCESS

PART 1 — THOSE PARTS OF ACCESSES TO BE MAINTAINED AT THE PUBLIC EXPENSE

(1) Area	(2) Street	(3) Description of relevant part of access
In the District of Rhondda Cynon Taf	Main Avenue	Those parts of the modified accesses at Main Avenue providing permanent access to numbered work 2 and shown on the rights of way, streets and access plan hatched blue between points marked D and E, F and G.

PART 2 — THOSE PARTS OF ACCESSES TO BE MAINTAINED BY THE STREET AUTHORITY

(1) Area	(2) Street	(3) Description of the relevant part of access
In the District of Rhondda Cynon Taf	Main Avenue	Those parts of the modified accesses at Main Avenue providing permanent access to numbered work 2 and shown on the rights of way, streets and access plan hatched red between points marked D and E, F and G.
In the District of Rhondda Cynon Taf	Fourth Avenue	That part of the modified access at Fourth Avenue shown on the rights of way, streets and access plan hatched red between points marked I and J for access to numbered work 2.

SCHEDULE 5 — MODIFICATION OF COMPENSATION AND COMPULSORY PURCHASE ENACTMENTS FOR CREATION OF NEW RIGHTS

Compensation enactments

1

The enactments for the time being in force with respect to compensation for the compulsory purchase of land apply, with the necessary modifications as respects compensation, in the case of a compulsory acquisition under this Order of a right by the creation of a new right as they apply as respects compensation on the compulsory purchase of land and interests in land.

2

(1) Without prejudice to the generality of paragraph 1, the Land Compensation Act 1973[^f00028] has effect subject to the modifications set out in sub-paragraph (2) and (3).

(2) In section 44(1) (compensation for injurious affection), as it applies to compensation for injurious affection under section 7 of the 1965 Act as substituted by paragraph 4—

(a) for the words “land is acquired or taken” there are substituted the words “a right or restrictive covenant over land is purchased from or imposed on”; and

(b) for the words “acquired or taken from him” there are substituted the words “over which the right is exercisable or the restrictive covenant enforceable”.

(3) In section 58(1) (determination of material detriment where part of house etc. proposed for compulsory acquisition), as it applies to determinations under section 8 of the 1965 Act as substituted by paragraph 5—

(a) for the word “part” in paragraph (a) and (b) there are substituted the words “a right over or restrictive covenant affecting land consisting”;

(b) for he word “severance” there are substituted the words “right or restrictive covenant over or affecting the whole of the park or garden”;

(d) for the words “part is” there are substituted the words “right or restrictive covenant is”.

Application of the 1965 Act

3

(1) The 1965 Act has effect with the modifications necessary to make it apply to the compulsory acquisition under this Order of a right by the creation of a new right, or to the imposition under this Order of a restrictive covenant, as it applies to the compulsory acquisition under this Order of land, so that, in appropriate contexts, references in that Act to land are read (according to the requirements of the particular context) as referring to, or as including references to—

(a) the right acquired or to be acquired; or

(b) the land over which the right is or is to be exercisable.

(2) Without prejudice to the generality of sub-paragraph (1), Part 1 of the 1965 Act applies in relation to the compulsory acquisition under this Order of a right by the creation of a new right with the modifications specified in the following provisions of this Schedule.

4

For section 7 of the 1965 Act (measure of compensation) there is substituted the following section—

(7) In assessing the compensation to be paid by the acquiring authority under this Act, regard must be had not only to the extent (if any) to which the value of the land over which the right is to be acquired or the restrictive covenant is to be imposed is depreciated by the acquisition of the right or the imposition of the covenant but also to the damage (if any) to be sustained by the owner of the land by reason of its severance from other land of the owner, or injuriously affecting that other land by the exercise of the powers conferred by this or the special Act.

5

For section 8 of the 1965 Act (provisions as to divided land) there is substituted the following section—

(8) (1) Where in consequence of the service on a person under section 5 of this Act of a notice to treat in respect of a right over land consisting of a house, building or manufactory or of a park or garden belonging to a house (“the relevant land”)— (a) a question of disputed compensation in respect of the purchase of the right or the imposition of the restrictive covenant would apart from this section fall to be determined by the Upper Tribunal (“the tribunal”); and (b) before the tribunal has determined that question the tribunal is satisfied that the person has an interest in the whole of the relevant land and is able and willing to sell that land and— (i) where that land consists of a house, building or manufactory, that the right cannot be purchased or the restrictive covenant imposed without material detriment to that land; or (ii) where the land consists of such a park or garden, that the right cannot be purchased or the restrictive covenant imposed without seriously affecting the amenity or convenience of the house to which that land belongs, the Hirwaun Generating Station Order 2015 (“the Order”) ceases, in relation to that person, to authorise the purchase of the right and be deemed to authorise the purchase of that person’s interest in the whole of the relevant land including, where the land consists of such a park or garden, the house to which it belongs, and the notice is deemed to authorise the purchase of that person’s interest in the whole of the relevant land including, where the land consists of such a park or garden, the house to which it belongs, and the notice is deemed to have been served in respect of that interest on such date as the tribunal directs. (2) Any question as to the extent of the land in which the Order is deemed to authorise the purchase of an interest by virtue of subsection (1) of this section must be determined by the tribunal. (3) Where in consequence of a determination of the tribunal that it is satisfied as mentioned in subsection (1) of this section the Order is deemed by virtue of that subsection to authorise the purchase of an interest in land, the acquiring authority may, at any time within the period of 6 weeks beginning with the date of the determination, withdraw the notice to treat in consequence of which the determination was made; but nothing in this subsection prejudices any other power of the authority to withdraw the notice.

6

The following provisions of the 1965 Act (which state the effect of a deed poll executed in various circumstances where there is no conveyance by persons with interests in the land), that is to say—

(a) section 9(4) (failure by owners to convey);

(b) paragraph 10(3) of Schedule 1 (owners under incapacity);

(d) paragraphs 2(3) and 7(2) of Schedule 4 (common land),

are modified as to secure that, as against persons with interests in the land which are expressed to be overridden by the deed, the right which is to be compulsorily acquired or the restrictive covenant which is to be imposed is vested absolutely in the acquiring authority.

7

Section 11 of the 1965 Act (powers of entry) is modified as to secure that, as from the date on which the acquiring authority has served notice to treat in respect of any right it has power, exercisable in equivalent circumstances and subject to equivalent conditions, to enter for the purpose of exercising that right or enforcing that restrictive covenant (which is deemed for this purpose to have been created on that date of service of the notice); and sections 12 (penalty for unauthorised entry) and 13 (entry on warrant in the event of obstruction) of the 1965 Act are modified correspondingly.

8

Section 20 of the 1965 Act (protection for interests of tenants at will, etc.) applies with the modifications necessary to secure that persons with such interests in land as are mentioned in that section are compensated in a manner corresponding to that in which they would be compensated on a compulsory acquisition under this Order of that land, but taking into account only the extent (if any) of such interference with such an interest as is actually caused, or likely to be caused, by the exercise of the right or the enforcement of the restrictive covenant in question.

9

Section 22 of the 1965 Act (protection of acquiring authority’s possession where by inadvertence an estate, right or interest has not been got in) is modified as to enable the acquiring authority, in circumstances corresponding to those referred to in that section, to continue to be entitled to exercise the right acquired, subject to compliance with that section as respects compensation.

SCHEDULE 6 — LAND OF WHICH TEMPORARY POSSESSION MAY BE TAKEN

(1) Location	(2) Number of land shown on land plans	(3) Purpose for which temporary possession may be taken	(4) Relevant part of the authorised development
Land forming part of public adopted highway known as Main Avenue, Hirwaun	1a_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Land forming part of public adopted highway known as Main Avenue, Hirwaun	1b_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Land situated to the south of Building 6, Hirwaun Industrial Estate, Hirwaun	2a_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Land forming part of the northern half width of public adopted highway known as Rhigos Road together with a bus lay-by, situated to the south of Building 6, Hirwaun Industrial Estate, Hirwaun	3a_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Land forming part of the northern half width of public adopted highway and drain known as Rhigos Road together with part of a Public Right of Way leading from Rhigos Road to Main Avenue situated to the south of Building 6, Hirwaun Industrial Estate, Hirwaun	3b_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Land and overhead electricity lines forming part of the southern half width of public adopted highway known as Rhigos Road situated to the south of Building 6, Hirwaun Industrial Estate, Hirwaun	4a_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Land and overhead electricity lines forming part of the southern half width of public adopted highway and drain known as Rhigos Road situated to the south of Building 6, Hirwaun Industrial Estate, Hirwaun	4b_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Land forming part of the southern half width of public adopted highway known as Rhigos Road situated to the south of Building 6, Hirwaun Industrial Estate, Hirwaun	5a_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Agricultural land, drains and overhead electricity lines (including poles) situated to the east and south east of The Fairways, Hirwaun	6a_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Agricultural land, drains and overhead electricity lines (including poles) situated to the east and south east of The Fairways, Hirwaun	6b_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G
Land and overhead electricity lines situated to the east of The Fairways, Hirwaun	6c_GR	Temporary use to facilitate construction for numbered work 2G	Part of numbered work 2G

SCHEDULE 7 — PROTECTIVE PROVISIONS

PART 1 — FOR THE PROTECTION OF NATIONAL GRID

Application

1

For the protection of National Grid as referred to in this Part of this Schedule the following provisions shall, unless otherwise agreed in writing between the undertaker and National Grid, have effect.

Interpretation

2

In this Part of this Schedule—

“alternative apparatus” means appropriate alternative apparatus to the satisfaction of National Grid to enable National Grid to fulfil its statutory functions in a manner no less efficient than previously;

“apparatus” meanselectric lines or electrical plant as defined in the Electricity Act 1989[^f00029], belonging to or maintained by National Grid;mains, pipes or other apparatus belonging to or maintained by National Grid for the purposes of gas supply;

“authorised development” has the same meaning as in article 2 of this Order and (unless otherwise specified) for the purposes of this Schedule shall include the use and maintenance of the authorised development;

“commence” has the same meaning as under section 56 of the 1990 Act and means the earliest date on which any material operation comprised in the authorised development begins to be carried out and commencement shall be construed to have the same meaning;

“functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

“National Grid” means either—National Grid Electricity Transmission PLC (Company No. 2366977) whose registered office is at 1-3 Strand, London, WC2N 5EH; orNational Grid Gas PLC (Company No. 200600) whose registered office is at 1-3 Strand, London, WC2N 5EH,as the context shall require;

“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed.

3

Except for paragraphs 4 (apparatus in streets subject to temporary prohibition or restriction), 8, 9 (retained apparatus: protection), 10 (expenses) and 11 (indemnity) this Schedule does not apply to apparatus in respect of which the relations between the undertaker and National Grid are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus of National Grid in streets subject to temporary prohibition or restriction

4

Notwithstanding the temporary prohibition or restriction under the powers of article 11 (temporary prohibition or restriction of use of streets), National Grid shall be at liberty at all times to take all necessary access across any such street and/or to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.

Acquisition of land

5

(1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order the undertaker must not acquire any land interest or apparatus or override any easement or other interest of National Grid otherwise than by agreement (such agreement not to be unreasonably withheld).

(2) The undertaker and National Grid agree that where there is any inconsistency or duplication between the provisions set out in this Schedule relating to the relocation and/or removal of apparatus/including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid as of right or other use in relation to the apparatus then the provisions in this Schedule shall prevail.

Removal of apparatus

6

(1) If, in the exercise of the agreement reached in accordance with paragraph (5) or in any other authorised manner, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of National Grid to maintain that apparatus in that land shall not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid in accordance with sub-paragraphs (2) to (5) inclusive.

(2) If, for the purpose of executing any works comprised in the authorised development in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Grid 56 days’ advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid reasonably needs to remove any of its apparatus) the undertaker shall, subject to sub-paragraph (3), afford to National Grid to their satisfaction (taking into account paragraph 7 sub-paragraph (1) below) the necessary facilities and rights for—

(a) the construction of alternative apparatus in other land of the undertaker; and

(b) subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for National Grid to use its compulsory purchase powers to this end unless it elects to so do.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule shall be constructed in such manner and in such line or situation as may be agreed between National Grid and the undertaker.

(5) National Grid must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the grant to National Grid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Facilities and rights for alternative apparatus

7

(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to National Grid facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights shall be granted upon such terms and conditions as may be agreed between the undertaker and National Grid and must be no less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless agreed by National Grid.

(2) If the facilities and rights to be afforded by the undertaker and agreed with National Grid under paragraph 7 sub-paragraph (1) above in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject in the matter shall be referred to arbitration and, the arbitrator shall make such provision for the payment of compensation by the undertaker to National Grid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. In respect of the appointment of an arbitrator under this sub-paragraph (2), article 39 of the Order shall apply.

Retained apparatus: protection of National Grid as Gas Undertaker

8

(1) Not less than 56 days before the commencement of any authorised development authorised by this Order that involves activities or works specified in National Grid’s “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22” that are within the proximities described therein to any apparatus the removal of which has not been required by the undertaker under paragraph 6 sub paragraph (2) or otherwise, the undertaker must submit to National Grid a plan.

(2) In relation to works which will be situated on, over, under or within 15 metres measured in any direction of any apparatus to which sub-paragraph (1) applies, or (wherever situated) impose any load directly upon any such apparatus or involve embankment works within 15 metres of any such apparatus, the plan to be submitted to National Grid under sub-paragraph (1) shall show—

(a) the exact position of the works;

(b) the level at which these are proposed to be constructed or renewed;

(d) the position of all apparatus;

(e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;

(f) intended maintenance regimes; and

(g) details of any ground monitoring scheme (if required in accordance with National Grid’s “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22”.

(3) The undertaker must not commence any works to which sub-paragraph (2) applies until National Grid has given written approval of the plan so submitted.

(4) Any approval of National Grid required under sub-paragraph (3)—

(a) may be given subject to reasonable conditions for any purpose mentioned in sub-paragraph (5) or (7);

(b) must not be unreasonably withheld.

(5) In relation to a work to which sub-paragraphs (1) and (2) applies, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its system against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(6) Works executed under sub-paragraphs (1) or (2) shall be executed only in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub paragraph (2), as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (4), (5), (7) and/or (8) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid shall be entitled to watch and inspect the execution of those works.

(7) Where National Grid requires protective works to be carried out either themselves or by the undertaker (whether of a temporary or permanent nature) such protective works shall be carried out to National Grid’s satisfaction prior to the commencement of any authorised development (or any relevant part thereof) and National Grid must give 56 days’ notice of such works from the date of submission of a plan in line with sub-paragraph (1) or (2) (except in an emergency).

(8) If National Grid in accordance with sub-paragraph (5) or (7) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 6 to 7 shall apply as if the removal of the apparatus had been required by the undertaker under paragraph 6 sub-paragraph (2).

(9) Nothing in this paragraph shall preclude the undertaker from submitting at any time or from time to time, but in no case less that 56 days before commencing the execution of any works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan.

(10) The undertaker shall not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and shall—

(a) comply with sub-paragraph (5), (6) and (7) insofar as is reasonably practicable in the circumstances; and

(b) comply with sub-paragraph (11) at all times.

(11) At all times when carrying out any works authorised under the Order comply with National Grid’s policies for safe working in proximity to gas apparatus “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22” and the Health and Safety Executive’s “HS(~G)47 Avoiding Danger from underground services”.

Retained apparatus: protection of National Grid as Electricity Undertaker

9

(1) Not less than 56 days before the commencement of any authorised development under this Order that is near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 6 sub-paragraph (2) or otherwise and to which sub-paragraph (2)(i) or (2)(ii) applies, the undertaker must submit to National Grid a plan and seek from National Grid details of the underground extent of their electricity tower foundations.

(2) In relation to works which will or may be situated on, over, under or within (i) 15 metres measured in any direction of any apparatus, or (ii) involve embankment works within 15 metres of any apparatus, the plan to be submitted under sub-paragraph (1) shall show—

(a) the exact position of the works;

(b) the level at which these are proposed to be constructed or renewed;

(d) the position of all apparatus;

(e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;

(3) In relation to any works which will or may be situated on, over, under or within 10 metres of any part of the foundations of an electricity tower or between any two or more electricity towers, the plan to be submitted under sub-paragraph (1) shall be detailed including a method statement and describing in addition to the matters set out in sub-paragraph (2)—

(a) details of any cable trench design including route, dimensions, clearance to pylon foundations;

(b) demonstration that pylon foundations will not be affected prior to, during and post construction;

(d) details of cable installation methodology including access arrangements, jointing bays and backfill methodology;

(e) a written management plan for high voltage hazard during construction and on-going maintenance of the cable route;

(f) written details of the operations and maintenance regime for the cable, including frequency and method of access;

(g) assessment of earth rise potential if reasonably required by National Grid’s engineers;

(h) evidence that trench bearing capacity is to be designed to 26 tonnes to take the weight of overhead line construction traffic.

(4) The undertaker must not commence any works to which sub-paragraph (1), (2) or (3) applies until National Grid has given written approval of the plan so submitted,

(5) Any approval of National Grid required under sub-paragraph (1), (2) or (3)—

(a) may be given subject to reasonable conditions for any purpose mentioned in this sub-paragraph or sub-paragraph (8);

(b) must not be unreasonably withheld.

(6) In relation to a work to which sub-paragraph (1), (2) or (3) applies, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its system against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(7) Works executed under sub-paragraph (1), (2) or (3) must be executed only in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub-paragraph (2), (3) or (5), as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (5), (6), (8) and/or (9) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid shall be entitled to watch and inspect the execution of those works.

(8) Where National Grid require any protective works to be carried out either themselves or by the undertaker (whether of a temporary or permanent nature) such protective works must be carried out to the undertakers’ satisfaction prior to the commencement of any authorised development (or any relevant part thereof) and National Grid must give 56 days’ notice of such works from the date of submission of a plan in line with sub-paragraph (1), (2), (3) or (5) (except in an emergency).

(9) If National Grid in accordance with sub-paragraph (6) or (8) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 6 to 7 shall apply as if the removal of the apparatus had been required by the undertaker under paragraph 6 sub-paragraph (2).

(10) Nothing in this paragraph shall preclude the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of any works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan.

(11) The undertaker shall not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and shall—

(a) comply with sub-paragraph (6), (7) and (8) insofar as is reasonably practicable in the circumstances; and

(b) comply with sub-paragraph (12) at all times.

(12) At all times when carrying out any works authorised under the Order comply with National Grid’s policies for development near over headlines ENA TA 43-8 and the Health and Safety Executive’s guidance note 6 “Avoidance of Danger from Overhead Lines”.

Expenses

10

(1) Subject to the following provisions of this paragraph, the undertaker shall pay to National Grid on demand all charges, costs and expenses reasonably anticipated or incurred by that undertaker in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in this Schedule including without limitation—

(a) any costs reasonably incurred or compensation properly paid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation in the event that National Grid elects to use compulsory purchase powers to acquire any necessary rights under paragraph 6 sub-paragraph (3) all costs incurred as a result of such action;

(b) in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus;

(d) the approval of plans;

(e) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

(f) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Schedule.

(2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or in default of agreement settled by arbitration in accordance with article 39 (arbitration) of the Order to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) shall be reduced by the amount of that excess save where it is not possible in the circumstances to obtain the existing type of operations, capacity, dimensions or place at the existing depth in which case full costs shall be borne by the undertaker.

(4) For the purposes of sub-paragraph (3)—

(a) an extension of apparatus to a length greater than the length of existing apparatus shall not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole shall be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) shall, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Indemnity

11

(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Schedule or in consequence of the construction, use, maintenance or failure of any of the authorised development by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works (including without limitation works carried out by the undertaker under this Schedule or any subsidence resulting from any of these works), any material damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of National Grid , or there is any interruption in any service provided, or in the supply of any goods, by National Grid , or National Grid becomes liable to pay any amount to any third party, the undertaker shall—

(a) bear and pay on demand the cost reasonably incurred by National Grid in making good such damage or restoring the supply; and

(b) indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party as aforesaid.

(2) The fact that any act or thing may have been done by National Grid on behalf of the undertaker or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid as a consequence of the authorised development or under its supervision shall not (subject to sub-paragraph (3)) excuse the undertaker from liability under the provisions of this sub-paragraph (1) where the undertaker fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not materially accord with the approved plan or as otherwise agreed between the undertaker and National Grid.

(3) Nothing in sub-paragraph (1) shall impose any liability on the undertaker in respect of—

(a) any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents; and

(b) any authorised development and/or any other works authorised by this Schedule carried out by National Grid as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 of the 2008 Act subject to the proviso that once such works become apparatus (“new apparatus”), any works yet to be executed and not falling within this sub-paragraph 3(b) shall be subject to the full terms of this Schedule including this paragraph 11 in respect of such new apparatus.

(4) National Grid must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise shall be made without first consulting the undertaker and considering their representations.

(5) National Grid must use its reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph 11 applies. If requested to do so by the undertaker, National Grid shall provide an explanation of how the claim has been minimised. The undertaker shall only be liable under this paragraph 11 for claims reasonably incurred by National Grid.

Enactments and agreements

12

Nothing in this Part of this Schedule shall affect the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Co-operation

13

National Grid and the undertaker must each use their best endeavours to co-ordinate with the other party on the timing and method of execution of any works carried out under the Order or this Schedule (including, for the avoidance of doubt, pursuant to paragraph 6 sub-paragraph (2) and paragraphs 8 or 12) in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of the other party’s operations.

Access

14

If in consequence of the agreement reached in accordance with paragraph 5 sub-paragraph (1) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker shall provide such alternative means of access to such apparatus as will enable National Grid to maintain or use the apparatus no less effectively than was possible before such obstruction.

Arbitration

15

Save for differences or disputes arising under paragraph 6(2), 6(4), 7(1), 8 and 9 any difference or dispute arising between the undertaker and National Grid under this Schedule shall, unless otherwise agreed in writing between the undertaker and National Grid, be determined by arbitration in accordance with article 39 (arbitration) of the Order.

PART 2 — FOR THE PROTECTION OF WESTERN POWER DISTRIBUTION

16

For the protection of WPD as referred to in this Part of this Schedule the following provisions, unless otherwise agreed in writing between the undertaker and WPD, have effect.

17

In this Part of this Schedule—

“alternative apparatus” means alternative apparatus adequate to enable WPD to fulfil its statutory functions in a manner not less efficient than previously;

“alternative rights” means all and any necessary legal easements, consents, or permissions required by WPD in order to permit or authorise a diversion;

“apparatus” means electric lines or electrical plant as defined in the Electricity Act 1989, belonging to or maintained by WPD;

“diversion” means an alteration to the WPD Network in order to enable or facilitate the authorised development;

“WPD” means Western Power Distribution (South Wales) PLC (company number 02366985) whose registered office is at Avonbank, Feeder Road, Bristol BS2 0TB;

“WPD Network” means WPD’s distribution network operated pursuant to its distribution licence issued pursuant to section 6 of the 1989 Act; andfor the avoidance of doubt, all other terms are as defined in Part 1 of the Order.

18

This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and WPD are regulated by the provisions of Part 3 of the 1991 Act.

19

Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

20

(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of WPD to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of WPD.

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to WPD written notice of that requirement, together with a plan and section of the work proposed.

(3) If alternative apparatus or any part of such apparatus is to be constructed as a consequence of the removal of apparatus placed on the land referred to in sub-paragraph 20(2), WPD must on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its reasonable endeavours to obtain the alternative rights in other land in which the alternative apparatus is to be constructed.

(4) WPD must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 39 of the Order and after the grant to WPD of any alternative rights, proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(5) In respect of apparatus on plots numbered 1_MS and 3_MS in the book of reference and land plans—

(a) if requested by the undertaker, WPD must remove any of its apparatus within a building on those plots (or relocate such apparatus as applicable) within 56 days of the undertaker making such a request, unless factors outside the control of WPD prevent such a removal or relocation within the 56 day time period (for the avoidance of doubt the 56 day period shall only begin once all necessary consents and permissions for the relevant removal or relocation have been granted); and

(b) WPD and the undertaker may agree for the undertaker to remove or relocate as applicable any of such apparatus; and

(c) following the removal or relocation by WPD or the undertaker (as applicable) under sub-paragraph 20(5)(a) or 20(5)(b), the undertaker may demolish such building(s).

21

(1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect any apparatus the removal of which has not been required by the undertaker under paragraph 20(2), the undertaker must submit to WPD a plan, section and description of the works to be executed. For the avoidance of doubt, if any works referred to require any diversion or require WPD to obtain any alternative rights, the undertaker shall give WPD sufficient notice to obtain any such alternative rights and shall not commence works of the type described unless or until any such alternative rights have been obtained.

(2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph 21(1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph 21(3) by WPD for the alteration or otherwise for the protection of the apparatus, or for securing access to it.

(3) Any requirements made by WPD under sub-paragraph 21(2) must be made within a reasonable period beginning with the date on which a plan, section and description under sub-paragraph 21(1) are submitted to it.

(4) If WPD in accordance with sub-paragraph 21(3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 16 to 20 apply as if the removal of the apparatus had been required by the undertaker under paragraph 20(2)).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than the reasonable period provided for in sub-paragraph 21(3) before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The undertaker is not required to comply with sub-paragraph 21(1) in a case of emergency but in that case it must give to WPD notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph 21(1)) in so far as is reasonably practicable in the circumstances.

22

(1) Subject to the following provisions of this paragraph, the undertaker must repay to WPD the proper and reasonable expenses reasonably incurred by WPD in, or in connection with, the inspection, removal, alteration or protection of any apparatus.

(2) The value of any apparatus removed under the provisions of this Part of the Schedule is to be deducted from any sum payable under sub-paragraph 22(1), that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 39 of the Order to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to WPD by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph 22(3)—

(a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to WPD in respect of works by virtue of sub-paragraph 22(1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on WPD any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

23

The undertaker will indemnify WPD and keep them indemnified in respect of any losses, costs, claims or liabilities arising out of, or as a consequence of anything done under this Part of this Schedule.

PART 3 — FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS

24

For the protection of the utility undertakers referred to in this Part of this Schedule (save for National Grid, which is protected by and as defined in Part 1 of this Schedule, WPD, which is protected by and as defined in Part 2 of this Schedule and DCC, which is protected by and as defined in Part 7 of this Schedule), the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertakers concerned.

25

In this Part of this Schedule—

“alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;

“apparatus” means—in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989), belonging to or maintained by that utility undertaker;in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply;in the case of a water undertaker—mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; andany water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A of the Water Industry Act 1991[^f00030];in the case of a sewerage undertaker—any drain or works vested in the utility undertaker under the Water Industry Act 1991; andany sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act,and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

“functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

“utility undertaker” means—any licence holder within the meaning of Part 1 of the Electricity Act 1989;a gas transporter within the meaning of Part 1 of the Gas Act 1986[^f00031],a water undertaker within the meaning of the Water Industry Act 1991; anda sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.

26

This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 of the 1991 Act.

27

Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 11 (temporary prohibition or restriction of use of streets), a utility undertaker is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.

28

Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

29

(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7).

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 39 (arbitration).

(5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 39 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

(7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 600 millimetres of the apparatus.

30

(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 39 (arbitration).

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

31

(1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 29(2), the undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed.

(2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.

(3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 24 to 30 apply as if the removal of the apparatus had been required by the undertaker under paragraph 29(2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

32

(1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker the reasonable expenses incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 29(2).

(2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal.

(3) in accordance with the provisions of this Part of this Schedule—

(a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 39 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 29(2); and

(b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

33

(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 29(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—

(a) bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

(b) make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

(3) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

34

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaking in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 4 — FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

35

(1) For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.

(2) In this Part of this Schedule—

“the 2003 Act” means the Communications Act 2003[^f00032];

“electronic communications apparatus” has the same meaning as in the electronic communications code;

“the electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act[^f00034];

“electronic communications code network” means—so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; andan electronic communications network which the Secretary of State is providing or proposing to provide;

“electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act; and

“infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7 of that code;

“operator” means the operator of an electronic communications code network.

36

The exercise of the powers of article 28 (statutory undertakers) is subject to Part 10 of Schedule 3A to the Communications Act 2003 (undertaker’s works affecting electronic communications apparatus).

37

(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works

(a) any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

(b) there is any interruption in the supply of the service provided by an operator,

the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 39 (arbitration).

38

This Part of this Schedule does not apply to—

(a) any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 of the 1991 Act; or

(b) any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.

39

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 5 — FOR THE PROTECTION OF AFFECTED PERSONS

40

For the protection of affected persons as referred to in this Part of this Schedule the following provisions, unless otherwise agreed in writing between the undertaker and the affected person concerned, have effect.

41

In this Part of this Schedule—

“affected person” means a person who—is identified in column 3 of the tables at sections 1.3, 2.3 and 3.3 of the book of reference as having the benefit of any right listed in column 4 of the tables at sections 1.3, 2.3 and 3.3 of the book of reference; andis not subject to any protective provisions set out in Parts 1-4 and Part 6 of this Schedule;

“affected rights” means the rights listed in column 4 of the tables at sections 1.3, 2.3 and 3.3 of the book of reference in relation to the Order land for an affected person to:pass along, or exercise rights of access over, Order land; orconnect to, use, maintain, repair or renew services in, on or over the Order land;

“services” means water, gas, electricity, sewerage and/or electronic communications services;for the avoidance of doubt, all other terms are as defined in Part 1 of this Order.

42

The undertaker must comply with paragraphs 43 and 44.

43

In respect of part (a) of the definition of “affected rights”—

(1) where the undertaker interferes with such affected rights, such interference, in so far as reasonably practicable, must be to the minimum area and for the minimum period; and

(2) where the undertaker requires suspension as a result of the exercise of the powers under the Order, the undertaker must provide alternative access which is no less convenient than the access enjoyed prior to the suspension for the period in which the affected rights are suspended.

44

In respect of part (b) of the definition of “affected rights”—

(1) where the undertaker requires the extinguishment of any such affected rights, the undertaker must not extinguish such affected rights unless and until replacement rights have been granted to the affected person on equivalent terms and conditions to those affected rights that are being extinguished save that this sub-paragraph will not apply where such replacement rights can only be obtained on land outside the Order land; and

(2) where the undertaker requires the relocation of any such affected rights, the undertaker must not interfere with or suspend such affected rights unless and until the relocated affected rights have been brought into operation provided that this sub-paragraph will not apply where the relocated affected rights can only be obtained on land outside the Order land.

45

The undertaker is not required to comply with paragraphs 43 and 44 in a case of emergency but in that case it must give to the affected person notice of the interference or suspension with the affected right as soon as is reasonably practicable and thereafter comply with paragraphs 43 and 44 in so far as is reasonably necessary and practicable in the circumstances.

PART 6 — FOR THE PROTECTION OF TOWER REGENERATION LIMITED

46

For the protection of Tower Regeneration Limited the following provision, unless otherwise agreed in writing between the undertaker and Tower Regeneration Limited, has effect.

47

(1) The undertaker must not—

(2) vest the land identified in the book of reference and the land plans by plot reference numbers 10_GR and 11_GR in itself;

(3) exercise the powers conferred on it by article 26 in respect of the land identified in the book of reference and the land plans by plot reference numbers 10_GR, 10a_GR, 11_GR and 11a_GR; or

(4) commence the authorised development on the land identified in the book of reference and the land plans by plot reference numbers 10_GR, 10a_GR, 11_GR and 11a_GR;

no earlier than 2nd January 2018.

PART 7 — FOR THE PROTECTION OF DWR CYMRU CYFYNGEDIG

48

For the protection of DCC referred to in this Part 7 of Schedule 7, the following provisions shall, unless otherwise agreed in writing between the undertaker and DCC, have effect.

49

In this Part of this Schedule—

“acceptable insurance” means a policy of public liability/third party liability insurance effected and maintained by the undertaker and available in the market on commercially reasonable terms having regard (inter alia) to premiums required and the policy terms obtainable, with a level of insurance cover to be agreed between the undertaker and DCC, during the construction of the works pursuant to this Order with a reputable insurer and with DCC named as an insured party under the policy;

Reading this document does not replace reading the official text published on legislation.gov.uk. Contains public sector information licensed under the Open Government Licence v3.0. We assume no responsibility for any inaccuracies arising from the conversion of the original CLML XML to this format.

This text is published under legislation.gov.uk's own terms of reuse, not a Legalize or public-domain licence. legislation.gov.uk
Open Government Licence v3.0 (attribution required)
© Crown and database right. Derived from content available under the Open Government Licence v3.0 from legislation.gov.uk.