The Triton Knoll Electrical System Order 2016

• (1) The undertaker must not in the exercise of the powers conferred by this Order prevent, obstruct or interfere with pedestrian or vehicular access to any Canal & River Trust property, unless preventing, obstructing or interfering with such access is with the consent of Canal & River Trust.

• (2) The undertaker must not exercise the powers conferred by sections 271 or 272 of the 1990 Act in relation to any right of access of Canal & River Trust to Canal & River Trust property, but such right of access may be diverted with the consent of Canal & River Trust.

5

• (1) The undertaker must, before commencing construction of any specified work or carrying out any works on Canal & River Trust property, supply to Canal & River Trust proper and sufficient plans of that work (and such further information as Canal & River Trust may reasonably require) for the approval (having regard to the undertaker’s timetable for the construction of the authorised development) of the engineer; and the specified work must not be commenced except in accordance with such plans as have been approved in writing by the engineer or settled by arbitration in accordance with article 36 (arbitration).

• (2) If by the end of the period of 28 days beginning with the date on which the plans have been supplied to Canal & River Trust the engineer has not provided, in writing, disapproval of the plans and the grounds of disapproval, the undertaker may serve on the engineer written notice requiring the engineer to intimate approval or disapproval within a period of 14 days beginning with the date on which the engineer receives written notice from the undertaker; and if by the expiry of the 14 days the engineer has not intimated approval or disapproval, the engineer is deemed to have approved the plans as submitted.

• (3) When signifying approval of the plans, the engineer may specify any protective works (whether temporary or permanent) that in the engineer’s opinion should be carried out before the commencement of the construction of a specified work to ensure the safety or stability of the waterway or the continued safe and efficient use of the waterway or any Canal & River Trust property, and—

• (a) such protective works (which for the avoidance of doubt may include requirements to fence any proposed works in order to separate them from the waterways, ponds or watercourses situated on Canal & River Trust property either on a permanent or temporary basis) as may be reasonably necessary for those purposes must be constructed by the undertaker, as agreed between the parties or settled by arbitration in accordance with article 36;

• (b) the protective works must be carried out at the expense of the undertaker with all reasonable dispatch; and

• (c) the undertaker must not commence the construction of the specified work until the engineer has notified the undertaker that the protective works have been completed to the engineer’s reasonable satisfaction.

• (4) If the undertaker fails to complete the construction of, or part of, any specified work or any protective work, Canal & River Trust may, if reasonably necessary to ensure the safety or stability of the waterway or the continued safe and efficient use of the waterway, construct any specified work or protective or part of such work in order to complete the construction of, or part of, the work.

6

• (1) Any specified work and any protective work to be constructed by virtue of paragraph 5(3) must, when commenced, be constructed —

• (a) with all reasonable dispatch (having regard to the undertaker’s timetable for construction of the authorised development) in accordance with the plans approved or deemed to have been approved or settled under paragraph 5;

• (b) under the supervision (where appropriate and if given) and to the reasonable satisfaction of the engineer;

• (c) in such manner as to cause as little damage or disturbance as is possible to the waterway;

• (d) in such a manner to ensure that no materials are discharged or deposited into any stream, watercourse, waterway, pond or any other water feature on or forming part of Canal & River Trust property; and

• (e) so far as is reasonably practicable, so as not to interfere with or obstruct the free, uninterrupted and safe use of the waterway.

• (2) If any damage to the waterway is caused by the carrying out of, or in consequence of, the construction of a specified work or a protective work, the undertaker must make good such damage and must pay to Canal & River Trust all reasonable and proper expenses that Canal & River Trust may incur or may be put to and reasonable and proper compensation for any loss which it may sustain in making good or otherwise by reason of such damage, interference or obstruction.

• (3) Nothing in this Part imposes any liability on the undertaker with respect to any damage, costs, expenses or loss attributable to the negligent act or default of Canal & River Trust or its servants, contractors or agents or any liability on Canal & River Trust with respect to any damage, costs, expenses or loss attributable to the negligent act or default of the undertaker or its servants, contractors or agents.

7

The undertaker must—

• (a) at all times afford reasonable facilities to the engineer for access to a specified work during its construction; and

• (b) supply the engineer with all such information as the engineer may reasonably require with regard to a specified work or the method of constructing it.

8

Canal & River Trust must at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by Canal & River Trust under this Part during their construction and must supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them.

9

The undertaker must repay to Canal & River Trust in accordance with the code of practice all costs, charges and expenses reasonably incurred by Canal & River Trust in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction of a specified work.

10

If, at any time during or after the completion of a specified work or a protective work, Canal & River Trust gives notice to the undertaker informing it that the state of maintenance of any part of the specified work or protective work appears to be such as adversely affects the operation of the waterway, the undertaker must, on receipt of the notice, take such steps as may be reasonably necessary to put that specified work in such state of maintenance as not adversely to affect the operation of the waterway.

11

• (1) The undertaker must pay to Canal & River Trust all reasonable and proper costs, charges, damages, losses and expenses not otherwise provided for in this Part that may be reasonably incurred by Canal & River Trust by reason of—

• (a) the existence, construction or maintenance of a specified work or a protective work or the failure of such a work; or

• (b) any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged on a specified work or a protective work,

and the undertaker must indemnify and keep indemnified Canal & River Trust from and against all reasonable and proper claims and demands arising out of or in connection with a specified work or a protective work or any such act or omission within 12 months of completion of the specified work or a protective work.

• (2) The fact that any act or thing may have been done by Canal & River Trust on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision does not (if it was done without negligence on the part of Canal & River Trust or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under this paragraph.

• (3) Canal & River Trust must give the undertaker reasonable notice of any such claim or demand, and except as such conduct would be contrary to law no settlement or compromise of such a claim or demand may be made without the prior written consent of the undertaker, such consent not to be unreasonably withheld or delayed.

12

Canal & River Trust must, on receipt of a written request from the undertaker, from time to time provide the undertaker free of charge with written estimates of the costs, charges, expenses and other liabilities for which the undertaker is or will become liable under this Part and with such information as may reasonably enable the undertaker to assess the reasonableness of any such estimate or claim made or to be made under this Part.

13

In the assessment of any sums payable to Canal & River Trust under this Part, no account must be taken of any increase in the sums claimed that are attributable to any action taken by or any agreement entered into by Canal & River Trust if that action or agreement was not reasonably necessary and was taken or entered into with a view to obtaining the payment of those sums by the undertaker under this Part or increasing the sums so payable.

14

The undertaker and Canal & River Trust may enter into, and carry into effect, agreements for the transfer to the undertaker of—

• (a) any Canal & River Trust property shown on the works or land plans and described in the book of reference;

• (b) any lands, works or other property held in connection with any such Canal & River Trust property; and

• (c) any rights and obligations (whether or not statutory) of Canal & River Trust relating to any Canal & River Trust property or any lands, works or other property referred to in this paragraph.

15

The undertaker must repay to Canal & River Trust in accordance with the code of practice all fees, costs, charges and expenses reasonably incurred by Canal & River Trust—

• (a) in constructing any part of a specified work or protective work on behalf of the undertaker as provided by paragraph 5(4) including, in respect of any permanent protective works, a capitalised sum representing the cost of maintaining and renewing the works;

• (b) in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction of a specified work;

• (c) in respect of the employment or procurement of the services of any persons whom it must be reasonably necessary to appoint for inspecting, signalling, watching and lighting Canal & River Trust property and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or incident arising from the construction or failure of a specified work; and

• (d) in respect of any additional temporary lighting of Canal & River Trust property in the vicinity of the specified work, being lighting made reasonably necessary by reason or in consequence of the construction or failure of a specified work.

16

• (1) If any permanent or temporary alterations or additions to Canal & River Trust property are reasonably necessary in consequence of the construction of a specified work or a protective work during construction, or during a period of 24 months after the completion, of that work in order to ensure the safety of Canal & River Trust property or the continued safe operation of the waterway, such alterations and additions may be carried out by Canal & River Trust.

• (2) If Canal & River Trust gives to the undertaker reasonable notice of its intention to carry out such alterations or additions (which must be specified in the notice), the undertaker must pay to Canal & River Trust the reasonable cost of those alterations or additions including, in respect of any such alterations and additions as are to be permanent, a capitalised sum representing the increase of the costs which may be expected to be reasonably incurred by Canal & River Trust in maintaining, working and, when necessary, renewing the alterations or additions.

• (3) The engineer must, in respect of the capitalised sums referred to in this paragraph and paragraph 15, provide such details of the formula by which those sums have been calculated as the undertaker may reasonably require.

• (4) If the cost of maintaining, working or renewing Canal & River Trust property is reduced in consequence of any such alterations or additions, a capitalised sum representing the saving must be set off against any sum payable by the undertaker to Canal & River Trust under this paragraph.

17

Any difference arising between the undertaker and Canal & River Trust under this Part (other than a difference as to the meaning or construction of this Part) must be referred to and settled by arbitration in accordance with article 36.

PART 6 — Protection for electricity, gas and sewerage undertakers

1

The provisions of this Part have effect for the protection of affected undertakers unless otherwise agreed in writing between the undertaker and the affected undertaker in question.

2

In this Part—

• “affected undertaker” means—a licence holder within the meaning of Part 1 of the 1989 Act;a gas transporter within the meaning of Part 1 of the Gas Act 1986⁴⁸;a water undertaker⁴⁹; anda sewerage undertaker,for the area of the authorised development, and in relation to any apparatus, means the affected undertaker to whom it belongs or by whom it is maintained;

• “alternative apparatus” means alternative apparatus adequate to enable the affected undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;

• “apparatus”—in the case of an affected undertaker that is a licence holder within the meaning of Part 1 of the 1989 Act, means electric lines or electrical plant (as defined in the 1989 Act) belonging to or maintained by the affected undertaker;in the case of an affected undertaker that is a gas transported within the meaning of Part 1 of the Gas Act 1986, means any mains, pipes or other apparatus belonging to or maintained by the affected undertaker for the purposes of gas supply;in the case of an affected undertaker that is a water undertaker, means mains, pipes or other apparatus belonging to or maintained by the affected undertaker for the purposes of water supply; andin the case of an affected undertaker that is a sewerage undertaker—means—any drain or works vested in the affected undertaker under the Water Industry Act 1991; andany sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act; andincludes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,and in each case includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

• “functions” includes powers and duties;

• “in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or on land.

3

This Part does not apply to apparatus in respect of which the relations between the undertaker and the affected undertaker are regulated by Part 3 of the 1991 Act (street works in England and Wales).

4

Despite any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

5

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, the apparatus must not be removed under this Part, and any right of an affected undertaker to maintain that apparatus in the land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the affected undertaker in question.

• (2) If, for the purpose of executing any works in, on or under any land purchased, held or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to the affected undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed; and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an affected undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the affected undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford the facilities and rights referred to in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, the affected undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably practicable use all reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

• (4) Any alternative apparatus to be constructed in land of the undertaker under this Part must be constructed in such manner and in such line or situation as may be agreed between the affected undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 36 (arbitration).

• (5) The affected undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 36, and after the grant to the affected undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under this Part.

• (6) Despite anything in sub-paragraph (5), if the undertaker gives notice in writing to the affected undertaker in question that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the affected undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the affected undertaker .

• (7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

6

• (1) Where, in accordance with this Part, the undertaker affords to an affected undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted on such terms and conditions as may be agreed between the undertaker and the affected undertaker in question or in default of agreement settled by arbitration in accordance with article 36.

• (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the affected undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to the affected undertaker as appears to the arbitrator to be reasonable, having regard to all the circumstances of the particular case.

7

• (1) Not less than 28 days before commencing the execution of any works of the type referred to in paragraph 5(2) that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under that sub-paragraph, the undertaker must submit to the affected undertaker in question a plan, section and description of the works to be executed.

• (2) The works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the affected undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it; and the affected undertaker is entitled to watch and inspect the execution of the works.

• (3) Any requirements made by an affected undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

• (4) If an affected undertaker, in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 5 and 6 apply as if the removal of the apparatus had been required by the undertaker under paragraph 5(2).

• (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and the undertaker having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

• (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency, but in that case it must give to the affected undertaker in question notice as soon as is reasonably practicable and a plan, section and description of the works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

8

• (1) Subject to the following provisions of this paragraph, the undertaker must repay to an affected undertaker the reasonable expenses incurred by the affected undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus (including costs or compensation payable in connection with the acquisition of land for that purpose) which may be required in consequence of the execution of any works referred to in paragraph 5(2).

• (2) The value of any apparatus removed under this Part, that value being calculated after removal, must be deducted from any sum payable under sub-paragraph (1).

• (3) If in accordance with this Part—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 36 to be necessary, then, if such placing involves cost in the construction of works under this Part exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the affected undertaker in question by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

• (5) An amount which, apart from this sub-paragraph, would be payable to an affected undertaker in respect of works by virtue of sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the affected undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

9

• (1) Subject to sub-paragraphs (2) and (3), if, by reason or in consequence of the construction of any works referred to in paragraph 5(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the works) or property of an affected undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any affected undertaker, the undertaker must—

• (a) bear and pay the cost reasonably incurred by the affected undertaker in making good the damage or restoring the service or supply; and

• (b) make reasonable compensation to the affected undertaker for any other expenses, loss, damages, penalty or costs incurred by the affected undertaker by reason or in consequence of the damage or interruption.

• (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an affected undertaker, its officers, servants, contractors or agents.

• (3) An affected undertaker must give the undertaker reasonable notice of any claim or demand, and no settlement or compromise may be made without the consent of the undertaker which, if it withholds consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

10

Nothing in this Part affects the provisions of any enactment or agreement regulating the relations between the undertaker and an affected undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 7 — Protection for operators of electronic communications code networks

1

The provisions of this Part have effect for the protection of an operator unless otherwise agreed in writing between the undertaker and the operator.

2

In this Part—

• “2003 Act” means the Communications Act 2003;

• “conduit system” has the same meaning as in the electronic communications code; and references to providing a conduit system must be construed in accordance with paragraph 1(3A) of the code;

• “electronic communications apparatus” has the same meaning as in the electronic communications code;

• “electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act⁵⁰;

• “electronic communications code network” means—so much of an electronic communications network or conduit system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; andan electronic communications network which the Secretary of State is providing or proposing to provide;

• “electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act;

• “operator” means the operator of an electronic communications code network.

3

The exercise of the powers referred to in article 27 (statutory undertakers) is subject to paragraph 23 of Schedule 2 to the Telecommunications Act 1984⁵¹.

4

• (1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development, its construction or any subsidence resulting from any of those works—

• (a) any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or other property of an operator; or

• (b) there is any interruption in the supply of the service provided by an operator,

the undertaker must—

• (c) bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply;

• (d) make reasonable compensation to an operator for loss sustained by it; and

• (e) indemnify an operator against claims, demands, proceedings, costs, damages and expenses which may be made or taken against, or recovered from, or incurred by, an operator by reason, or in consequence of, any such damage or interruption.

• (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

• (3) The operator must give the undertaker reasonable notice of any claim or demand, and no settlement or compromise of the claim or demand may be made without the consent of the undertaker which, if it withholds consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

• (4) Any difference arising between the undertaker and the operator under this paragraph must be referred to and settled by arbitration under article 36 (arbitration).

5

This Part does not apply to—

• (a) any apparatus in respect of which the relations between the undertaker and an operator are regulated by Part 3 of the 1991 Act (street works in England and Wales); or

• (b) any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.

6

Nothing in this Part affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 8 — Protection for Western Power Distribution (East Midlands) plc

1

The provisions of this Part have effect for the protection of WPD unless otherwise agreed in writing between the undertaker and WPD.

2

In this Part—

• “alternative apparatus” means alternative apparatus adequate to enable WPD to fulfil its statutory functions in a manner no less efficient than previously;

• “alternative rights” means all necessary legal easements, consents, or permissions required by WPD to permit or authorise a diversion;

• “apparatus” means electric lines or electrical plant (in both cases, as defined in the 1989 Act) belonging to or maintained by WPD;

• “emergency” means the immediate threat of death or injury to persons or of damage to property;

• “functions” includes powers and duties;

• “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or on land;

• “WPD” means Western Power Distribution (East Midlands) plc (company number 02366923).

3

This Part does not apply to apparatus in respect of which the relations between the undertaker and WPD are regulated by Part 3 of the 1991 Act (street works in England and Wales).

4

Despite any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

5

If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, except in an emergency—

• (a) the apparatus must not be removed under this Part; and

• (b) any right of WPD to maintain that apparatus in that land must not be extinguished,

until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of WPD.

6

• (1) Unless required as a result of an emergency, the undertaker must not interfere with, build over, under or near to any apparatus within the Order land unless otherwise approved in writing by WPD, following a request from the undertaker (including a description and plan of the works), such approval not to be unreasonably withheld or delayed.

• (2) If—

• (a) for the purpose of executing any works, the undertaker requires to remove or divert any apparatus placed within the Order land; and

• (b) alternative apparatus or any part of alternative apparatus is to be constructed in land other than the Order land as a consequence of the removal or diversion of apparatus,

the undertaker must use its reasonable endeavours to obtain any alternative rights in other land in which the alternative apparatus is to be constructed.

• (3) If the undertaker is not able to obtain the alternative rights required under sub-paragraph (2), the undertaker and WPD must use reasonable endeavours to agree a reasonably practicable and mutually agreeable alternative engineering solution which does not require to be constructed in land other than Order land and does not require alternative rights.

• (4) If—

• (a) alternative apparatus or any part of alternative apparatus is to be constructed elsewhere than in other land of the undertaker; or

• (b) the undertaker is unable to afford the alternative rights referred to in sub-paragraph (2) and an alternative engineering solution cannot be agreed in accordance in sub-paragraph (3) in the land in which the alternative apparatus or part of alternative apparatus is to be constructed,

WPD must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed, except that this obligation does not extend to the requirement for WPD to use its compulsory purchase powers to this end unless WPD elects to do so.

• (5) The works must be executed only in accordance with the plans or drawings submitted under sub-paragraph (1) (or sub-paragraph (3), where relevant) and with such reasonable requirements as may be made in accordance with sub-paragraph (6) by WPD for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and WPD is entitled to watch and inspect the execution of the works.

• (6) Any requirements made by WPD under sub-paragraph (5) must be made within 21 days beginning with the date on which the plans or drawings under sub-paragraph (1) are submitted to WPD.

• (7) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan and description instead of the plan and description previously submitted, and the undertaker having done so the provisions of this paragraph apply to and in respect of the new plan and description.

• (8) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency, but in that case it must give to WPD notice as soon as is reasonably practicable and a plan and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (5) in so far as is reasonably practicable in the circumstances.

7

• (1) Subject to the following provisions of this paragraph, the undertaker must pay to WPD on demand all charges, costs and expenses reasonably anticipated or incurred by WPD in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any works referred to in this Part including without limitation any costs reasonably incurred or compensation properly paid in connection with—

• (a) the acquisition of rights or the exercise of statutory powers for the apparatus including without limitation, if WPD elects to use compulsory acquisition powers to acquire any necessary rights under paragraph 6(4), all costs incurred as a result of such action; and

• (b) the carrying out of any diversion work or the provision of any alternative apparatus;

• (c) the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

• (d) the approval of plans;

• (e) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

• (f) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any works referred to in this Part.

• (2) WPD must dispose of any apparatus removed under paragraph 6 on receipt of written notice from the undertaker.

• (3) If in accordance with this Part and at the request of WPD apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions where it is not necessary as a direct replacement of existing apparatus or to meet the current industry standards and best practice then, if such placing involves cost in the construction of works under this Part exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, as the case may be, the amount which apart from this sub-paragraph would be payable to WPD by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

8

• (1) Subject to sub-paragraphs (2) and (3), if—

• (a) by reason or in consequence of the construction of any works referred to in this Part;

• (b) in consequence of the construction use, maintenance, or failure of any of the authorised development by or on behalf of the undertaker; or

• (c) in consequence of any act or default of the undertaker (or any person employed or authorised by the undertaker) in the course of carrying out the works including without limitation works carried out by the undertaker under this Part (or any subsidence resulting from any of the works),

any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the works) or property of WPD, or there is any interruption in any service provided, or in the supply of any goods, by WPD, the undertaker must—

• (d) bear and pay the documented cost reasonably incurred by WPD in making good the damage or restoring the supply; and

• (e) indemnify WPD for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from WPD by reason or in consequence of the damage or interruption or WPD becoming liable to any third party.

• (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of WPD, its officers, servants, contractors or agents.

• (3) WPD must give the undertaker reasonable notice of any claim or demand, and no settlement or compromise may be made without the consent of the undertaker which, if it withholds consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

9

• (1) Any difference or dispute arising between the undertaker and WPD under this Part must, unless otherwise agreed in writing between the undertaker and WPD, be determined by arbitration in accordance with article 36 (arbitration).

SCHEDULE 9 — Deemed licence under Marine and Coastal Access Act 2009

PART 1 — Licensed marine activities

Interpretation

1

• (1) In this licence—

• “2009 Act” means the Marine and Coastal Access Act 2009;

• “Annex 1 habitat” means a habitat set out in Annex 1 to Council Directive 92/43/EEC of 21st May 1992 on the conservation of natural habitats and of wild fauna and flora;

• “authorised deposits” means the substances and articles specified in clause 2(3);

• “authorised scheme” means Work Nos. 1 and 2 described in clause 2;

• “cable” includes fibre-optic cables either within the cable or laid alongside it;

• “cable ducts” means conduits for the installation of electrical cables;

• “cable protection” means measures to protect cables from physical damage and exposure due to loss of sea bed sediment including (but not limited to) the use of bagged solutions filled with gravel or other materials as approved by the MMO, protective aprons or covering mattresses, flow energy dissipation devices or rock and gravel placement;

• “collector substations” means the collector substations authorised by the Triton Knoll Offshore Wind Farm Order 2013;

• “commence” means begin to carry out the licensed marine activities other than pre-construction surveys or monitoring; and “commencement” must be construed accordingly;

• “Condition” means a condition in Part 2;

• “enforcement officer” means a person authorised to carry out enforcement duties under Part 4 of the 2009 Act;

• “environmental statement” means the document certified as the environmental statement by the Secretary of State under article 35 of the Order;

• “Historic England” means the Historic Buildings and Monuments Commission for England or any replacement body;

• “horizontal directional drilling works” means works for the laying of cables by means of horizontal directional drilling and includes exit for horizontal directional drilling and related works;

• “Kingfisher Fortnightly Bulletin” means the bulletin published by the Humber Seafood Institute or such other alternative publication approved in writing by the MMO;

• “licensed marine activities” means the activities specified in Part 1;

• “maintain” includes— inspect, upkeep, repair, adjust and alter; and in relation to any of the ancillary works in Part 2 of Schedule 1 to the Order, remove, reconstruct and replace, to the extent assessed in the environmental statement; and “maintenance” must be construed accordingly;

• “MCA” means the Maritime and Coastguard Agency;

• “MHWS” (mean high water springs) means the average throughout a year of the heights of 2 successive high waters during the periods of 24 hours when the range of the tide is greatest as defined by the MMO and shown on the Order limits plans;

• “MMO” means the Marine Management Organisation;

• “notice to mariners” includes any notice to mariners which may be issued by the Admiralty, Trinity House, Queen’s harbour masters, government departments and harbour and pilotage authorities;

• “offshore Order limits” means the limits shown on the Order limits plans within which the authorised scheme may be carried out, whose grid co-ordinates are set out in clause 2(4);

• “Order” means the Triton Knoll Electrical System Order 2016;

• “Order limits plans” means the plans certified as the Order limits plans by the Secretary of State under article 35 of the Order;

• “outline offshore written scheme of investigation” means the document certified as the outline offshore written scheme of investigation by the Secretary of State under article 35 of the Order;

• “outline offshore operations and maintenance plan” means the document certified as the outline offshore operations and maintenance plan by the Secretary of State under article 35 of the Order;

• “statutory nature conservation body” means the Government’s advisor on the natural environment;

• “Trinity House” means the Corporation of Trinity House of Deptford Strond;

• “UKHO” means the United Kingdom Hydrographic Office;

• “undertaker” means Triton Knoll Offshore Wind Farm Limited (company number 03696654);

• “vessel” means every description of vessel, however propelled or moved, and includes a non-displacement craft, a personal watercraft, a seaplane on the surface of the water, a hydrofoil vessel, a hovercraft or any other amphibious vehicle and any other thing constructed or adapted for movement through, in, on or over water and which is at the time in, on or over water;

• “Work No. 3” means Work No. 3 as set out in Part 1 of Schedule 1 to the Order.

• (2) A reference to any statute, order, regulation or similar instrument must be construed as a reference to the statute, order, regulation or instrument as amended by any subsequent statute, order, regulation or instrument or as contained in any subsequent re-enactment.

• (3) Unless otherwise indicated—

• (a) all times are Greenwich Mean Time (GMT);

• (b) all co-ordinates are latitude and longitude degrees, minutes and seconds to 3 decimal places.

• (4) Except where otherwise notified in writing by the relevant organisation, the primary point of contact with the organisations listed below and the address for returns and correspondence is—

• (a) Marine Management Organisation

Offshore Marine Licensing

Lancaster House

Hampshire Court

Newcastle-upon-Tyne NE4 7YH

Tel: 0300 123 1032

• (b) Marine Management Organisation (coastal office)

Estuary House

Wharncliffe Road

Grimsby

Lincolnshire DN31 3QL

Tel: 01472 355 112

• (c) Trinity House

Tower Hill

London EC3N 4DH

Tel: 0207 481 6900

• (d) The United Kingdom Hydrographic Office

Admiralty Way

Taunton

Somerset TA1 2DN

Tel: 01823 337 900

• (e) Maritime and Coastguard Agency

Navigation Safety Branch

Bay 2/20

Spring Place

105 Commercial Road

Southampton S015 1EG

Tel: 023 8032 9448

• (f) Centre for Environment, Fisheries and Aquaculture Science

Pakefield Road

Lowestoft

Suffolk NR33 0HT

Tel: 01502 562 244

• (g) Natural England

Foss House

Kings Pool

1-2 Peasholme Green

York Y01 7PX

Tel: 0300 060 4911

• (h) The Historic Buildings and Monuments Commission for England

Eastgate Court

195-205 High Street

Guildford GU1 3EH

Tel: 01483 252 057

• (i) Joint Nature Conservation Committee

Inverdee House

Baxter Street

Aberdeen AB11 9QA

Details of licensed marine activities

2

• (1) This licence authorises the undertaker (and any agent or contractor acting on its behalf) to carry out seaward of MHWS the following licensable marine activities under section 66(1) of the 2009 Act, subject to the Conditions—

• (a) the deposit at sea of the substances and articles specified in paragraph (3);

• (b) the construction of works in or over the sea and/or on or under the sea bed; and

• (c) the removal of sediment samples for the purposes of informing environmental monitoring under this licence during pre-construction, construction and operation.

• (2) The activities are authorised in relation to the construction, maintenance and operation of—

• (a) Work No. 1 – up to 6 cables for the transmission of high voltage alternating current electricity together with fibre-optic cables for the transmission of electronic communications laid on or beneath the seabed between the collector substations and Work No. 2 including pipeline crossings and cable protection;

• (b) Work No. 2 – up to 6 cables for the transmission of high voltage alternating current electricity together with fibre-optic cables for the transmission of electronic communications laid in cable ducts from mean low water connecting Work No. 1 and Work No. 3;

• (c) in connection with Work Nos. 1 and 2, ancillary works within the offshore Order limits seaward of MHWS which have been subject to an environmental impact assessment recorded in the environmental statement comprising—

• (i) temporary landing places, moorings or other means of accommodating vessels in the construction and/or maintenance of the authorised scheme;

• (ii) temporary or permanent buoys, beacons, fenders and other navigational warning or ship impact protection works;

• (iii) cable route preparation works;

• (iv) the removal, reconstruction or alteration of the position of subsea cables existing at the date of commencement of the licensed marine activities; and

• (v) horizontal directional drilling exit pits.

• (3) The substances or articles authorised for deposit at sea are—

• (a) iron/steel;

• (b) stone and rock;

• (c) concrete;

• (d) sand and gravel;

• (e) plastic/synthetic; and

• (f) marine coatings, other chemicals and timber.

• (4) The grid co-ordinates for the offshore Order limits seaward of MHWS are specified below and more particularly shown on the Order limits plans—

Decommissioning

3

• (1) This licence does not permit the decommissioning of the authorised scheme.

• (2) No decommissioning activity may commence until a decommissioning programme has been approved by the Secretary of State under section 106 of the Energy Act 2004.

• (3) At least 4 months before carrying out any decommissioning activity, the undertaker must notify the MMO of the proposed activity to establish whether a marine licence is required for the activity.

Application of section 72 of Marine and Coastal Access Act 2009

4

Section 72 of the 2009 Act applies to this licence, except that subsection (7) relating to the transfer of the licence applies only to a transfer not falling within article 5 of the Order.

Agreement to variations

5

Where the words “unless otherwise agreed” appear in the Conditions, any agreement may be given only where it has been demonstrated to the satisfaction of the MMO (or the MCA, as the case may be) that such agreement is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

PART 2 — Conditions

Design parameters

1

• (1) The total number of cables comprising Work No. 1 must not exceed 6.

• (2) The total length of the cables comprising Work No. 1 must not exceed 396 kilometres.

• (3) The total amount of cable protection for the cables comprising Work No. 1 must not exceed 367,200 square metres and 320,760 cubic metres.

• (4) The finished height of any cable protection must not exceed 10% of the navigable water depth existing before works commence unless otherwise agreed in writing in advance with the MMO and the MCA.

Notifications and inspections

2

• (1) The undertaker must ensure that—

• (a) a copy of this licence and any subsequent amendments or revisions to it is provided to—

• (i) all agents and contractors notified to the MMO in accordance with Condition 11; and

• (ii) the masters and transport managers responsible for the vessels notified to the MMO in accordance with that Condition;

• (b) within 28 days of receipt of a copy of this licence the persons referred to in sub-paragraph (a) provide a completed form to the MMO confirming their understanding of the terms and conditions of this licence.

• (2) Only the persons and vessels notified to the MMO in accordance with Condition 11 are permitted to carry out the licensed marine activities.

• (3) Copies of this licence must also be available for inspection at the following locations—

• (a) the undertaker’s registered address;

• (b) any site office located at or adjacent to the construction site and used by the undertaker or its agents and contractors responsible for the loading, transportation or deposit of the authorised deposits; and

• (c) on board each vessel and at the office of any transport manager with responsibility for vessels from which authorised deposits or removals are to be made.

• (4) The document referred to in paragraph (1)(a) must be available for inspection by an authorised enforcement officer at all times at the locations set out in paragraph (3).

• (5) The undertaker must provide access, and if necessary appropriate transportation, to the offshore construction site or any other associated works or vessels to facilitate any inspection that the MMO considers necessary to inspect the works during construction and operation of the authorised scheme.

• (6) The undertaker must inform the local MMO coastal office in writing at least 5 working days before the commencement of the licensed marine activities or any part of them.

• (7) The Kingfisher Information Service of Seafish must be informed by email to kingfisher@seafish.co.uk of details of the vessel routes, timings and locations relating to the construction of the authorised scheme or relevant part—

• (a) at least 2 weeks before the commencement of offshore activities, for inclusion in the Kingfisher Fortnightly Bulletin and offshore hazard awareness data; and

• (b) on completion of all offshore activities,

and confirmation of notification must be provided to the MMO.

• (8) The undertaker must ensure that a notice to mariners is issued at least 10 working days before the commencement of the licensed marine activities or any part of them advising of the start date of Work No. 1 and Work No. 2 and the expected vessel routes from the local construction ports to the relevant locations.

• (9) The undertaker must ensure that the notices to mariners are updated and reissued at weekly intervals during construction activities and within 5 days of any planned operations and maintenance works and supplemented with VHF radio broadcasts agreed with the MCA in accordance with the construction and monitoring programme approved under Condition 7(b). Copies of all notices must be provided to the MMO.

• (10) The undertaker must notify the UKHO of the commencement (within 2 weeks), progress and completion (within 2 weeks) of the authorised scheme in order that all necessary amendments to nautical charts are made. Copies of all notices must be provided to the MMO.

• (11) In case of damage to, or the destruction or decay of, the authorised scheme or any part of it, the undertaker must, as soon as possible and no later than 24 hours following the identification of damage, destruction or decay, notify Trinity House, the MMO, the MCA and the UKHO.

Offshore safety management

3

• (1) No part of the authorised scheme may be commenced until the MMO, in consultation with the MCA, has given written approval for an emergency response co-operation plan which includes full details of the emergency response co-operation plans for the construction, operation and decommissioning phases of that part of the authorised scheme in accordance with the MCA recommendations as appropriate contained within MCA Marine Guidance Note 543 “Safety of Navigation: Offshore Renewable Energy Installations (OREIs) - Guidance on UK Navigational Practice, Safety and Emergency Response Issues”.

• (2) The emergency response co-operation plan must be implemented as approved, unless otherwise agreed in writing by the MMO in consultation with the MCA.

• (3) No part of the authorised scheme may commence until the MMO in consultation with the MCA, has confirmed in writing that the undertaker has taken into account and, so far as is applicable to that stage of the development, adequately addressed all MCA recommendations as appropriate to the authorised scheme contained within MCA Marine Guidance Note 543 “Safety of Navigation: Offshore Renewable Energy Installations (OREIs) - Guidance on UK Navigational Practice, Safety and Emergency Response Issues” and its annexes.

Aids to navigation

4

• (1) The undertaker must during the whole period of the construction, operation, alteration, replacement or decommissioning of the authorised scheme exhibit such lights, marks, sounds, signals and other aids to navigation, and take such other steps for the prevention of danger to navigation, as Trinity House directs.

• (2) The undertaker must keep Trinity House and the MMO informed of progress of the authorised scheme including—

• (a) a notice of commencement of construction of the authorised scheme within 24 hours of commencement having occurred;

• (b) notice within 24 hours of any aids to navigation being established by the undertaker; and

• (c) notice within 5 working days of completion of construction of the authorised scheme.

• (3) The undertaker must submit reports to Trinity House detailing the working condition of aids to navigation quarterly or at more frequent intervals as specified by Trinity House.

• (4) The undertaker must notify Trinity House and the MMO of any failure of the aids to navigation including timescales and plans for remedying the failure, as soon as possible and no later than 24 hours following the detection of the failure.

• (5) Where Condition 2(11) applies, the undertaker must lay down such buoys, exhibit such lights and take such other steps for preventing danger to navigation as Trinity House directs.

Chemicals, drilling and debris

5

• (1) Unless otherwise agreed in writing by the MMO, all chemicals used in the construction of the authorised scheme must be selected from the list of notified chemicals approved for use by the offshore oil and gas industry under the Offshore Chemicals Regulations 2002⁵².

• (2) Unless otherwise agreed in writing by the MMO, the undertaker must ensure that any coatings and any treatments are suitable for use in the marine environment and are used in accordance with Pollution Prevention Guidelines or guidelines approved by the Health and Safety Executive.

• (3) The storage, handling, transport and use of fuels, lubricants, chemicals and other substances must be undertaken so as to prevent releases into the marine environment including bunding of a minimum of 110% of the total volume of all reservoirs and containers.

• (4) The undertaker must ensure that no waste concrete slurry or wash water from concrete or cement works is discharged into the marine environment. Concrete and cement mixing and washing areas must be contained to prevent run off entering the water through the freeing ports.

• (5) The undertaker must ensure that any oil, fuel or chemical spill within the marine environment is reported to the MMO Marine Pollution Response Team within 24 hours.

• (6) The undertaker must ensure that any debris arising from the construction of the authorised scheme or from equipment or temporary works placed seaward of MHWS is removed within 4 weeks of completion of the authorised scheme unless otherwise agreed with the MMO.

• (7) Subject to paragraph (10), at least 10 days before the commencement of licensed marine activities, the undertaker must submit to the MMO an audit sheet covering all aspects of the construction of the authorised scheme or any phase of it. The audit sheet must include details of—

• (a) loading facilities;

• (b) vessels;

• (c) equipment;

• (d) shipment routes;

• (e) transport;

• (f) working schedules; and

• (g) all components and materials to be used in the construction of the authorised scheme.

• (8) The audit sheet must be maintained throughout the construction of the authorised scheme (or relevant phase) and must be submitted to the MMO for review at fortnightly intervals during periods of active offshore construction.

• (9) If the undertaker discovers that any materials on the audit sheet are unaccounted for, the undertaker must inform the MMO within 6 hours of the discovery. The notification must include a description of the materials unaccounted for and, where known, provide the co-ordinates where they may be located. Where the MMO thinks it is appropriate to do so, the MMO may require the undertaker to carry out a side-scan survey to plot all the potential obstructions within the relevant area of the offshore Order limits (and this area may be extended at the reasonable discretion of the MMO). Where practicable, the undertaker must remove any obstruction that the MMO believes to be associated with the licensed marine activities at the undertaker’s expense.

• (10) As an alternative to the completion of an audit sheet, with written approval from the MMO, the undertaker may introduce a dropped object procedure. If a dropped object procedure is introduced, any dropped objects must be reported to the MMO using the dropped object procedure form within 6 hours of the undertaker becoming aware of an incident. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) and may require obstructions to be removed from the seabed at the undertaker’s expense.

• (11) The undertaker must agree with the MMO, before commencement of works, whether the dropped object procedure or audit sheet is to be used.

• (12) The undertaker must ensure that any rock material used in the construction of the authorised scheme is from a recognised source free from contaminants and containing minimal fines.

• (13) If any rock material used in the construction of the authorised scheme is misplaced or lost seaward of MHWS, the undertaker must report the loss to the MMO, Trinity House, the MCA and the UKHO as soon as possible and in any event within 6 hours and, if the MMO reasonably considers such material to constitute a navigation or environmental hazard (dependent on the size and nature of the material), the undertaker must endeavour to locate the material and recover it.

Force majeure

6

• (1) If, due to stress of weather or any other cause, the master of a vessel determines that it is necessary to deposit the authorised deposits otherwise than in accordance with this licence because the safety of human life or of the vessel is threatened, full details of the circumstances of the deposit must be notified to the MMO within 48 hours.

• (2) The unauthorised deposits must be removed at the expense of the undertaker unless written approval is obtained from the MMO.

Pre-construction plans and documentation

7

The licensed marine activities or any part of those activities except for horizontal directional drilling works within Work No. 2 must not be commenced until the following (as far as relevant to that part) have been submitted to and approved in writing by the MMO—

• (a) a plan (to be approved after consultation with Trinity House, the MCA and the statutory nature conservation body) which shows the length and arrangement of the cables comprising Work Nos. 1 and 2 to ensure conformity with the description of Work Nos. 1 and 2 and compliance with Condition 1;

• (b) a construction and monitoring programme to include details of—

• (i) the proposed construction start date;

• (ii) proposed timings for mobilisation of plant, delivery of materials and installation works;

• (iii) proposed pre-construction surveys, baseline report format and content, post-construction monitoring and related reporting in accordance with paragraph (g) and Conditions 12 and 13; and

• (iv) an indicative written construction programme (insofar as not shown in accordance with sub-paragraph (ii)),

with details in accordance with sub-paragraph (iii) to be submitted to the MMO at least 4 months before the first survey unless otherwise agreed in writing with the MMO;

• (c) a construction method statement (to be approved after consultation with the statutory nature conservation body) in accordance with the construction methods assessed in the environmental statement and including details of—

• (i) cable installation including cable landfall, cable protection and pipeline crossings;

• (ii) contractors;

• (iii) vessels and vessels transit corridors; and

• (iv) associated and ancillary works;

• (d) a project environmental management plan to include details of—

• (i) a marine pollution contingency plan to address the risks, methods and procedures to deal with any spills and collision incidents during the construction and operation of the authorised scheme in relation to all activities carried out;

• (ii) a chemical risk assessment to include information regarding how and when chemicals are to be used, stored and transported in accordance with recognised best practice guidance;

• (iii) waste management and disposal arrangements; and

• (iv) the appointment and responsibilities of a fisheries liaison officer and an environmental liaison officer;

• (e) a cable protection plan (to be approved after consultation with the statutory nature conservation body) providing details of the need, type, sources, quantity and installation methods for cable armouring and a statement of the total area and volume of cable armouring material to be installed, to be within the scope of the environmental impact assessment recorded in the environmental statement;

• (f) a cable specification and installation plan for the offshore Order limits (to be approved after consultation with Trinity House, the MCA and the statutory nature conservation body) to include—

• (i) technical specification of the cables including a desk-based assessment of attenuation of electro-magnetic field strengths, shielding and cable burial depth in accordance with industry good practice; and

• (ii) a detailed cable-laying plan incorporating a burial risk assessment to ascertain suitable burial depths and cable-laying techniques including cable protection;

• (g) a written scheme of archaeological investigation in relation to the offshore Order limits seaward of mean low water (to be approved after consultation with Historic England) in accordance with the outline offshore written scheme of investigation and industry good practice to include—

• (i) details of responsibilities of the undertaker, archaeological consultant and contractor inclusive of a programme for the production of reports and publication of results;

• (ii) a methodology for any further site investigation including any specifications for geophysical, geotechnical and diver- or remotely-operated vehicle investigations;

• (iii) archaeological analysis and reporting of survey data, and a timetable, which must be submitted to the MMO within 4 months of any survey being completed;

• (iv) delivery of any mitigation including, where necessary, identification and modification of archaeological exclusion zones;

• (v) monitoring during and post-construction including a conservation programme for finds;

• (vi) archiving of archaeological material inclusive of any completed and agreed archaeological reports produced through the written scheme of archaeological investigation that are to be deposited by the undertaker within a public archive in accordance with the OASIS (outline access to the index of archaeological investigations) system; and

• (vii) a reporting and recording protocol including reporting of any wreck or wreck material during construction, operation and decommissioning of the authorised scheme;

• (h) a mitigation scheme (to be approved after consultation with the statutory nature conservation body) for Annex 1 habitat biogenic reef (Mytilus edulis and/or Sabellaria spinulosa) features (or biogenic reef outside the Inner Dowsing, Race Bank and North Ridge Site of Community Importance) identified by the survey referred to in Condition 12(4)(a); and

• (i) an offshore operations and maintenance plan (to be approved after consultation with the statutory nature conservation body) in accordance with the outline offshore operations and maintenance plan to be submitted to the MMO at least 4 months before commencement of operation of the authorised scheme and to provide for review and resubmission every 3 years during the operational phase.

Archaeological reports

8

• (1) Any archaeological reports produced in accordance with Condition 7(g)(iii) must be agreed with Historic England.

• (2) The undertaker must ensure that a copy of any agreed archaeological report is deposited with the National Record of the Historic Environment by submitting a Historic England OASIS form with a digital copy of the report within 6 months of the completion of construction of the authorised scheme.

• (3) If the report relates to the intertidal area, the undertaker must notify the MMO and Lincolnshire County Council that the OASIS report has been submitted to the National Record of the Historic Environment within 2 weeks of the submission.

Pre-construction plans and documentation: horizontal directional drilling works within Work No. 2

9

• (1) Horizontal directional drilling works within Work No. 2 must not be commenced until the following have been submitted to and approved in writing by the MMO (as far as relevant to those works)—

• (a) a construction method statement in accordance with the construction methods assessed in the environmental statement and including details of contractors, vessels and vessel transit corridors;

• (b) a written scheme of archaeological investigation (to be approved after consultation with Historic England) in accordance with the outline offshore written scheme of investigation and industry good practice; and

• (c) a marine pollution contingency plan to address the risks, methods and procedures to deal with any spills and collision incidents.

• (2) The undertaker must also comply with Condition 2(6) to (9) before horizontal directional drilling works are commenced.

Pre-construction plans and documentation: time for submission, etc.

10

• (1) Each plan, programme, scheme or statement required to be approved under Condition 7 or 9 must be submitted for approval at least 4 months before the intended start of construction, except where otherwise stated or unless otherwise agreed in writing by the MMO.