The Springwell Solar Farm Order 2026

• (4) Any refusal under this paragraph must be accompanied by a statement of the reasons for refusal.

20

Without limiting the scope of paragraph 3, the requirements which the drainage authority may make under that paragraph include conditions requiring the undertaker at its own expense to construct such protective works, whether temporary or permanent, during the construction of the specified work (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary taking account of the terms of this Order—

• (a) to safeguard any drainage work against damage by reason of any specified work; or

• (b) to secure that the efficiency of any drainage work for flood defence and land drainage purposes is not impaired, and that the risk of flooding is not otherwise increased beyond the level of flood risk that was assessed in the environmental statement, by reason of any specified work.

21

• (1) Subject to sub-paragraph (2), any specified work, and all protective works required by the drainage authority under paragraph 4, must be constructed—

• (a) without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under this Part of this Schedule; and

• (b) to the reasonable satisfaction of the drainage authority,

and an officer of the drainage authority is entitled to watch and inspect the construction of such works.

• (2) The undertaker must give to the drainage authority—

• (a) not less than 14 days’ notice in writing of its intention to commence construction of any specified work; and

• (b) notice in writing of its completion not later than seven days after the date on which it is brought into use.

22

If by reason of the construction of a specified work or of the failure of any a specified work the efficiency of any drainage work for flood defence purposes or land drainage is impaired, or that drainage work is otherwise damaged, the impairment or damage must be made good by the undertaker as soon as reasonably practicable to the reasonable satisfaction of the drainage authority and, if the undertaker fails to do so, the drainage authority may make good the impairment or damage and recover from the undertaker the expense reasonably incurred by it in doing so.

23

The undertaker must make reasonable compensation for costs, charges and expenses which the drainage authority may reasonably incur—

• (a) in the examination or approval of plans under this Part of this Schedule;

• (b) in inspecting the construction of the specified work or any protective works required by the drainage authority under this Part of this Schedule; and

• (c) in carrying out any surveys or tests by the drainage authority which are reasonably required in connection with the construction of the specified work.

24

• (1) The undertaker must make reasonable compensation for liabilities, costs and losses which may be reasonably incurred or suffered by reason of—

• (a) the construction of any specified works comprised within the authorised development; or

• (b) any act or omission of the undertaker, its employees, contractors or agents or others while engaged upon the construction of the authorised development.

• (2) The drainage authority must give to the undertaker reasonable notice of any such claim or demand.

• (3) The undertaker may at its own expense conduct all negotiations for the settlement of the same and any litigation that may arise therefrom.

• (4) The drainage authority must not compromise or settle any such claim or make any admission which might be prejudicial to the claim without the agreement of the undertaker which agreement must not be unreasonably withheld or delayed.

• (5) The drainage authority will, having regard to its statutory functions, at all times take reasonable steps to prevent and mitigate any such claims, demands, proceedings, costs, damages, expenses or loss.

• (6) The drainage authority will, at the request of the undertaker and having regard to its statutory functions, afford all reasonable assistance for the purpose of contesting any such claim or action, and is entitled to be repaid its reasonable expenses reasonably incurred in so doing.

• (7) The fact that any work or thing has been executed or done by the undertaker in accordance with a plan approved or deemed to be approved by the drainage authority, or to its satisfaction, or in accordance with any directions or award of an arbitrator, does not relieve the undertaker from any liability under this Part of this Schedule.

• (8) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage to the extent that it is attributable to the act, neglect or default of the drainage authority or the breach of a statutory duty of the drainage authority, its officers, servants, contractors or agents.

25

Any dispute arising between the undertaker and the drainage authority under this Part of this Schedule, if the parties agree, is to be determined by arbitration under article 42 (arbitration).

PART 4 — FOR THE PROTECTION OF LINCOLNSHIRE FIRE AND RESCUE SERVICE

Interpretation

26

• (1) For the protection of Lincolnshire Fire and Rescue Service as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and Lincolnshire Fire and Rescue Service.

• (2) In this Part of this Schedule—

• “Index Linked” means an increase in the sums payable on an annual basis or pro rata per diem in accordance with the most recent published figure for the Consumer Price Index, or during any period when no such index exists the index which replaces it or is the nearest equivalent to it; and

• “Lincolnshire Fire and Rescue Service” means Lincolnshire County Council in its capacity as a fire and rescue authority pursuant to section 1(2)(a) of the Fire and Rescue Services Act 2004.

Site visits

27

• (1) The undertaker must, prior to the date of final commissioning of Work No. 4, use reasonable endeavours to facilitate a site familiarisation exercise in connection with Work No. 4 of the authorised development for Lincolnshire Fire and Rescue Service for the purposes of providing the necessary assurance to Lincolnshire Fire and Rescue Service that all the required systems and measures are in place in accordance with the battery safety management plan.

• (2) Following the first anniversary of the date of final commissioning of Work No. 4 of the authorised development, the undertaker must use reasonable endeavours to facilitate an annual review of Work No. 4 by Lincolnshire Fire and Rescue Service at the reasonable request of Lincolnshire Fire and Rescue Service, up until the year in which the undertaker commences decommissioning of Work No. 4.

Costs

28

• (1) Pursuant to the provisions set out at paragraph 27, the undertaker must pay to Lincolnshire Fire and Rescue Service—

• (a) £16,665 in the first year of operation of the authorised development for, or in connection with Lincolnshire Fire and Rescue Service’s attendance at the site familiarisation exercise facilitated by the undertaker pursuant to paragraph 27(1), such sum to be paid within 30 days following the date of the site familiarisation exercise; and

• (b) £1,530 in each subsequent year of operation of the authorised development until the date of decommissioning of Work No. 4, such sums to be paid within 30 days of the date of the annual review for that year, if in that year an annual review has taken place pursuant to paragraph 27(2).

• (2) The costs payable under this sub-paragraph (1)(b) are to be Index Linked.

Arbitration

29

Any difference or dispute arising between the undertaker and Lincolnshire Fire and Rescue Service under this Part of this Schedule must be determined by arbitration in accordance with article 42 (arbitration).

PART 5 — FOR THE PROTECTION OF RAILWAY INTERESTS

30

The provisions of this Part of this Schedule have effect, unless otherwise agreed in writing between the undertaker and Network Rail and, in the case of paragraph 44 of this Part of this Schedule any other person on whom rights or obligations are conferred by that paragraph.

31

In this Part of this Schedule—

• “asset protection agreement” means an agreement to regulate the construction and maintenance of the specified work in a form prescribed from time to time by Network Rail;

• “construction” includes execution, placing, alteration and reconstruction and “construct” and “constructed” have corresponding meanings;

• “the engineer” means an engineer appointed by Network Rail for the purposes of this Order;

• “network licence” means the network licence, as the same is amended from time to time, granted to Network Rail Infrastructure Limited by the Secretary of State in exercise of their powers under section 8 (licences) of the Railways Act 1993;

• “Network Rail” means Network Rail Infrastructure Limited (company number 02904587, whose registered office is at Waterloo General Office, London SE1 8SW) and any associated company of Network Rail Infrastructure Limited which holds property for railway purposes, and for the purpose of this definition “associated company” means any company which is (within the meaning of section 1159 of the Companies Act 2006) the holding company of Network Rail Infrastructure Limited, a subsidiary of Network Rail Infrastructure Limited or another subsidiary of the holding company of Network Rail Infrastructure Limited and any successor to Network Rail Infrastructure Limited’s railway undertaking;

• “plans” includes sections, designs, design data, software, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of railway property;

• “railway operational procedures” means procedures specified under any access agreement (as defined in the Railways Act 1993) or station lease;

• “railway property” means any railway belonging to Network Rail, and— any station, land, works, apparatus and equipment belonging to Network Rail or connected with any such railway; and any easement or other property interest held or used by Network Rail or a tenant or licencee of Network Rail for the purposes of such railway or works, apparatus or equipment;

• “regulatory consents” means any consent or approval required under— the Railways Act 1993; the network licence; and/or any other relevant statutory or regulatory provisions; by either the Office of Rail and Road or the Secretary of State for Transport or any other competent body including change procedures and any other consents, approvals of any access or beneficiary that may be required in relation to the authorised development;

• “specified work” means so much of any of the authorised development as is situated upon, across, under, over or within 15 metres of, or may in any way adversely affect, railway property and, for the avoidance of doubt, includes the maintenance of such works under the powers conferred by article 5 (power to maintain authorised development) in respect of such works.

32

• (1) Where under this Part of this Schedule Network Rail is required to give its consent or approval in respect of any matter, that consent or approval is subject to the condition that Network Rail complies with any relevant railway operational procedures and any obligations under its network licence or under statute.

• (2) In so far as any specified work or the acquisition or use of railway property is or may be subject to railway operational procedures, Network Rail must—

• (a) co-operate with the undertaker with a view to avoiding undue delay and securing conformity as between any plans approved by the engineer and requirements emanating from those procedures; and

• (b) use their reasonable endeavours to avoid any conflict arising between the application of those procedures and the proper implementation of the authorised development pursuant to this Order.

33

• (1) The undertaker must not exercise the powers conferred by—

• (a) article 3 (development consent etc. granted by the Order);

• (b) article 5 (power to maintain authorised development);

• (c) article 13 (temporary prohibition or restriction on use of streets and public rights of way);

• (d) article 18 (discharge of water);

• (e) article 20 (authority to survey and investigate the land);

• (f) article 21 (compulsory acquisition of land);

• (g) article 23 (compulsory acquisition of rights);

• (h) article 26 (acquisition of subsoil only);

• (i) article 27 (power to override easements and other rights);

• (j) article 30 (temporary use of land for constructing the authorised development);

• (k) article 31 (temporary use of land for maintaining the authorised development);

• (l) article 32 (statutory undertakers);

• (m) article 39 (felling or lopping of trees and removal of hedgerows);

• (n) article 40 (trees subject to tree preservation orders);

• (o) the powers conferred by section 11(3) (power of entry) of the 1965 Act;

• (p) the powers conferred by section 203 (power to override easements and rights) of the Housing and Planning Act 2016;

• (q) the powers conferred by section 172 (right to enter and survey land) of the Housing and Planning Act 2016;

• (r) any powers under in respect of the temporary possession of land under the Neighbourhood Planning Act 2017;

in respect of any railway property unless the exercise of such powers is with the consent of Network Rail.

• (2) The undertaker must not in the exercise of the powers conferred by this Order prevent pedestrian or vehicular access to any railway property, unless preventing such access is with the consent of Network Rail.

• (3) The undertaker must not exercise the powers conferred by sections 271 or 272 of the 1990 Act, article 32, article 27 or article 24 (private rights), in relation to any right of access of Network Rail to railway property, but such right of access may be diverted with the consent of Network Rail.

• (4) The undertaker must not under the powers of this Order acquire or use or acquire new rights over, or seek to impose any restrictive covenants over, any railway property, or extinguish any existing rights of Network Rail in respect of any third party property, except with the consent of Network Rail.

• (5) The undertaker must not under the powers of this Order do anything which would result in railway property being incapable of being used or maintained or which would affect the safe running of trains on the railway.

• (6) Where Network Rail is asked to give its consent pursuant to this paragraph, such consent must not be unreasonably withheld but may be given subject to reasonable conditions but it shall never be unreasonable to withhold consent for reasons of operational or railway safety (such matters to be in Network Rail’s absolute discretion).

• (7) The undertaker must enter into an asset protection agreement prior to the carrying out of any specified work.

34

• (1) The undertaker must before commencing construction of any specified work supply to Network Rail proper and sufficient plans of that work for the reasonable approval of the engineer and the specified work must not be commenced except in accordance with such plans as have been approved in writing by the engineer or settled by arbitration.

• (2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld, and if by the end of the period of 28 days beginning with the date on which such plans have been supplied to Network Rail the engineer has not intimated their disapproval of those plans and the grounds of such disapproval the undertaker may serve upon the engineer written notice requiring the engineer to intimate approval or disapproval within a further period of 28 days beginning with the date upon which the engineer receives written notice from the undertaker. If by the expiry of the further 28 days the engineer has not intimated approval or disapproval, the engineer shall be deemed to have approved the plans as submitted.

• (3) If by the end of the period of 28 days beginning with the date on which written notice was served upon the engineer under sub-paragraph (2), Network Rail gives notice to the undertaker that Network Rail desires itself to construct any part of a specified work which in the opinion of the engineer will or may affect the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker desires such part of the specified work to be constructed, Network Rail must construct it without unnecessary delay on behalf of and to the reasonable satisfaction of the undertaker in accordance with the plans approved or deemed to be approved or settled under this paragraph, and under the supervision (where appropriate and if given) of the undertaker.

• (4) When signifying their approval of the plans the engineer may specify any protective works (whether temporary or permanent) which in the engineer’s opinion should be carried out before the commencement of the construction of a specified work to ensure the safety or stability of railway property or the continuation of safe and efficient operation of the railways of Network Rail or the services of operators using the same (including any relocation decommissioning and removal of works, apparatus and equipment necessitated by a specified work and the comfort and safety of passengers who may be affected by the specified works), and such protective works as may be reasonably necessary for those purposes must be constructed by Network Rail or by the undertaker, if Network Rail so desires, and such protective works must be carried out at the expense of the undertaker in either case without unnecessary delay and the undertaker must not commence the construction of the specified works until the engineer has notified the undertaker that the protective works have been completed to their reasonable satisfaction.

35

• (1) Any specified work and any protective works to be constructed by virtue of paragraph 34(4) must, when commenced, be constructed—

• (a) without unnecessary delay in accordance with the plans approved or deemed to have been approved or settled under paragraph 34;

• (b) under the supervision (where appropriate and if given) and to the reasonable satisfaction of the engineer;

• (c) in such manner as to cause as little damage as is possible to railway property; and

• (d) so far as is reasonably practicable, so as not to interfere with or obstruct the free, uninterrupted and safe use of any railway of Network Rail or the traffic thereon and the use by passengers of railway property.

• (2) If any damage to railway property or any such interference or obstruction shall be caused by the carrying out of, or in consequence of the construction of a specified work, the undertaker must, notwithstanding any such approval, make good such damage and must pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss which it may sustain by reason of any such damage, interference or obstruction.

• (3) Nothing in this Part of this Schedule imposes any liability on the undertaker with respect to any damage, costs, expenses or loss attributable to the negligence of Network Rail or its servants, contractors or agents or any liability on Network Rail with respect of any damage, costs, expenses or loss attributable to the negligence of the undertaker or its servants, contractors or agents.

36

The undertaker must—

• (a) at all times afford reasonable facilities to the engineer for access to a specified work during its construction; and

• (b) supply the engineer with all such information as they may reasonably require with regard to a specified work or the method of constructing it.

37

Network Rail must at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by Network Rail under this Part of this Schedule during their construction and must supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them.

38

• (1) If any permanent or temporary alterations or additions to railway property are reasonably necessary in consequence of the construction or completion of a specified work in order to ensure the safety of railway property or the continued safe operation of the railway of Network Rail, such alterations and additions may be carried out by Network Rail and if Network Rail gives to the undertaker 56 days’ notice (or in the event of an emergency or safety critical issue such notice as is reasonable in the circumstances) of its intention to carry out such alterations or additions (which must be specified in the notice), the undertaker must pay to Network Rail the reasonable cost of those alterations or additions including, in respect of any such alterations and additions as are to be permanent, a capitalised sum representing the increase of the costs which may be expected to be reasonably incurred by Network Rail in maintaining, working and, when necessary, renewing any such alterations or additions.

• (2) If during the construction of a specified work by the undertaker, Network Rail gives notice to the undertaker that Network Rail desires itself to construct that part of the specified work which in the opinion of the engineer is endangering the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker decides that part of the specified work is to be constructed, Network Rail must assume construction of that part of the specified work and the undertaker must, notwithstanding any such approval of a specified work under paragraph 34(3), pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss which it may suffer by reason of the execution by Network Rail of that specified work.

• (3) The engineer must, in respect of the capitalised sums referred to in this paragraph and paragraph 39(a) provide such details of the formula by which those sums have been calculated as the undertaker may reasonably require.

• (4) If the cost of maintaining, working or renewing railway property is reduced in consequence of any such alterations or additions a capitalised sum representing such saving must be set off against any sum payable by the undertaker to Network Rail under this paragraph.

39

The undertaker must repay to Network Rail all reasonable fees, costs, charges and expenses reasonably incurred by Network Rail—

• (a) in constructing any part of a specified work on behalf of the undertaker as provided by paragraph 34(3) or in constructing any protective works under the provisions of paragraph 34(4) including, in respect of any permanent protective works, a capitalised sum representing the cost of maintaining and renewing those works;

• (b) in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction of a specified work;

• (c) in respect of the employment or procurement of the services of any inspectors, signallers, watch-persons and other persons whom it shall be reasonably necessary to appoint for inspecting, signalling, watching and lighting railway property and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of a specified work;

• (d) in respect of any special traffic working resulting from any speed restrictions which may in the opinion of the engineer, require to be imposed by reason or in consequence of the construction or failure of a specified work or from the substitution or diversion of services which may be reasonably necessary for the same reason; and

• (e) in respect of any additional temporary lighting of railway property in the vicinity of the specified works, being lighting made reasonably necessary by reason or in consequence of the construction or failure of a specified work.

40

• (1) In this paragraph—

• “EMI” means, subject to sub-paragraph (2), electromagnetic interference with Network Rail apparatus generated by the operation of the authorised development where such interference is of a level which adversely affects the safe operation of Network Rail’s apparatus; and

• “Network Rail’s apparatus” means any lines, circuits, wires, apparatus or equipment (whether or not modified or installed as part of the authorised development) which are owned or used by Network Rail for the purpose of transmitting or receiving electrical energy or of radio, telegraphic, telephonic, electric, electronic or other like means of signalling or other communications.

• (2) This paragraph applies to EMI only to the extent that such EMI is not attributable to any change to Network Rail’s apparatus carried out after approval of plans under paragraph 34(1) for the relevant part of the authorised development giving rise to EMI (unless the undertaker has been given notice in writing before the approval of those plans of the intention to make such change).

• (3) Subject to sub-paragraph (5), the undertaker must in the design and construction of the authorised development take all measures necessary to prevent EMI and must establish with Network Rail (both parties acting reasonably) appropriate arrangements to verify their effectiveness.

• (4) In order to facilitate the undertaker’s compliance with sub-paragraph (3)—

• (a) the undertaker must consult with Network Rail as early as reasonably practicable to identify all Network Rail’s apparatus which may be at risk of EMI, and thereafter must continue to consult with Network Rail (both before and after formal submission of plans under paragraph 34(1)) in order to identify all potential causes of EMI and the measures required to eliminate them;

• (b) Network Rail must make available to the undertaker all information in the possession of Network Rail reasonably requested by the undertaker in respect of Network Rail’s apparatus identified pursuant to sub-paragraph (a); and

• (c) Network Rail must allow the undertaker reasonable facilities for the inspection of Network Rail’s apparatus identified pursuant to sub-paragraph (a).

• (5) In any case where it is established that EMI can only reasonably be prevented by modifications to Network Rail’s apparatus, Network Rail must not withhold its consent unreasonably to modifications of Network Rail’s apparatus, but the means of prevention and the method of their execution must be selected in the reasonable discretion of Network Rail, and in relation to such modifications paragraph 34(1) has effect subject to the sub-paragraph.

• (6) Prior to the commencement of operation of the authorised development the undertaker shall test the use of the authorised development in a manner that shall first have been agreed with Network Rail and if, notwithstanding any measures adopted pursuant to sub-paragraph (3), the testing of the authorised development causes EMI then the undertaker must immediately upon receipt of notification by Network Rail of such EMI either in writing or communicated orally (such oral communication to be confirmed in writing as soon as reasonably practicable after it has been issued) forthwith cease to use (or procure the cessation of use of) the undertaker’s apparatus causing such EMI until all measures necessary have been taken to remedy such EMI by way of modification to the source of such EMI or (in the circumstances, and subject to the consent, specified in sub-paragraph (5)) to Network Rail’s apparatus.

• (7) In the event of EMI having occurred—

• (a) the undertaker must afford reasonable facilities to Network Rail for access to the undertaker’s apparatus in the investigation of such EMI;

• (b) Network Rail must afford reasonable facilities to the undertaker for access to Network Rail’s apparatus in the investigation of such EMI;

• (c) Network Rail must make available to the undertaker any additional material information in its possession reasonably requested by the undertaker in respect of Network Rail’s apparatus or such EMI; and

• (d) the undertaker shall not allow the use or operation of the authorised development in a manner that has caused or will cause EMI until measures have been taken in accordance with this paragraph to prevent EMI occurring.

• (8) Where Network Rail approves modifications to Network Rail’s apparatus pursuant to sub-paragraphs (5) or (6)—

• (a) Network Rail must allow the undertaker reasonable facilities for the inspection of the relevant part of Network Rail’s apparatus;

• (b) any modifications to Network Rail’s apparatus approved pursuant to those sub-paragraphs must be carried out and completed by the undertaker in accordance with paragraph 35.

• (9) To the extent that it would not otherwise do so, the indemnity in paragraph 44(1) applies to the costs and expenses reasonably incurred or losses suffered by Network Rail through the implementation of the provisions of this paragraph (including costs incurred in connection with the consideration of proposals, approval of plans, supervision and inspection of works and facilitating access to Network Rail’s apparatus) or in consequence of any EMI to which sub-paragraph (6) applies.

• (10) For the purpose of paragraph 39(a) any modifications to Network Rail’s apparatus under this paragraph shall be deemed to be protective works referred to in that paragraph.

• (11) In relation to any dispute arising under this paragraph the reference in article 42 (arbitration) to the Institution of Civil Engineers shall be read as a reference to the Institution of Engineering and Technology.

41

If at any time after the completion of a specified work, not being a work vested in Network Rail, Network Rail gives notice to the undertaker informing it that the state of maintenance of any part of the specified work appears to be such as adversely affects the operation of railway property, the undertaker must, on receipt of such notice, take such steps as may be reasonably necessary to put that specified work in such state of maintenance as not adversely to affect railway property.

42

The undertaker must not provide any illumination or illuminated sign or signal on or in connection with a specified work in the vicinity of any railway belonging to Network Rail unless it has first consulted Network Rail and it must comply with Network Rail’s reasonable requirements for preventing confusion between such illumination or illuminated sign or signal and any railway signal or other light used for controlling, directing or securing the safety of traffic on the railway.

43

Any additional expenses which Network Rail may reasonably incur in altering, reconstructing or maintaining railway property under any powers existing at the making of this Order by reason of the existence of a specified work must, provided that 56 days’ previous notice of the commencement of such alteration, reconstruction or maintenance has been given to the undertaker, be repaid by the undertaker to Network Rail.

44

• (1) The undertaker must pay to Network Rail all reasonable costs, charges, damages and expenses not otherwise provided for in this Part of this Schedule (subject to article 49 (no double recovery)) which may be occasioned to or reasonably incurred by Network Rail—

• (a) by reason of the construction, maintenance or operation of a specified work or the failure thereof; or

• (b) by reason of any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged upon a specified work;

• (c) by reason of any act or omission of the undertaker or any person in its employ or of its contractors or others whilst accessing to or egressing from the authorised development;

• (d) in respect of any damage caused to or additional maintenance required to, railway property or any such interference or obstruction or delay to the operation of the railway as a result of access to or egress from the authorised development by the undertaker or any person in its employ or of its contractors or others;

• (e) in respect of costs incurred by Network Rail in complying with any railway operational procedures or obtaining any regulatory consents which procedures are required to be followed or consents obtained to facilitate the carrying out or operation of the authorised development;

and the undertaker must indemnify and keep indemnified Network Rail from and against all claims and demands arising out of or in connection with a specified work or any such failure, act or omission: and the fact that any act or thing may have been done by Network Rail on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision shall not (if it was done without negligence on the part of Network Rail or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under the provisions of this sub-paragraph.

• (2) Network Rail must—

• (a) give the undertaker reasonable written notice of any such claims or demands;

• (b) not make any settlement or compromise of such a claim or demand without the prior consent of the undertaker; and

• (c) take such steps as are within its control and are reasonable in the circumstances to mitigate any liabilities relating to such claims or demands.

• (3) The sums payable by the undertaker under sub-paragraph (1) shall if relevant include a sum equivalent to the relevant costs.

• (4) Subject to the terms of any agreement between Network Rail and a train operator regarding the timing or method of payment of the relevant costs in respect of that train operator, Network Rail must promptly pay to each train operator the amount of any sums which Network Rail receives under sub-paragraph (3) which relates to the relevant costs of that train operator.

• (5) The obligation under sub-paragraph (3) to pay Network Rail the relevant costs shall, in the event of default, be enforceable directly by any train operator concerned to the extent that such sums would be payable to that operator pursuant to sub-paragraph (4).

• (6) In this paragraph—

• “the relevant costs” means the costs, losses and expenses (including loss of revenue) reasonably incurred by each train operator as a consequence of any specified work including but not limited to any restriction of the use of Network Rail’s railway network as a result of the construction, maintenance or failure of a specified work or any such act or omission as mentioned in sub-paragraph (1); and

• “train operator” means any person who is authorised to act as the operator of a train by a licence under section 8 of the Railways Act 1993.

45

Network Rail must, on receipt of a request from the undertaker, from time to time provide the undertaker free of charge with written estimates of the costs, charges, expenses and other liabilities for which the undertaker is or will become liable under this Part of this Schedule (including the amount of the relevant costs mentioned in paragraph 44) and with such information as may reasonably enable the undertaker to assess the reasonableness of any such estimate or claim made or to be made pursuant to this Part of this Schedule (including any claim relating to those relevant costs).

46

In the assessment of any sums payable to Network Rail under this Part of this Schedule there must not be taken into account any increase in the sums claimed that is attributable to any action taken by or any agreement entered into by Network Rail if that action or agreement was not reasonably necessary and was taken or entered into with a view to obtaining the payment of those sums by the undertaker under this Part of this Schedule or increasing the sums so payable.

47

The undertaker and Network Rail may, subject in the case of Network Rail to compliance with the terms of its network licence, enter into, and carry into effect, agreements for the transfer to the undertaker of—

• (a) any railway property shown on the works and land plans and described in the book of reference;

• (b) any lands, works or other property held in connection with any such railway property; and

• (c) any rights and obligations (whether or not statutory) of Network Rail relating to any railway property or any lands, works or other property referred to in this paragraph.

48

Nothing in this Order, or in any enactment incorporated with or applied by this Order, prejudices or affects the operation of Part I of the Railways Act 1993.

49

The undertaker must give written notice to Network Rail if any application is proposed to be made by the undertaker for the Secretary of State’s consent, under article 36 (consent to transfer the benefit of the Order) of this Order and any such notice must be given no later than 28 days before any such application is made and must describe or give (as appropriate)—

• (a) the nature of the application to be made;

• (b) the extent of the geographical area to which the application relates; and

• (c) the name and address of the person acting for the Secretary of State to whom the application is to be made.

50

The undertaker must no later than 28 days from the date that the plans submitted to and certified by the Secretary of State in accordance with article 41 (certification of plans and documents etc.) are certified by the Secretary of State, provide a set of those plans to Network Rail in a format specified by Network Rail.

51

Any dispute arising under this Part of this Schedule, unless otherwise provided for, must be referred to and settled by arbitration in accordance with article 42 (arbitration) and the Rules at Schedule 14 (arbitration rules).

PART 6 — FOR THE PROTECTION OF ANGLIAN WATER SERVICES LIMITED

Application

52

For the protection of Anglian Water the following provisions have effect, unless otherwise agreed in writing between the undertaker and Anglian Water.

Interpretation

53

In this Part of this Schedule—

• “alternative apparatus” means alternative apparatus adequate to enable Anglian Water to fulfil its statutory functions in a manner no less efficient than previously;

• “Anglian Water” means Anglian Water Services Limited;

• “apparatus” means— works, mains, pipes or other apparatus belonging to or maintained by Anglian Water for the purposes of water supply and sewerage; any drain or works vested in Anglian Water under the Water Industry Act 1991; any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act; any drainage system constructed for the purpose of reducing the volume of surface water entering any public sewer belonging to Anglian Water; and includes a sludge main, disposal main or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus, and for the purpose of this definition, where words are defined by section 219 of that Act, they are taken to have the same meaning.

• “functions” includes powers and duties;

• “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

• “plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed.

On street apparatus

54

This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and Anglian Water are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus in stopped up streets

55

Regardless of the temporary closure or diversion of any highway under the powers conferred by article 13 (temporary prohibition or restriction on use of streets and public rights of way), Anglian Water is at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.

Protective works to buildings

56

The undertaker, in the case of the powers conferred by article 19 (protective works to buildings), may not exercise those powers so as to obstruct or render less convenient the access to any apparatus without the written consent of Anglian Water (such consent not to be unreasonably withheld or delayed).

Acquisition of land

57

Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Removal of apparatus

58

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that Anglian Water’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of Anglian Water to maintain that apparatus in that land must not be extinguished, until—

• (a) alternative apparatus has been constructed and is in operation to the reasonable satisfaction of Anglian Water in accordance with sub-paragraphs (2) to (8); and

• (b) facilities and rights have been secured for that alternative apparatus in accordance with paragraph 59.

• (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to Anglian Water 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Anglian Water the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed Anglian Water must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

• (4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Anglian Water and the undertaker or in default of agreement settled by arbitration in accordance with article 42 (arbitration).

• (5) Anglian Water must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 42, and after the grant to Anglian Water of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

• (6) Regardless of anything in sub-paragraph (5), if Anglian Water gives notice in writing to the undertaker that it desires the undertaker to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker or to the extent that Anglian Water fails to proceed with that work in accordance with sub-paragraph (5) or the undertaker and Anglian Water otherwise agree, that work, instead of being executed by Anglian Water, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of Anglian Water.

• (7) If Anglian Water fails either reasonably to approve, or to provide reasons for its failure to approve along with an indication of what would be required to make acceptable, any proposed details relating to required removal works under sub-paragraph (2) within 28 days of receiving a notice of the required works from the undertaker, then such details are deemed to have been approved. For the avoidance of doubt, any such “deemed consent” does not extend to the actual undertaking of the removal works, which must remain the sole responsibility of Anglian Water or its contractors unless these works are to be carried out by the undertaker in accordance with sub-paragraph (6).

• (8) Whenever alternative apparatus is to be or is being substituted for existing apparatus, the undertaker must, before taking or requiring any further step in such substitution works, use best endeavours to comply with Anglian Water’s reasonable requests for a reasonable period of time to enable Anglian Water to—

• (a) make network contingency arrangements; or

• (b) bring such matters as it may consider reasonably necessary to the attention of end users of the utility in question.

Facilities and rights for alternative apparatus

59

• (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and Anglian Water or in default of agreement settled by arbitration in accordance with article 42 (arbitration).

• (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Anglian Water than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Anglian Water as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

• (3) Such facilities and rights as are set out in this paragraph are deemed to include any statutory permits granted to the undertaker in respect of the apparatus in question, whether under the Environmental Permitting Regulations 2010 or other legislation.

Retained apparatus

60

• (1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus (or any means of access to it) the removal of which has not been required by the undertaker under paragraph 58(2), the undertaker must submit to Anglian Water a plan of the works to be executed.

• (2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Anglian Water for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and Anglian Water is entitled to watch and inspect the execution of those works.

• (3) Any requirements made by Anglian Water under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it.

• (4) If Anglian Water in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, sub-paragraphs 1 to 3 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 58(2).

• (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

• (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case must give to Anglian Water notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances, using its best endeavours to keep the impact of those emergency works on Anglian Water’s apparatus, on the operation of its water and sewerage network and on end-users of the services Anglian Water provides to a minimum.

• (7) For the purposes of sub-paragraph (1) and without prejudice to the generality of the principles set out in that sub-paragraph, works are deemed to be in land near Anglian Water’s apparatus (where it is a pipe) if those works fall within the following distances measured from the medial line of such apparatus—

• (a) 4 metres where the diameter of the pipe is less than 250 millimetres;

• (b) 5 metres where the diameter of the pipe is between 250 and 400 millimetres, and

• (c) a distance to be agreed on a case by case basis and before the submission of the Plan under sub-paragraph (1) is submitted where the diameter of the pipe exceeds 400 millimetres.

Expenses and costs

61

• (1) Subject to the following provisions of this paragraph, the undertaker must repay to Anglian Water all expenses reasonably incurred by Anglian Water in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in this Part of this Schedule.

• (2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule that value being calculated after removal.

• (3) If in accordance with the provisions of this Part of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 42 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Anglian Water by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

62

• (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 56 or 58(2), or by reason of any subsidence resulting from such development or works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Anglian Water, or there is any interruption in any service provided, or in the supply of any goods, by Anglian Water, the undertaker must—

• (a) bear and pay the cost reasonably incurred by Anglian Water, accompanied by an invoice or claim from Anglian Water, in making good such damage or restoring the supply; and

• (b) make reasonable compensation to Anglian Water for any other expenses, loss, damages, penalty, or costs incurred by the undertaker,

by reason or in consequence of any such damage or interruption.

• (2) The fact that any act or thing may have been done by Anglian Water on behalf of the undertaker or in accordance with a plan approved by Anglian Water or in accordance with any requirement of Anglian Water or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1) unless Anglian Water fails to carry out and execute the works properly with due care and attention and in a skilful and professional like manner or in a manner that does not accord with the approved plan.

• (3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the unlawful or unreasonable act, neglect or default of Anglian Water, its officers, servants, contractors, or agents.

• (4) Anglian Water must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made, without the consent of the undertaker (such consent not to be unreasonably withheld or delayed) who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

• (5) Anglian Water must use reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands and penalties to which the undertaker must bear and pay the costs for.

Cooperation

63

Where in consequence of the proposed construction of any of the authorised development, the undertaker or Anglian Water requires the removal of apparatus under paragraph 58(2) or Anglian Water makes requirements for the protection or alteration of apparatus under paragraph 60, the undertaker must use all reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of Anglian Water’s undertaking, using existing processes where requested by Anglian Water, provided it is appropriate to do so, and Anglian Water must use all reasonable endeavours to co-operate with the undertaker for that purpose.

64

Where the undertaker identifies any apparatus which may belong to or be maintainable by Anglian Water but which does not appear on any statutory map kept for the purpose by Anglian Water, it must inform Anglian Water of the existence and location of the apparatus as soon as reasonably practicable.

65

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Anglian Water in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

66

The undertaker and Anglian Water may by written agreement substitute any period of time for those periods set out in this Part of this Schedule.

PART 7 — FOR THE PROTECTION OF NATIONAL GRID ELECTRICITY TRANSMISSION PLC AS ELECTRICITY UNDERTAKER

Application

67

• (1) For the protection of National Grid Electricity Transmission plc (NGET) as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and NGET.

• (2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and NGET, where the benefit of this Order is transferred or granted to another person under article 37 (consent to transfer the benefit of the Order)—

• (a) any agreement of the type mentioned in subparagraph (1) has effect as if it had been made between NGET and the transferee or grantee (as the case may be); and

• (b) written notice of the transfer or grant must be given to NGET on or before the date of that transfer or grant.

• (3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to NGET (but without prejudice to paragraph 83(3)(b)).

Interpretation

68

In this Part of this Schedule—

• “acceptable credit provider” means a bank or financial institution with a credit rating that is not lower than: (i) “A-” if the rating is assigned by Standard & Poor’s Ratings Group or Fitch Ratings; and “A3” if the rating is assigned by Moody’s Investors Services Inc.;

• “acceptable insurance” means general third party liability insurance effected and maintained by the undertaker with a combined property damage and bodily injury limit of indemnity of not less than a sum to be notified by NGET and agreed in writing between the parties. Evidence of that insurance must be provided to NGET on request. Such insurance shall be maintained (a) during the construction period of the specified works; and (b) after the construction period of the specified works in respect of any use and maintenance of the specified works by or on behalf of the undertaker and arranged with an insurer whose security/credit rating meets the same requirements as an “acceptable credit provider”, such insurance shall include (without limitation)— a waiver of subrogation and an indemnity to principal clause in favour of NGET; pollution liability for third party property damage and third party bodily damage arising from any pollution/contamination event with a (sub)limit of indemnity of not less than a sum to be notified by NGET and agreed in writing between the parties;

• “acceptable security” means either— a parent company guarantee from a parent company in favour of NGET to cover the undertaker’s liability to NGET to a total liability cap in an amount to be notified to the undertaker by NGET and agreed in writing between the parties (in a form reasonably satisfactory to NGET and where required by NGET, accompanied with a legal opinion confirming the due capacity and authorisation of the parent company to enter into and be bound by the terms of such guarantee); or a bank bond or letter of credit from an acceptable credit provider in favour of NGET to cover the undertaker’s liability to NGET for an amount to be notified to the undertaker by NGET and agreed in writing between the parties (in a form reasonably satisfactory to NGET);

• “alternative apparatus” means appropriate alternative apparatus to the satisfaction of NGET to enable NGET to fulfil its statutory functions in a manner no less efficient than previously;

• “apparatus” means any electric lines or electrical plant as defined in the 1989 Act, belonging to or maintained by NGET together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of NGET for the purposes of transmission, distribution and/or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

• “authorised works” has the same meaning as is given to the term “authorised development” in article 2 (interpretation) of this Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Schedule;

• “commence” and “commencement” in this Part of this Schedule will include any below ground surveys, monitoring, ground work operations or the receipt and erection of construction plant and equipment;

• “deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;

• “functions” includes powers and duties;

• “grid connection works” means that part of the authorised development identified in work numbers 5, 7, 8 and 9 (to the extent work numbers 7, 8 and 9 are necessary in connection with work number 5) and carried out in the Navenby Substation area;

• “ground mitigation scheme” means a scheme approved by NGET (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;

• “ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, must require the undertaker to submit for NGET’s approval a ground mitigation scheme;

• “ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme;

• “in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

• “incentive deduction” means any incentive deduction NGET receives under its electricity transmission licence which is caused by an event on its transmission system that causes electricity not to be supplied to a demand customer and which arises as a result of the authorised works;

• “maintain” and “maintenance” will include the ability and right to do any of the following in relation to any apparatus or alternative apparatus of NGET: construct, use, repair, alter, inspect, renew or remove the apparatus;

• “National Grid Navenby Substation” means the proposed substation at Heath Lane, Navenby, LN5 0AY, owned and operated by NGET which NGET will seek planning permission for under the Town and Country Planning Act 1990;

• “Navenby Substation area” means the land shown in the land plans as plots 11/1, 11/3 and 11/4 and shaded grey on the Navenby Substation area plan within which NGET intends to construct the National Grid Navenby Substation;

• “Navenby Substation area plan” means the document of that name identified in the table at Schedule 13 (documents and plans to be certified) and which is certified by the Secretary of State as the Navenby Substation area plan for the purposes of this Order;

• “NGET” means National Grid Electricity Transmission Plc (Company Number 2366977) whose registered office is at 1-3 Strand, London, WC2N 5EH or any successor as a licence holder within the meaning of Part 1 of the 1989 Act;

• “NGESO” means as defined in the STC;

• “plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;

• “parent company” means a parent company of the undertaker acceptable to and which shall have been approved by NGET acting reasonably;

• “specified works” means any of the authorised works or activities undertaken in association with the authorised development which— will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 79(2) or otherwise; and/or may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 79(2) or otherwise; and/or includes any of the activities that are referred to in development near overhead lines EN43-8 and HSE’s guidance note 6 “Avoidance of Danger from Overhead Lines”.

• “STC” means the System Operator Transmission Owner Code prepared by the electricity transmission owners and NGESO as modified from time to time;

• “STC claims” means any claim made under the STC against NGET arising out of or in connection with the de-energisation (whereby no electricity can flow to or from the relevant system through the generator or interconnector’s equipment) of a generator or interconnector party solely as a result of the de-energisation of plant and apparatus forming part of NGET’s transmission system which arises as a result of the authorised works; and

• “transmission owner” means as defined in the STC.

Interaction with the National Grid Navenby Substation

69

Without limiting any other provision of this Part of this Schedule, the undertaker and NGET must use reasonable endeavours to avoid any conflict arising between the construction, maintenance and operation of the grid connection works and the National Grid Navenby Substation. For the purposes of this paragraph, “reasonable endeavours” means—

• (a) providing a point of contact for each of the undertaker and NGET for continuing liaison and co-ordination throughout the construction and operation of the grid connection works and the National Grid Navenby Substation;

• (b) the undertaker will share its relevant design documents and programme for the grid connection works with NGET and NGET will share its relevant design documents with the undertaker;

• (c) NGET will notify the undertaker of its programme of works for the National Grid Navenby Substation, including programme for the user-bay into which the authorised development’s grid connection works will connect, not less than 21 days ahead of carrying out the works;

• (d) a commitment by the undertaker to keep NGET informed through the point of contact identified under sub-paragraph (a) of any material changes to the programme and detailed design for the grid connection works in the event such changes arise; and

• (e) the parties seeking to facilitate as far as reasonably practicable a co-ordinated approach to the programme, land assembly, and the carrying out of the grid connection works and the National Grid Navenby Substation.

Grid connection works

70

The undertaker must not except with the agreement of NGET pursuant to this Part of this Schedule, carry out the grid connection works, or any part of it (excepting any works which are works regulated by the connection agreement between the undertaker and National Grid Energy Systems Operator (or a successor thereto)).

71

• (1) Before beginning to construct any grid connection works, or any part of it, the undertaker must submit to NGET plans of the relevant grid connection works (or part of it) and such further particulars available to it as NGET may request within 21 days of receipt of the plans reasonably requested.

• (2) Any grid connection works must not be constructed except in accordance with such plans as may be approved in writing by NGET.

72

• (1) Any approval of NGET required under this Schedule—

• (a) must not be unreasonably withheld or delayed;

• (b) in the case of a refusal must be accompanied by a statement of grounds or refusal; and

• (c) may be given subject to such reasonable requirements as NGET may have in connection with the safe, economic and efficient construction, commissioning, operation, maintenance and future decommissioning of the National Grid Navenby Substation or otherwise for the protection of National Grid Navenby Substation apparatus,

provided always that in relation to a refusal under sub-paragraph (b) or any requirements requested pursuant to sub-paragraph (c) the undertaker shall be permitted to refer such matters to dispute resolution pursuant to paragraph 88 (arbitration).

• (2) NGET must respond to the submission of any plans within a period of 56 days from the date of submission of the plans. If NGET require further particulars, such particulars must be requested by NGET no later than 21 days from the submission of plans and thereafter NGET must employ reasonable endeavours to respond to the submission within 56 days from receipt of the further particulars.

73

• (1) The undertaker must give to NGET not less than 14 days’ notice in writing of its intention to commence construction of any National Grid connection works and notice in writing of its completion not later than 7 days after the date on which it is completed and NGET will be entitled by its officer to watch and inspect the construction of such works.

• (2) If any part of the grid connection works is constructed otherwise than in accordance with paragraph 71(2) above NGET may by notice in writing identify the extent to which the grid connection works do not comply with the approved details and request the undertaker at the undertaker’s own expense carry out remedial works so as to comply with the requirements of paragraph 71(2) of this Schedule or such alternative works as may be agreed with NGET or as otherwise may be agreed between the parties.

• (3) Subject to sub-paragraph 71, if within a reasonable period, being not less than 28 days beginning with the date when a notice under sub-paragraph (2) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, NGET may execute the works specified in the notice and any reasonable expenditure incurred by NGET in so doing will be recoverable from the undertaker.

• (4) In the event of any dispute as to whether sub-paragraph (2) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, NGET will not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined in accordance with paragraph 86.

74

Not used.

On Street Apparatus

75

Except for paragraphs 76 (apparatus of NGET in stopped up streets), 81 (retained apparatus: protection of NGET), 82 (expenses) and 83 (indemnity) of this Schedule which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of NGET, the other provisions of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and NGET are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus of NGET in stopped up streets

76

Notwithstanding the temporary prohibition or restriction on use or diversion of any highway under the powers of article 13 (temporary prohibition or restriction on use of streets and public rights of way), NGET is at liberty at all times to take all necessary access across any such street or public right of way and to execute and do all such works and things in, upon or under any such street or public right of way as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction on use or diversion was in that street or public right of way.

Protective works to buildings

77

The undertaker, in the case of the powers conferred by article 19 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus or to the National Grid Navenby Substation without the written consent of NGET.

Acquisition of land

78

• (1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order, the undertaker may not (a) appropriate or acquire or take temporary possession of any land or apparatus or (b) appropriate, acquire, extinguish, interfere with or override any easement, other interest or right and/or apparatus of NGET otherwise than by agreement.

• (2) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between NGET and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of NGET or affect the provisions of any enactment or agreement regulating the relations between NGET and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as NGET reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between NGET and the undertaker acting reasonably and which must be no less favourable on the whole to NGET unless otherwise agreed by NGET, and it will be the responsibility of the undertaker to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works.

• (3) Save where otherwise agreed in writing between NGET and the undertaker, the undertaker and NGET agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation and/or removal of apparatus/including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by NGET and/or other enactments relied upon by NGET as of right or other use in relation to the apparatus, then the provisions in this Part of this Schedule will prevail.

• (4) Any agreement or consent granted by NGET under paragraph 81 or any other paragraph of this Part of this Schedule, must not be taken to constitute agreement under sub-paragraph (1).

Removal of apparatus

79

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of NGET to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of NGET in accordance with sub-paragraph (2) to (5).

• (2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to NGET advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order NGET reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), secure any necessary consents for the alternative apparatus and afford to NGET to its satisfaction (taking into account paragraph 80(1) below) the necessary facilities and rights—

• (a) for the construction of alternative apparatus in other land of or land secured by the undertaker; and

• (b) subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such consents, facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, NGET may in its sole discretion, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances to assist the undertaker to obtain the necessary consents, facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation will not extend to the requirement for NGET to use its compulsory purchase powers to this end unless it elects to do so.

• (4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between NGET and the undertaker.

• (5) NGET must, after the alternative apparatus to be provided or constructed has been agreed, and subject to a written diversion agreement having been entered into between the parties and the grant to NGET of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Facilities and rights for alternative apparatus

80

• (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for NGET facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and NGET and must be no less favourable on the whole to NGET than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by NGET.

• (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to NGET than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject the matter may be referred to arbitration in accordance with paragraph 88 (Arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to NGET as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus: protection of NGET

81

• (1) Not less than 56 days before the commencement of any specified works the undertaker must submit to NGET a plan of the works to be executed and seek from NGET details of the underground extent of their electricity assets.

• (2) In relation to specified works the plan to be submitted to NGET under sub-paragraph (1) must include a method statement and describe—

• (a) the exact position of the works;

• (b) the level at which these are proposed to be constructed or renewed;

• (c) the manner of their construction or renewal including details of excavation, positioning of plant;

• (d) the position of all apparatus;

• (e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;