The A428 Black Cat to Caxton Gibbet Development Consent Order 2022

• (1) Subject to the following provisions of this paragraph, the undertaker must pay to National Grid within 30 days of receipt of an itemised invoice or claim from National Grid all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by National Grid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works including without limitation—

• (a) any costs reasonably incurred by or compensation properly paid by National Grid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by National Grid as a consequence of National Grid—

• (i) using its own compulsory purchase powers to acquire any necessary rights under paragraph 36(3); or

• (ii) exercising any compulsory purchase powers in the Order transferred to or benefitting National Grid;

• (b) in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place;

• (c) the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

• (d) the approval of plans;

• (e) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

• (f) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule.

• (2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

• (3) If in accordance with the provisions of this Part of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 45 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.

• (5) Any amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Indemnity

41

• (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, use, maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of National Grid, or there is any interruption in any service provided, or in the supply of any goods, by National Grid, or National Grid becomes liable to pay any amount to any third party, the undertaker will—

• (a) bear and pay on demand accompanied by an invoice or claim from National Grid the cost reasonably and properly incurred by National Grid in making good such damage or restoring the supply; and

• (b) indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party as aforesaid other than arising from any default of National Grid.

• (2) The fact that any act or thing may have been done by National Grid on behalf of the undertaker or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid or under its supervision will not (unless sub-paragraph (3) applies), excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless National Grid fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.

• (3) Nothing in sub-paragraph (1) imposes any liability on the undertaker in respect of—

• (a) any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents;

• (b) any part of the authorised works carried out by National Grid in the exercise of any functions conferred by this Order pursuant to a grant or transfer under article 10 (consent to transfer benefit of Order).

• (4) National Grid must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

• (5) National Grid must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds.

• (6) National Grid must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within National Grid’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of National Grid’s control and if reasonably requested to do so by the undertaker National Grid must provide an explanation of how the claim has been minimised, where relevant.

Enactments and agreements

42

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Co-operation

43

• (1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or National Grid requires the removal of apparatus under paragraph 36(2) or National Grid makes requirements for the protection or alteration of apparatus under paragraph 38 or 39, the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of National Grid’s undertaking and National Grid must use its best endeavours to co-operate with the undertaker for that purpose.

• (2) For the avoidance of doubt whenever the undertaker’s or National Grid’s consent, agreement or approval is required in relation to plans, documents or other information submitted under this schedule, or agreement is required to be reached between the parties under this Part of this Schedule, it must not be unreasonably withheld or delayed.

Access

44

If in consequence of the agreement reached in accordance with paragraph 35(1) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative means of access to such apparatus as will enable National Grid to maintain or use the apparatus no less effectively than was possible before such obstruction.

Arbitration

45

Save for differences or disputes arising under paragraph 36(2), 36(4) and 37(1), any difference or dispute arising between the undertaker and National Grid under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and National Grid, be determined by arbitration in accordance with article 50 (arbitration).

Notices

46

Notwithstanding article 49 (service of notices), any plans submitted to National Grid by the undertaker pursuant to paragraph 9 or 10 must be sent to National Grid Plant Protection at plantprotection@nationalgrid.com or such other address as National Grid may from time to time appoint instead for that purpose and notify to the undertaker in writing.

PART 5 — PROTECTION FOR NETWORK RAIL INFRASTRUCTURE LIMITED

47

The following provisions of this Part of this Schedule have effect, unless otherwise agreed in writing between the undertaker and Network Rail and, in the case of paragraph 61, any other person on whom rights or obligations are conferred by that paragraph.

48

In this Part of the Schedule—

• “construction” includes execution, placing, alteration and reconstruction and “construct” and “constructed” have corresponding meanings;

• “the engineer” means an engineer appointed by Network Rail for the purposes of this Order;

• “network licence” means the network licence, as the same is amended from time to time, granted to Network Rail Infrastructure Limited by the Secretary of State in exercise of his powers under section 8¹²⁷ (licences) of the Railways Act 1993;

• “Network Rail” means Network Rail Infrastructure Limited (company number 02904587 whose registered office is at 1 Eversholtt Street, London, NW1 2DN) and any associated company of Network Rail Infrastructure Limited which holds property for railway purposes, and for the purpose of this definition “associated company” means any company which is (within the meaning of section 1159 (meaning of “subsidiary” etc.) of the Companies Act 2006¹²⁸ the holding company of Network Rail Infrastructure Limited, a subsidiary of Network Rail Infrastructure Limited or another subsidiary of the holding company of Network Rail Infrastructure Limited;

• “plans” includes sections, designs, design data, software, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of railway property;

• “protective works” means any works specified by the engineer under paragraph 51(4);

• “railway operational procedures” means procedures specified under any access agreement (as defined in the Railways Act 1993) or station lease;

• “railway property” means any railway belonging to Network Rail Infrastructure Limited and—any station, land, works, apparatus and equipment belonging to Network Rail Infrastructure Limited or connected with any such railway; andany easement or other property interest held or used by Network Rail Infrastructure Limited for the purposes of such railway or works, apparatus or equipment; and

• “specified work” means so much of any of the authorised development as is situated upon, across, under, over or within 15 metres of, or may in any way adversely affect, railway property.

49

• (1) Where under this Part of this Schedule Network Rail is required to give its consent or approval in respect of any matter, that consent or approval is subject to the condition that Network Rail complies with any relevant railway operational procedures and any obligations under its network licence or under statute.

• (2) In so far as any specified work or the acquisition or use of railway property is or may be subject to railway operational procedures, Network Rail must—

• (a) co-operate with the undertaker with a view to avoiding undue delay and securing conformity as between any plans approved by the engineer and requirements emanating from those procedures; and

• (b) use its reasonable endeavours to avoid any conflict arising between the application of those procedures and the proper implementation of the authorised development pursuant to this Order.

50

• (1) The undertaker must not exercise the powers conferred by articles 24 (compulsory acquisition of land) or 27 (compulsory acquisition of rights and imposition of restrictive covenants) or the powers conferred by section 11(3) (powers of entry) of the 1965 Act in respect of any railway property unless the exercise of such powers is with the consent of Network Rail.

• (2) The undertaker must not in the exercise of the powers conferred by this Order prevent pedestrian or vehicular access to any railway property, unless preventing such access is with the prior written consent of Network Rail.

• (3) The undertaker must not exercise the powers conferred by sections 271 (extinguishment of rights of statutory undertakers: preliminary notices) or 272¹²⁹ (extinguishment of rights of electronic communications code network operators: preliminary notices) of the 1990 Act, or article 39 (statutory undertakers), in relation to any right of access of Network Rail to railway property, but such right of access may be diverted with the prior written consent of Network Rail.

• (4) The undertaker must not under the powers of this Order acquire or use or acquire new rights over any railway property except with the consent of Network Rail.

• (5) Where Network Rail is asked to give its consent pursuant to this paragraph, such consent must not be unreasonably withheld but may be given subject to reasonable conditions.

51

• (1) The undertaker must before commencing construction of any specified work supply to Network Rail proper and sufficient plans of that work for the reasonable approval of the engineer and the specified work must not be commenced except in accordance with such plans as have been approved in writing by the engineer or settled by in accordance with article 50 (arbitration).

• (2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld, and if by the end of the period of 28 days beginning with the date on which such plans have been supplied to Network Rail the engineer has not intimated his disapproval of those plans and the grounds of disapproval the undertaker may serve upon the engineer written notice requiring the engineer to intimate his approval or disapproval within a further period of 28 days beginning with the date upon which the engineer receives written notice from the undertaker. If by the expiry of the further 28 days the engineer has not intimated his approval or disapproval, the engineer shall be deemed to have approved the plans as submitted.

• (3) If by the end of the period of 28 days beginning with the date on which written notice was served upon the engineer under sub-paragraph (2), Network Rail gives notice to the undertaker that Network Rail desires itself to construct any part of a specified work which in the opinion of the engineer will or may affect the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker desires such part of the specified work to be constructed, Network Rail must construct it without unnecessary delay on behalf of and to the reasonable satisfaction of the undertaker in accordance with the plans approved or deemed to be approved or settled under this paragraph, and under the supervision (where appropriate and if given) of the undertaker.

• (4) When signifying approval of the plans the engineer may specify any protective works (whether temporary or permanent) which in his opinion should be carried out before the commencement of the construction of a specified work to ensure the safety or stability of railway property or the continuation of safe and efficient operation of the railways of Network Rail or the services of operators using the same (including any relocation de-commissioning and removal of works, apparatus and equipment necessitated by a specified work and the comfort and safety of passengers who may be affected by the specified works), and such protective works as may be reasonably necessary for those purposes must be constructed by Network Rail or by the undertaker, if Network Rail so desires, and such protective works must be carried out at the expense of the undertaker in either case without unnecessary delay and the undertaker must not commence the construction of the specified works until the engineer has notified the undertaker that the protective works have been completed to the engineer’s reasonable satisfaction.

52

• (1) Any specified work and any protective works to be constructed by virtue of paragraph 5(4) must, when commenced, be constructed—

• (a) without unnecessary delay in accordance with the plans approved or deemed to have been approved or settled under paragraph 51;

• (b) under the supervision (where appropriate and if given) and to the reasonable satisfaction of the engineer;

• (c) in such manner as to cause as little damage as is possible to railway property; and

• (d) so far as is reasonably practicable, so as not to interfere with or obstruct the free, uninterrupted and safe use of any railway of Network Rail or the traffic thereon and the use by passengers of railway property.

• (2) If any damage to railway property or any such interference or obstruction shall be caused by the carrying out of, or in consequence of the construction of a specified work, the undertaker must, notwithstanding any such approval, make good such damage and must pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss which it may sustain by reason of any such damage, interference or obstruction.

• (3) Nothing in this Part of this Schedule imposes any liability on the undertaker with respect to any damage, costs, expenses or loss attributable to the negligence of Network Rail or its servants, contractors or agents or any liability on Network Rail with respect of any damage, costs, expenses or loss attributable to the negligence of the undertaker or its servants, contractors or agents.

53

The undertaker must—

• (a) at all times afford reasonable facilities to the engineer for access to a specified work during its construction; and

• (b) supply the engineer with all such information as the engineer may reasonably require with regard to a specified work or the method of constructing it.

54

Network Rail must at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by Network Rail under this Part of this Schedule during their construction and must supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them.

55

• (1) If any permanent or temporary alterations or additions to railway property, are reasonably necessary in consequence of the construction of a specified work, or during a period of 24 months after the completion of that work in order to ensure the safety of railway property or the continued safe operation of the railway of Network Rail, such alterations and additions may be carried out by Network Rail and if Network Rail gives to the undertaker reasonable written notice of its intention to carry out such alterations or additions (which must be specified in the notice), the undertaker must pay to Network Rail the reasonable cost of those alterations or additions including, in respect of any such alterations and additions as are to be permanent, a capitalised sum representing the increase of the costs which may be expected to be reasonably incurred by Network Rail in maintaining, working and, when necessary, renewing any such alterations or additions.

• (2) If during the construction of a specified work or a protective work by the undertaker, Network Rail gives notice to the undertaker that Network Rail desires itself to construct that part of the specified work or the protective work which in the opinion of the engineer is endangering the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker decides that part of the specified work or the protective work is to be constructed, Network Rail must assume construction of that part of the specified work or the protective work and the undertaker must, regardless of any such approval of a specified work under paragraph 51(3), pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss which it may suffer by reason of the execution by Network Rail of that specified work or protective work.

• (3) The engineer must, in respect of the capitalised sums referred to in this paragraph and paragraph 56(a) provide such details of the formula by which those sums have been calculated as the undertaker may reasonably require.

• (4) If the cost of maintaining, working or renewing railway property is reduced in consequence of any such alterations or additions a capitalised sum representing such saving must be set off against any sum payable by the undertaker to Network Rail under this paragraph.

56

The undertaker must repay to Network Rail all reasonable fees, costs, charges and expenses reasonably incurred by Network Rail—

• (a) in constructing any part of a specified work on behalf of the undertaker as provided by paragraph 51(3) or in constructing any protective works under the provisions of paragraph 51(4) including, in respect of any permanent protective works, a capitalised sum representing the cost of maintaining and renewing those works;

• (b) in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction of a specified work or a protective work;

• (c) in respect of the employment or procurement of the services of any inspectors, signalmen, watchmen and other persons whom it shall be reasonably necessary to appoint for inspecting, signalling, watching and lighting railway property and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of a specified work or a protective work;

• (d) in respect of any special traffic working resulting from any speed restrictions which may in the opinion of the engineer, require to be imposed by reason or in consequence of the construction or failure of a specified work or a protective work or from the substitution of diversion of services which may be reasonably necessary for the same reason; and

• (e) in respect of any additional temporary lighting of railway property in the vicinity of the specified works, being lighting made reasonably necessary by reason or in consequence of the construction or failure of a specified work or a protective work.

57

• (1) In this paragraph—

• “EMI” means, subject to sub-paragraph (2), electromagnetic interference with Network Rail apparatus generated by the operation of the authorised development where such interference is of a level which adversely affects the safe operation of Network Rail’s apparatus; and

• “Network Rail’s apparatus” means any lines, circuits, wires, apparatus or equipment (whether or not modified or installed as part of the authorised development) which are owned or used by Network Rail for the purpose of transmitting or receiving electrical energy or of radio, telegraphic, telephonic, electric, electronic or other like means of signalling or other communications.

• (2) This paragraph applies to EMI only to the extent that such EMI is not attributable to any change to Network Rail’s apparatus carried out after approval of plans under paragraph 51(1) for the relevant part of the authorised development giving rise to EMI (unless the undertaker has been given notice in writing before the approval of those plans of the intention to make such change).

• (3) Subject to sub-paragraph (5), the undertaker must in the design and construction of the authorised development take all measures necessary to prevent EMI and must establish with Network Rail (both parties acting reasonably) appropriate arrangements to verify their effectiveness.

• (4) In order to facilitate the undertaker’s compliance with sub-paragraph (3)—

• (a) the undertaker must consult with Network Rail as early as reasonably practicable to identify all Network Rail’s apparatus which may be at risk of EMI, and thereafter must continue to consult with Network Rail (both before and after formal submission of plans under paragraph 51(1)) in order to identify all potential causes of EMI and the measures required to eliminate them;

• (b) Network Rail must make available to the undertaker all information in the possession of Network Rail reasonably requested by the undertaker in respect of Network Rail’s apparatus identified pursuant to sub-paragraph (a); and

• (c) Network Rail must allow the undertaker reasonable facilities for the inspection of Network Rail’s apparatus identified pursuant to sub-paragraph (a).

• (5) In any case where it is established that EMI can only reasonably be prevented by modifications to Network Rail’s apparatus, Network Rail must not withhold its consent unreasonably to modifications of Network Rail’s apparatus, but the means of prevention and the method of their execution must be selected in the reasonable discretion of Network Rail and in relation to such modifications paragraph 51(1) has effect subject to this sub-paragraph.

• (6) If at any time prior to the commencement of regular revenue-earning operations on the authorised railway comprised in the authorised development and notwithstanding any measures adopted pursuant to sub-paragraph (3), the testing or commissioning of the authorised development causes EMI then the undertaker must immediately upon receipt of notification by Network Rail of such EMI either in writing or communicated orally (such oral communication to be confirmed in writing as soon as reasonably practicable after it has been issued) forthwith cease to use (or procure the cessation of use of) the undertaker’s apparatus causing such EMI until all measures necessary have been taken to remedy such EMI by way of modification to the source of such EMI or (in the circumstances, and subject to the consent, specified in sub-paragraph (5)) to Network Rail’s apparatus.

• (7) In the event of EMI having occurred—

• (a) the undertaker must afford reasonable facilities to Network Rail for access to the undertaker’s apparatus in the investigation of such EMI;

• (b) Network Rail must afford reasonable facilities to the undertaker for access to Network Rail’s apparatus in the investigation of such EMI; and

• (c) Network Rail must make available to the undertaker any additional material information in its possession reasonably requested by the undertaker in respect of Network Rail’s apparatus or such EMI.

• (8) Where Network Rail approves modifications to Network Rail’s apparatus pursuant to sub-paragraphs (5) or (6)—

• (a) Network Rail must allow the undertaker reasonable facilities for the inspection of the relevant part of Network Rail’s apparatus;

• (b) any modifications to Network Rail’s apparatus approved pursuant to those sub-paragraphs must be carried out and completed by the undertaker in accordance with paragraph 6.

• (9) To the extent that it would not otherwise do so, the indemnity in paragraph 61(1) applies to the costs and expenses reasonably incurred or losses suffered by Network Rail through the implementation of the provisions of this paragraph (including costs incurred in connection with the consideration of proposals, approval of plans, supervision and inspection of works and facilitating access to Network Rail’s apparatus) or in consequence of any EMI to which sub-paragraph (6) applies.

• (10) For the purpose of paragraph 56(a) any modifications to Network Rail’s apparatus under this paragraph shall be deemed to be protective works referred to in that paragraph.

58

If at any time after the completion of a specified work or a protective work, not being a work vested in Network Rail, Network Rail gives written notice to the undertaker informing it that the state of maintenance of any part of the specified work or a protective work appears to be such as adversely affects the operation of railway property, the undertaker must (to the extent it is reasonable to do so), on receipt of such written notice, take such steps as may be necessary to put that specified work or a protective work in such state of maintenance as not adversely to affect railway property.

59

The undertaker must not provide any illumination or illuminated sign or signal on or in connection with a specified work or a protective work in the vicinity of any railway belonging to Network Rail unless it has first consulted Network Rail and it must comply with Network Rail’s reasonable requirements for preventing confusion between such illumination or illuminated sign or signal and any railway signal or other light used for controlling, directing or securing the safety of traffic on the railway.

60

Any additional expenses which Network Rail may reasonably incur in altering, reconstructing or maintaining railway property under any powers existing at the making of this Order by reason of the existence of a specified work or a protective work must, provided that not less than 56 days’ previous notice of the commencement of such alteration, reconstruction or maintenance has been given to the undertaker, be repaid by the undertaker to Network Rail.

61

• (1) The undertaker must pay to Network Rail all reasonable costs, charges, damages and expenses not otherwise provided for in this Part of this Schedule which may be occasioned to or reasonably incurred by Network Rail—

• (a) by reason of the construction or maintenance of a specified work or a protective work or the failure thereof; or

• (b) by reason of any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged upon a specified work or a protective work,

and the undertaker must indemnify and keep indemnified Network Rail from and against all claims and demands arising out of or in connection with a specified work or a protective work or any such failure, act or omission: and the fact that any act or thing may have been done by Network Rail on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision shall not (if it was done without negligence on the part of Network Rail or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under the provisions of this sub-paragraph.

• (2) Network Rail must give the undertaker reasonable written notice (and in any event not less than 7 days) of any such claim or demand and no settlement or compromise of such a claim or demand shall be made without the prior written consent of the undertaker.

• (3) The sums payable by the undertaker under sub-paragraph (1) shall include a sum equivalent to the relevant costs to the extent such costs result from the actions or omissions of the undertaker.

• (4) Subject to the terms of any agreement between Network Rail and a train operator regarding the timing or method of payment of the relevant costs in respect of that train operator, Network Rail must promptly pay to each train operator the amount of any sums which Network Rail receives under sub-paragraph (3) which relates to the relevant costs of that train operator.

• (5) The obligation under sub-paragraph (3) to pay Network Rail the relevant costs is, in the event of default, enforceable directly by any train operator concerned to the extent that such sums would be payable to that operator pursuant to sub-paragraph (4).

• (6) In this paragraph—

• “the relevant costs” means the costs, direct losses and expenses (including loss of revenue) reasonably incurred by each train operator as a consequence of any restriction of the use of Network Rail’s railway network as a result of the construction, maintenance or failure of a specified work or a protective work or any such act or omission as mentioned in subparagraph (1); and

• “train operator” means any person who is authorised to act as the operator of a train by a licence under section 8 (licences) of the Railways Act 1993.

62

Network Rail must, on receipt of a request from the undertaker, from time to time provide the undertaker free of charge with written estimates of the costs, charges, expenses and other liabilities for which the undertaker is or will become liable under this Part of this Schedule (including the amount of the relevant costs mentioned in paragraph 61) and with such information as may reasonably enable the undertaker to assess the reasonableness of any such estimate or claim made or to be made pursuant to this Part of this Schedule (including any claim relating to those relevant costs).

63

In the assessment of any sums payable to Network Rail under this Part of this Schedule there must not be taken into account any increase in the sums claimed that is attributable to any action taken by or any agreement entered into by Network Rail if that action or agreement was not reasonably necessary and was taken or entered into with a view to obtaining the payment of those sums by the undertaker under this Part of this Schedule or increasing the sums so payable.

64

The undertaker and Network Rail may, subject in the case of Network Rail to compliance with the terms of its network licence, enter into, and carry into effect, agreements for the transfer to the undertaker of—

• (a) any railway property shown on the works plans or lands plans and described in the book of reference;

• (b) any lands, works or other property held in connection with any such railway property; and

• (c) any rights and obligations (whether or not statutory) of Network Rail relating to any railway property or any lands, works or other property referred to in this paragraph.

65

Nothing in this Order, or in any enactment incorporated with or applied by this Order, prejudices or affects the operation of Part I of the Railways Act 1993.

66

The undertaker must give written notice to Network Rail if any application is proposed to be made by the undertaker for the Secretary of State’s consent, under article 9 (benefit of Order) of this Order and any such notice must be given no later than 28 days before any such application is made and must describe or give (as appropriate)—

• (a) the nature of the application to be made;

• (b) the extent of the geographical area to which the application relates; and

• (c) the name and address of the person acting for the Secretary of State to whom the application is to be made.

67

The undertaker must no later than 28 days from the date that the plans and documents submitted to and certified by the Secretary of State in accordance with article 48 (certification of documents, etc.) are certified by the Secretary of State, provide a set of those plans and documents to Network Rail in an agreed electronic read only format.

PART 6 — FOR THE PROTECTION OF EXOLUM PIPELINE SYSTEM LTD

Application

68

For the protection of Exolum the following provisions, unless otherwise agreed in writing at any time between the undertaker and Exolum, have effect.

Interpretation

69

In this Part of this Schedule—

• “alternative apparatus” means alternative apparatus adequate to enable Exolum to fulfil its functions as a pipe-line operator in a manner no less efficient than previously;

• “apparatus” means the pipe-line and storage system owned or maintained by Exolum and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

• “Exolum” means Exolum Pipeline System Ltd (company number 09497223 whose registered office is 1st Floor 55 King William Street, London, England, EC4R 9AD) and any successor in title;

• “functions” includes powers and duties;

• “in” in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

• “pipe-line” means the whole or any part of a pipe-line belonging to or maintained by Exolum and includes any ancillary works and apparatus; all protective wrappings, valves, sleeves and slabs, cathodic protection units, together with ancillary cables and markers; and such legal interest and benefit of property rights and covenants as are vested in Exolum in respect of those items;

• “plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed;

• “specified work” means any work which will or may be situated on, over, under or within 15 metres measured in any direction of any apparatus, or (wherever situated) impose any load directly upon any apparatus or involve embankment works within 15 metres of any apparatus; and

• “working day” means any day other than a Saturday, Sunday or English bank or public holiday.

Acquisition of apparatus

70

Irrespective of any provision in this Order or anything shown on the land plans—

• (a) the undertaker must not acquire any apparatus or obstruct or render less convenient the access to any apparatus, otherwise than by agreement with Exolum; and

• (b) any right of Exolum to maintain, repair, renew, adjust, alter or inspect any apparatus must not be extinguished by the undertaker until any necessary alternative apparatus has been constructed and is in operation to the reasonable satisfaction of Exolum.

Removal of apparatus and rights for alternative apparatus

71

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that any apparatus is relocated or diverted, that apparatus must not be removed by the undertaker and any right of Exolum to maintain and use that apparatus in that land and to gain access to it must not be extinguished until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of Exolum.

• (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give Exolum not less than 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order Exolum reasonably needs to remove any apparatus) the undertaker must, subject to subparagraph (3), afford to Exolum the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, the undertaker must afford to and, if necessary, acquire for the benefit of Exolum the necessary facilities and rights (equivalent to those currently enjoyed by Exolum) for the construction, maintenance and use of the alternative apparatus and access to it.

• (4) Any alternative apparatus to be constructed in land of the undertaker under this part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Exolum and the undertaker or in default of agreement settled by arbitration in accordance with article 50 (arbitration).

• (5) Exolum must, after the alternative apparatus to be provided or constructed has been agreed or settled in accordance with article 50, and after the grant to Exolum of any such facilities and rights as are referred to in sub-paragraphs (2) and (3), proceed as soon as reasonably practicable using all reasonable endeavours to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Schedule.

• (6) Irrespective of sub-paragraph (5), if the undertaker gives notice in writing to Exolum that it desires itself to execute any work, or part of any work in connection with the construction, removal or decommissioning of apparatus in the land of the undertaker or the construction of alternative apparatus, that work, instead of being executed by Exolum, must be executed by the undertaker without unnecessary delay under the superintendence, if required, and to the reasonable satisfaction of Exolum.

• (7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 3000 millimetres of the apparatus without Exolum’s consent.

Facilities and rights for alternative apparatus

72

• (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to Exolum facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and Exolum or in default of agreement settled by arbitration in accordance with article 50 (arbitration).

• (2) In settling those terms and conditions in respect of alternative apparatus the arbitrator must—

• (a) give effect to all reasonable requirements of the undertaker for ensuring the safety and efficient operation of the authorised development and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of the undertaker or the traffic on the highway; and

• (b) so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus for which the alternative apparatus is to be substituted.

• (3) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Exolum than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Exolum as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus: protection

73

• (1) Unless a shorter period is otherwise agreed in writing between the undertaker and Exolum, not less than 28 days before commencing any specified work in relation to apparatus the removal of which has not been required by the undertaker under sub-paragraph 72(2), the undertaker must submit to Exolum a plan of the works to be executed.

• (2) The specified work must be executed only in accordance with the plan submitted under subparagraph (1) and approved by Exolum in accordance with sub-paragraph (4) by Exolum for the alteration or otherwise for the protection of the apparatus, or for securing access to it; and Exolum is entitled to watch and inspect the execution of the specified work.

• (3) Any requirements made by Exolum under sub-paragraph (2) must be made within a period of 14 days (unless a shorter period is otherwise agreed in writing between the undertaker and Exolum) beginning with the date on which a plan under sub-paragraph (1) is submitted to it.

• (4) If Exolum in accordance with sub-paragraph (2) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, this Part of this Schedule applies as if the removal of the apparatus had been required by the undertaker under sub-paragraph 89(2).

• (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time but (unless otherwise agreed in writing between the undertaker and Exolum) in no case less than 28 days before commencing any specified work, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

• (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to Exolum notice of the works it intends to carry out to remedy the emergency together with a plan as soon as is reasonably practicable and must comply with subparagraph (2) in so far as is reasonably practicable in the circumstances.

• (7) In relation to any specified work, the plan to be submitted to Exolum under sub-paragraph (1) must include a material statement describing—

• (a) the exact position of the work;

• (b) the level at which the work is to be constructed or renewed;

• (c) the manner of its construction or renewal;

• (d) the position of any apparatus; and

• (e) by way of detailed drawings, every alteration proposed to be made to the apparatus.

Cathodic protection testing

74

Where in the reasonable opinion of the undertaker—

• (a) the authorised development might interfere with the existing cathodic protection forming part of a pipe-line; or

• (b) a pipe-line might interfere with the proposed or existing cathodic protection forming part of the authorised development,

Expenses

75

• (1) Subject to the following provisions of this paragraph, the undertaker must pay to Exolum the reasonable costs and expenses incurred by Exolum in, or in connection with—

• (a) the inspection, removal, alteration or protection of any apparatus; or

• (b) the construction of any new apparatus; or

• (c) the watching and inspecting the execution of any specified work; or

• (d) imposing reasonable requirements for the protection or alteration of apparatus,

which may reasonably be required in consequence of the execution of any such works as are required under this Schedule.

• (2) The scrap value of any apparatus removed under the provisions of this Part of Schedule is to be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.

• (3) If in accordance with the provisions of this Part of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions (except where this has been solely due to using the nearest currently available type); or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 50 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Exolum by virtue of sub-paragraph (1) is reduced by the amount of that excess.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

• (5) An amount which apart from this sub-paragraph would be payable to Exolum in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on Exolum any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

Damage to property and other losses

76

• (1) Subject to the following provisions of this paragraph, the undertaker must—

• (a) pay Exolum for all loss, damage, liability, costs and expenses reasonably suffered or incurred by Exolum for which Exolum is legally liable as a result of legally sustainable claims brought against Exolum by any third party solely arising out of the carrying out of any relevant works and any protective building works;

• (b) pay the cost reasonably incurred by Exolum in making good any damage to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal or abandonment) arising from or caused by the carrying out of any relevant works or protective building work; (2) The fact that any act or thing may have been done by Exolum on behalf of the undertaker or in accordance with a plan approved by Exolum or in accordance with any requirement of Exolum or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1);

• (c) pay the cost reasonably incurred by Exolum in stopping, suspending and restoring the supply through its pipeline and make reasonable compensation to Exolum for any other expenses, losses, damages, penalty or costs incurred by Exolum by reason or in consequence of any such damage or interruption provided that the same arises in consequence of the carrying out of any relevant works and any protective building works.

• (2) Irrespective of anything to the contrary elsewhere in this Part of this Schedule—

• (a) the undertaker and Exolum must at all times take reasonable steps to prevent and mitigate any loss, damage, liability, claim, cost or expense (whether indemnified or not) which either suffers as a result of the other’s negligence or breach of this Part of this Schedule; and

• (b) neither the undertaker nor Exolum are liable for any loss, damage, liability, claim, cost or expense suffered or incurred by the other to the extent that the same are incurred as a result of or in connection with the sole, partial or complete breach of this Part of this Schedule or negligence arising out of an act, omission, default or works of the other, its officers, servants, contractors or agents.

• (3) Exolum must give to the undertaker reasonable notice of any claim or demand to which this paragraph 76 applies. The undertaker may at its own expense conduct all negotiations for the settlement of the same and any litigation that may arise therefrom. Exolum must not compromise or settle any such claim or make any admission which might be prejudicial to the claim. Exolum must, at the request of the undertaker, afford all reasonable assistance for the purpose of contesting any such claim or action, and is entitled to be repaid all reasonable expenses incurred in so doing.

• (4) In this paragraph—

• “protective building works” means the exercise by the undertaker of the powers conferred by article 22 (protective works to buildings); and

• “relevant works” means such of the authorised development as—does, will or is likely to affect any apparatus; orinvolves a physical connection or attachment to any apparatus.

Co-operation and reasonableness

77

• (1) Where in consequence of the proposed construction of any of the authorised development, the undertaker requires the removal of apparatus under this Part of this Schedule or Exolum makes requirements for the protection or alteration of apparatus under this Part of this Schedule, the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of Exolum’s undertaking and Exolum must use its best endeavours to co-operate with the undertaker for that purpose.

• (2) The undertaker and Exolum must act reasonably in respect of any given term of this Part of this Schedule and, in particular, (without prejudice to generality) where any consent or expression of satisfaction is required by this Part of this Schedule it must not be unreasonably withheld or delayed.

Miscellaneous

78

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Exolum in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made provided that the terms of the relevant enactment or agreement are not inconsistent with the provisions of this Order, including this Part of this Schedule. In the case of any inconsistency, the provisions of this Order, including this Part of this Schedule, prevail.

Emergency Circumstances

79

• (1) The Promoter acknowledges that Exolum provides services to Her Majesty’s Government, using its apparatus, which may affect any works to be carried under this Order.

• (2) In the following circumstances, Exolum may on written notice to the Promoter immediately suspend all works that necessitate the stopping or suspending of the supply of product through any apparatus under this Order and Exolum shall not be in breach of its obligations to proceed—

• (a) circumstances in which, in the determination of the Secretary of State, there subsists a material threat to national security, or a threat or state of hostility or war or other crisis or national emergency (whether or not involving hostility or war); or

• (b) circumstances in which a request has been received, and a decision to act upon such request has been taken, by Her Majesty’s Government for assistance in relation to the occurrence or anticipated occurrent of a major accident, crisis or natural disaster; or

• (c) circumstances in which a request has been received from or on behalf of NATO, the EU, the UN, the International Energy Agency (or any successor agency thereof) or the government of any other state for support or assistance pursuant to the United Kingdom’s international obligations and a decision to act upon such request has been taken by Her Majesty’s Government or the Secretary of State; or

• (d) any circumstances identified as such by the COBRA committee of Her Majesty’s Government (or any successor committee thereof); or

• (e) any situation, including where the United Kingdom is engaged in any planned or unplanned military operations within the United Kingdom or overseas, in connection with which the Secretary of State requires fuel capacity.

• (3) The parties agree to act in good faith and in all reasonableness to agree any revisions to any schedule, programme or costs estimate (which shall include costs of demobilising and remobilising any workforce, and any costs to protect Exolum’s apparatus “mid-works”) to account for the suspension.

• (4) Exolum shall not be liable for any costs, expenses, losses or liabilities the Promoter incurs as a result of the suspension of any activities under this paragraph or delays caused by it.

PART 7 — FOR THE PROTECTION OF ANGLIAN WATER SERVICES LIMITED

Application

80

For the protection of Anglian Water the following provisions have effect, unless otherwise agreed in writing between the undertaker and Anglian Water.

Interpretation

81

In this Part of this Schedule—

• “alternative apparatus” means alternative apparatus adequate to enable Anglian Water to fulfil its statutory functions in a manner no less efficient than previously;

• “Anglian Water” means Anglian Water Services Limited (company number 02366656 whose registered address is Lancaster House Lancaster Way, Ermine Business Park, Huntingdon, Cambridgeshire, United Kingdom, PE29 6XU;

• “apparatus” means:works, mains, pipes or other apparatus belonging to or maintained by Anglian Water for the purposes of water supply and sewerage;any drain or works vested in Anglian Water under the Water Industry Act 1991¹³⁰;any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4)¹³¹ of that Act or an agreement to adopt made under section 104¹³² of that Act, andincludes a sludge main, disposal main or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus

and for the purpose of this definition, where words are defined by section 219 of the Water Industry Act 1991 they shall be taken to have the same meaning;

• “functions” includes powers and duties;

• “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

• “plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed;

On street apparatus

82

This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and Anglian Water are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus in stopped up streets

83

• (1) Where any street is stopped up under article 18 (permanent stopping up and restriction of use of streets and private means of access), where Anglian Water has apparatus in the street or accessed by virtue of that street, it has the same powers and rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to Anglian Water legal easements reasonably satisfactory to Anglian Water in respect of such apparatus and access to it, but nothing in this paragraph affects any right of the undertaker or of Anglian Water to require the removal of that apparatus under paragraph 86 or the power of the undertaker to carry out works under paragraph 88.

• (2) Regardless of the temporary stopping up or diversion of any highway under the powers conferred by article 17 (temporary alteration, diversion, prohibition and restriction of the use of streets), Anglian Water is at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.

Protective works to buildings

84

The undertaker, in the case of the powers conferred by article 22 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus.

Acquisition of land

85

Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Removal of apparatus

86

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that Anglian Water’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of Anglian Water to maintain that apparatus in that land must not (without the prior written consent of Anglian Water) be extinguished, until—

• (a) alternative apparatus has been constructed and is in operation to the reasonable satisfaction of Anglian Water in accordance with sub-paragraphs (2) to (8); and

• (b) facilities and rights have been secured for that alternative apparatus in accordance with paragraph 87.

• (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to Anglian Water 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Anglian Water the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed Anglian Water must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

• (4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Anglian Water and the undertaker or in default of agreement settled by arbitration in accordance with article 50 (arbitration).

• (5) Anglian Water must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 50, and after the grant to Anglian Water of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

• (6) Regardless of anything in sub-paragraph (5), if Anglian Water gives notice in writing to the undertaker that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker or to the extent that Anglian Water fails to proceed with that work in accordance with sub-paragraph (5) or the undertaker and Anglian Water otherwise agree, that work, instead of being executed by Anglian Water, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of Anglian Water.

• (7) Notice under sub-paragraph (6) that Anglian Water desires the undertaker to execute any work, or part of any work, must be given within 14 days of agreement under sub-paragraph (4) or, in default of agreement, within 14 days of the date of settlement by arbitration under sub-paragraph (4).

• (8) If Anglian Water fails either reasonably to approve, or to provide reasons for its failure to approve along with an indication of what would be required to make acceptable, any proposed details relating to required removal works under sub-paragraph (2) within 28 days of receiving a notice of the required works from the undertaker, then such details are deemed to have been approved. For the avoidance of doubt, any such “deemed consent” does not extend to the actual undertaking of the removal works, which shall remain the sole responsibility of Anglian Water or its contractors.

• (9) Whenever alternative apparatus is to be or is being substituted for existing apparatus, the undertaker shall, before taking or requiring any further step in such substitution works, use best endeavours to comply with Anglian Water’s reasonable requests for a reasonable period of time to enable Anglian Water to—

• (a) make network contingency arrangements; or

• (b) bring such matters as it may consider reasonably necessary to the attention of end users of the utility in question.

Facilities and rights for alternative apparatus

87