The West Burton Solar Project Order 2025

• (4) Any amount which apart from this sub-paragraph would be payable to Uniper in respect of works by virtue of sub-paragraph ‎(1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on Uniper any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Indemnity

195

• (1) Subject to sub-paragraphs ‎(2) and ‎(3), if by reason or in consequence of the construction of the authorised development or in consequence of the construction, use, maintenance or failure of any of the authorised development by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by them) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any loss or damage is caused to any apparatus, alternative apparatus or property of Uniper, or there is any interruption in any services provided, or in the supply of any goods, or in the use of the apparatus or alternative apparatus (as applicable) by Uniper, the undertaker must—

• (a) bear and pay the costs reasonably and properly incurred by Uniper in making good such loss or damage or in restoring the supply or its use;

• (b) make compensation to Uniper for any other expenses, loss, damages, penalty or costs incurred by Uniper, by reason or in consequence of any such loss, damage or interruption; and

• (c) indemnify Uniper for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from Uniper, by reason or in consequence of any such damage or interruption or Uniper becoming liable to any third party (an “indemnity claim”).

• (2) Nothing in sub-paragraph ‎(1) imposes any liability on the undertaker with respect to—

• (a) any damage or interruption to the extent that it is attributable to the act, neglect or default of Uniper or its representatives; or

• (b) any indirect or consequential loss of any third party (including but not limited to loss of use, revenue, profit, contract, production, increased cost of working or business interruption) arising from any such damage or interruption which is not reasonably foreseeable.

• (3) Uniper must give the undertaker reasonable notice of an indemnity claim and no settlement or compromise is to be made that is prejudicial to the undertaker without the consent of the undertaker (not to be unreasonably withheld) which, if it withholds such consent, it will assume the sole conduct of the indemnity claim, provided that if the undertaker does not assume the sole conduct of the indemnity claim within 30 days of the indemnified claim being notified to it, Uniper, or a person designated by Uniper, may conduct the indemnity claim in such manner as it may deem appropriate and the undertaker will indemnify Uniper for any costs and expenses incurred in connection with defending any such indemnity claim.

• (4) The undertaker will give assistance to Uniper, as requested, in connection with an indemnity claim (including circumstances where Uniper reasonably believes may give rise to an action, claim or demand by a third party).

• (5) The undertaker undertakes not to commence construction (and not to permit the commencement of such construction) of the authorised development on any land owned by Uniper or in respect of which Uniper has an easement, wayleave or lease for its apparatus or any other interest or to carry out any works within 15 metres of Uniper’s apparatus (except in respect of any high pressure pipelines) or within 50 metres of Uniper’s high pressure pipelines until the following conditions are satisfied—

• (a) unless and until Uniper is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has first provided the acceptable security (and provided evidence that it will maintain such acceptable security for the construction period of the authorised development from the proposed date of commencement of construction the authorised development) and Uniper has confirmed the same to the undertaker in writing; and

• (b) unless and until Uniper is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has procured acceptable insurance (and provided evidence to Uniper that it will maintain such acceptable insurance for the construction period of the authorised development from the proposed date of commencement of construction of the authorised development) and Uniper has confirmed the same in writing to the undertaker.

• (6) The undertaker agrees that if, at any time, the acceptable security or acceptable insurance expires or terminates, ceases to fulfil the criteria of acceptable security or acceptable insurance, ceases to be in full force and effect or becomes invalid or unenforceable for the purpose of this Part of this Schedule or an insolvency-related event occurs in respect of the undertaker, then the relevant security or insurance will no longer constitute acceptable security or acceptable insurance and will promptly be replaced by the undertaker with alternative acceptable security or acceptable insurance as approved by the undertaker.

• (7) In the event that the undertaker fails to comply with sub-paragraph ‎(4) nothing in this Part of this Schedule will prevent Uniper from seeking injunctive relief (or any other equitable remedy) in any court of competent jurisdiction.

• (8) Uniper must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within Uniper’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of Uniper’s control and if reasonably requested to do so by the undertaker Uniper must provide an explanation of how the claim has been minimised, where relevant.

Co-operation

196

• (1) Where, in consequence of the proposed construction of any of the authorised development, Uniper makes requirements for the protection or alteration of apparatus under paragraphs ‎192(6) or ‎192(8), the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe, efficient and economic operation of Uniper’s apparatus and Uniper must use its best endeavours to co-operate with the undertaker for that purpose.

• (2) For the avoidance of doubt whenever Uniper’s consent, agreement or approval to is required in relation to plans, documents or other information submitted by Uniper or the taking of action by Uniper, it must not be unreasonably withheld or delayed.

Confidentiality

197

• (1) Each party must treat any confidential information as private and confidential. The party in receipt of any confidential information from the other party may not use it for a purpose other than for the performance of its obligations under this Part of this Schedule and must not disclose confidential information received from the other party to any person, provided that a party may disclose confidential information to any of its directors, other officers, employees, contractors, customers, affiliates, insurers, funders, advisers or consultants to the extent that disclosure is reasonably necessary for the purposes of this Part of this Schedule.

• (2) Sub-paragraph ‎(1) does not apply to confidential information—

• (a) which is at the date of commencement, or at any time after that date becomes, publicly known other than by breach of sub-paragraph ‎(1);

• (b) which was known by the receiving party before disclosure by the other party to the receiving party, provided that such confidential information was lawfully obtained; or

• (c) to the extent disclosure of the confidential information is required by laws, the instructions of a competent governmental authority or such competent authority acting on behalf of such governmental authority, or the rules of a relevant and recognised stock exchange.

Access

198

If in consequence of the agreement reached in accordance with paragraph ‎191(1) of this Part of this Schedule or otherwise as granted by this Order the access to any apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by Uniper (or representative) in respect of the apparatus) is materially obstructed, the undertaker must provide such alternative rights and means of access to such apparatus as will enable Uniper (or its representative) to maintain or use the apparatus no less effectively than was possible before such obstruction. For the avoidance of doubt, Uniper (or its representative) will be entitled to access its apparatus in the land at all times.

Arbitration

199

Any difference or dispute arising between the undertaker and Uniper under this Part of this Schedule must be determined by arbitration in accordance with article ‎42 (arbitration).

Notices

200

Any notice, statement, request, plan or any other written communication (including the plan to be provided at paragraph ‎192) to be given or made in respect of this Part of this Schedule by the undertaker must be given or made in writing FAO Lead Pipeline Engineer, Uniper Pipelines Team, Pipelines Office, Uniper Killingholme Power Station, Chase Hill Road, Killingholme, North Lincolnshire, DN40 3LU or such other address as Uniper may have notified to the undertaker from time to time.

PART 15 — FOR THE PROTECTION OF EXOLUM PIPELINE SYSTEM LIMITED

Application

201

• (1) For the protection of Exolum the following provisions, unless otherwise agreed in writing at any time between the undertaker and Exolum, have effect.

• (2) In this Part of this Schedule, the following terms have the following meanings—

• “additional rights” means rights for the construction and for access to and for the use, protection, inspection, maintenance, repair and renewal of retained apparatus including any restrictions on the landowner and occupiers for the protection of the retained apparatus and to allow Exolum to perform its functions;

• “alternative apparatus” means alternative apparatus adequate to enable Exolum to fulfil its functions as a pipeline operator in a manner not less efficient than previously;

• “alternative rights” means rights for the construction and for access to and for the use, protection, inspection, maintenance, repair and renewal of alternative apparatus including any restrictions on the landowner and occupiers for the protection of the alternative apparatus and to allow Exolum to perform its functions;

• “apparatus” means the pipeline and storage system and any ancillary apparatus owned or operated by Exolum and includes—any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;any ancillary works, all protective wrappings, valves, sleeves and slabs, cathodic protection units, together with ancillary cables and markers;such legal interest, and benefit of property rights and covenants as are vested in respect of these items;and, where the context requires, includes alternative apparatus;

• “Exolum” means Exolum Pipeline System Ltd (company registration number 09497223 whose registered office is 1st Floor 55 King William Street, London, England, EC4R 9AD) and for the purpose of enforcing the benefit of any provisions in this Part of this Schedule, any group company of Exolum Pipeline System Ltd and in all cases any successor in title;

• “functions” includes powers, duties and commercial undertaking;

• “in” in a context referring to apparatus in land includes a reference to apparatus under, over or upon land;

• “plan” includes all designs, drawings, sections, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary to allow Exolum to assess the restrictive works to be executed properly and sufficiently and in particular must describe—the position of the works as proposed to be constructed or renewed;the level at which the works are proposed to be constructed or renewed;the manner of the works’ construction or renewal including details of excavation, positioning of plant etc.;the position of the affected apparatus and/or premises and any other apparatus belonging to another undertaker that may also be affected by the restrictive works;by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;any intended maintenance regime;details of the proposed method of working and timing of execution of works; anddetails of vehicle access routes for construction and operational traffic;

• “premises” means land that Exolum owns, occupies or otherwise has rights to use including but not limited to storage facilities, administrative buildings and jetties;

• “protective works” means works for the inspection and protection of apparatus; and

• “restrictive works” means any works that are near to, or will or may affect any apparatus or premises including—all works within 15 metres measured in any direction of any apparatus including embankment works and those that involve a physical connection or attachment to any apparatus;the crossing of apparatus by other utilities;the use of explosives within 400 metres of any apparatus;piling, undertaking of a 3D seismic survey or the sinking boreholes within 30 metres of any apparatus; andall works that impose a load directly upon the apparatus, wherever situated,whether carried out by the undertaker or any third party in connection with the authorised development.

Acquisition of apparatus

202

• (1) Regardless of any other provision in the Order or anything shown on the land plan—

• (a) the undertaker must not, otherwise than by agreement with Exolum, acquire any apparatus, Exolum’s rights in respect of apparatus or any of Exolum’s interests in the Order land;

• (b) where the undertaker acquires the freehold of any land in which Exolum holds an interest, the undertaker must afford to or secure for Exolum such rights in land in substitution for any right which would be extinguished by that acquisition (the replacement rights). These replacement rights must be granted upon substantially the same terms and conditions as the right to be extinguished, unless otherwise agreed between the undertaker and Exolum, and must be granted or put in place contemporaneously with the extinguishment of the right which they replace;

• (c) the undertaker must not, otherwise than in accordance with this Part of this Schedule—

• (i) obstruct or render less convenient the access to any apparatus;

• (ii) interfere with or affect Exolum’s ability to carry out its functions as an oil pipeline operator;

• (iii) require that apparatus is relocated or diverted; or

• (iv) remove or required to be removed any apparatus;

• (d) any right of Exolum to maintain, repair, renew, adjust, alter or inspect apparatus must not be extinguished by the undertaker until any necessary alternative apparatus has been constructed and it is in operation and the alternative rights have been granted, all to the reasonable satisfaction of Exolum; and

• (e) any right of Exolum to access the Exolum operations must not be extinguished until necessary alternative access has been provided to Exolum’s reasonable satisfaction.

• (2) Prior to the carrying out of any restrictive works or any works authorised by this Order that will affect the apparatus, and if required by Exolum, the parties must use their reasonable endeavours to negotiate and enter into such deeds of consent (crossing consent) and (if considered necessary) variations to the existing rights upon such terms and conditions as may be agreed between Exolum and the undertaker acting reasonably and which must be no less favourable on the whole to Exolum than this Part of this Schedule, and the undertaker will use reasonable endeavours to procure and secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such works.

• (3) Where the undertaker acquires land which is subject to any existing rights and the provisions of paragraph ‎203(4) do not apply, the undertaker must—

• (a) retain any notice of the existing rights of Exolum on the title to the relevant land when registering the undertaker’s title to such acquired land;

• (b) (where no such notice of the existing rights or other interest exists in relation to such acquired land or any such notice is registered only on the Land Charges Register) include (with an application to register title to the undertaker’s interest in such acquired land at the Land Registry) a notice of the existing rights or other interest in relation to such acquired land; and

• (c) provide up to date official entry copies to Exolum within 20 working days of receipt of such up to date official entry copies.

• (4) Where the undertaker takes temporary possession of any land or carries out survey works on land in respect of which Exolum has apparatus—

• (a) where reasonably necessary, Exolum may exercise its rights to access such land;

• (i) in an emergency, without notice; and

• (ii) in non-emergency circumstances, having first given not less than 14 days’ written notice to the undertaker in order to allow the parties to agree the timing of their respective works during the period of temporary possession; and

• (b) the undertaker must not remove or in any way alter Exolum’s rights in such land, unless in accordance with the provisions of this Order.

Removal of apparatus and rights for alternative apparatus

203

• (1) If, having used all reasonable endeavours to implement the authorised development without the removal of any apparatus—

• (a) the undertaker reasonably requires the removal of any apparatus; or

• (b) Exolum reasonably requires the removal of any apparatus,

then the relevant party must give written notice of that requirement to the other.

• (2) The parties must use their reasonable endeavours to produce a plan of the work proposed and a plan of the proposed position of the alternative apparatus to be provided or constructed.

• (3) The undertaker must afford to Exolum the necessary facilities and rights for the construction of alternative apparatus and subsequently the grant of alternative rights in accordance with paragraph ‎204.

• (4) Any alternative apparatus is to be constructed in land owned by the undertaker or in land in respect of which alternative rights have been or are guaranteed to be granted to Exolum. The alternative apparatus must be constructed in such manner and in such line or situation as may be agreed between Exolum and the undertaker or in default of agreement settled by arbitration in accordance with article ‎42 (arbitration).

• (5) After the details for the works for alternative apparatus to be provided or constructed have been agreed or settled in accordance with article ‎42 (arbitration), and after the grant to Exolum of any such facilities and rights as are referred to in sub-paragraph ‎(4), Exolum must proceed as soon as reasonably practicable using reasonable endeavours to construct and bring into operation the alternative apparatus and subsequently to remove (or if agreed between the parties to allow the undertaker to remove) any redundant apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

• (6) The following sub-paragraphs ‎(7) and ‎(8) only apply if—

• (a) Exolum fails to comply with its obligations under sub-paragraph ‎(5) to remove any redundant apparatus; and

• (b) the undertaker has served notice on Exolum specifying the default; and

• (c) Exolum has failed to remedy the default within 28 days.

• (7) In the circumstances set out in sub-paragraph ‎(6), if the undertaker then gives notice in writing to Exolum that it desires itself to remove the redundant apparatus, that work, instead of being executed by Exolum, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of Exolum.

• (8) Nothing in sub-paragraph ‎(7) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 3000 millimetres of the apparatus unless that apparatus is redundant and disconnected from Exolum’s remaining system.

Facilities and Rights for alternative apparatus

204

• (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to Exolum facilities and rights for the construction of alternative apparatus and the grant of alternative rights, in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and Exolum and must be materially no less favourable on the whole to Exolum than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by Exolum, in accordance with this Part of this Schedule or in default of agreement settled by arbitration in accordance with article ‎42 (arbitration).

• (2) Alternative rights must be granted before any alternative apparatus is brought into use.

• (3) The parties agree that the undertaker must use reasonable endeavours to procure the grant of the alternative rights by way of a 999 year sub-soil lease, substantially in the form of Exolum’s precedent from time to time as amended by written agreement between the parties acting reasonably, or such other form of agreement as the parties otherwise agree acting reasonably.

• (4) Nothing in this Part of this Schedule or contained in the alternative rights requires Exolum to divert or remove any alternative apparatus.

• (5) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of Exolum less favourable on the whole to Exolum than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, Exolum may refer the matter to arbitration in accordance with article ‎42 (arbitration).

Retained apparatus and alternative apparatus: protection

205

• (1) Before commencing the execution of any restrictive works, the undertaker must submit to Exolum a plan of the works to be executed and any other information that Exolum may reasonably require to allow Exolum to assess the works.

• (2) No restrictive works are to be commenced until the plan to be submitted to Exolum under sub-paragraph ‎(1) has been approved by Exolum in writing (acting reasonably) and are to be carried out only in accordance with the details submitted under sub-paragraph ‎(1) and in accordance with such reasonable requirements as may be notified to the undertaker in writing in accordance with sub-paragraph ‎(3) by Exolum.

• (3) Any approval of Exolum in respect of restrictive works may be given subject to such reasonable requirements as Exolum may require to be made for—

• (a) the continuing safety and operational viability of any apparatus;

• (b) the requirement for Exolum to have reasonable access with or without vehicles to inspect, repair, replace, maintain and ensure the continuing safety and operation or viability of any apparatus; and

• (c) the requirement for Exolum to be entitled to watch and inspect the execution of restrictive works to ensure the continuing safety and operational viability of any apparatus and ensure compliance with the agreed plan,

providing such reasonable requirements will be notified to the undertaker in writing.

• (4) Where reasonably required by either party, in view of the complexity of any proposed works, timescales, phasing or costs, the parties must with due diligence and good faith negotiate a works agreement for the carrying out of protective works or the installation of alternative apparatus.

• (5) If in consequence of the works notified to Exolum by the undertaker under sub-paragraph ‎(1), the circumstances in paragraph ‎203 apply, then the parties must follow the procedure in paragraph ‎203 onwards.

• (6) Nothing in sub-paragraphs ‎(1) to ‎(5) precludes the undertaker from submitting prior to the commencement of works to protect retained apparatus or to construct alternative apparatus (unless otherwise agreed in writing between the undertaker and Exolum) a new plan, instead of the plan previously submitted, in which case the parties must re-run the procedure from sub-paragraph ‎(1) onwards.

• (7) Where Exolum reasonably requires protective works, the parties must use their reasonable endeavours to produce a plan of the work proposed and a plan of the proposed position of any physical features to be provided or constructed.

• (8) The undertaker must afford to Exolum the necessary facilities and rights for the construction of protective works and subsequently the grant of additional rights in accordance with paragraph ‎204.

• (9) Any protective works are to be constructed in land owned by the undertaker or in land in respect of which additional rights have been or are guaranteed to be granted to Exolum. The protective works must be constructed in such manner and in such line or situation as may be agreed between Exolum and the undertaker or in default of agreement settled by arbitration in accordance with article ‎42 (arbitration).

• (10) After the details for the protective works to be provided or constructed have been agreed or settled in accordance with article ‎42 (arbitration), and after the grant to Exolum of any such facilities and rights as are referred to in paragraph ‎203(3), Exolum must proceed as soon as reasonably practicable using reasonable endeavours to construct and bring into operation the protective works.

Cathodic protection testing

206

• (1) Where in the reasonable opinion of Exolum or the undertaker—

• (a) the authorised development might interfere with the cathodic protection forming part of apparatus; or

• (b) any apparatus might interfere with the proposed or existing cathodic protection forming part of the authorised development,

Exolum and the undertaker must co-operate in undertaking the tests which they consider reasonably necessary for ascertaining the nature and extent of such interference and measures for providing or preserving cathodic protection.

• (2) The Parties must carry out the works and enter into such agreements as are necessary to implement the measures for providing or preserving cathodic protection.

Expenses

207

• (1) Subject to the following provisions of this paragraph ‎207, the undertaker must pay to Exolum the reasonable and properly incurred costs and expenses (including reasonable staffing costs if work is carried out in-house) incurred by Exolum in, or in connection with—

• (a) undertaking its obligations under this Part of this Schedule including—

• (i) the installation, inspection, removal, alteration, testing or protection of any apparatus, alternative apparatus and protective works;

• (ii) the execution of any other works under this Part of this Schedule; and

• (iii) the review and assessment of plans;

• (b) the watching of and inspecting the execution of the authorised development, any restrictive works and any works undertaken by third parties as a result of authorised development (including the assessment of plans); and

• (c) imposing reasonable requirements for the protection or alteration of apparatus affected by the authorised development or works as a consequence of the authorised development in accordance with paragraph ‎205(3),

together with any administrative costs properly and reasonably incurred by Exolum.

• (2) There will be no deduction from any sum payable under sub-paragraph ‎(1) as a result of—

• (i) the placing of apparatus of a better type, greater capacity or of greater dimensions, or at a greater depth than the existing apparatus, to the extent Exolum has acted reasonably in procuring such apparatus;

• (ii) the placing of apparatus in substitution of the existing apparatus that may defer the time for renewal of the existing apparatus in the ordinary course; or

• (iii) the scrap value (if any) of any apparatus removed.

• (3) Upon the submission of proper and reasonable estimates of costs and expenses to be incurred by Exolum, the undertaker shall pay Exolum sufficiently in advance to enable Exolum to undertake its obligations under this Part of this Schedule in a manner that is neutral to its cash flow provided that in the event that the costs incurred by Exolum are less than the amount paid by the undertaker pursuant to this sub-paragraph ‎(3) then Exolum shall within 35 days of payment being made by Exolum for the costs anticipated in the costs and expenses estimates, repay any overpayment to the undertaker.

Damage to property and other losses

208

• (1) Subject to sub-paragraphs ‎(2) to ‎(7), the undertaker shall—

• (a) indemnify Exolum for all reasonably incurred loss, damage, liability, costs and expenses suffered or reasonably incurred by Exolum arising out of—

• (i) the carrying out of works under this Part of this Schedule;

• (ii) the carrying out of the authorised development;

• (iii) the use or occupation of land over or in the vicinity of any apparatus or in the vicinity of any premises in connection with the carrying out of the authorised development;

• (iv) any injury or damage whatsoever to any property, real or personal, including the property of Exolum; and

• (v) any matters arising out of or in connection with this Order;

• (b) indemnify Exolum against any claim made against, or loss suffered by, Exolum as a result of any act or omission committed by the undertaker’s officers, employees, contractors or agents whilst on or in the vicinity of any apparatus or premises for the purposes of carrying out any activity authorised by this Order;

• (c) pay to Exolum, in accordance with the terms of the provisions of this Part of this Schedule, the cost reasonably incurred by Exolum in making good any damage to the apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal or abandonment) arising out of the carrying out of works under this Part of this Schedule and arising out of the carrying out of the authorised development; and

• (d) pay to Exolum the cost reasonably incurred by Exolum in stopping, suspending and restoring the supply though its apparatus in consequence of the carrying out of works under this Part of this Schedule or the carrying out of the authorised development;

and make reasonable compensation to Exolum for any other expenses, losses, damages, penalty or costs incurred by Exolum by reason or in consequence of any such damage or interruption including all claims by third parties.

• (2) Nothing in sub-paragraph ‎(1) imposes any liability on the undertaker with respect to any indirect or consequential loss of any third party (including but not limited to loss of use, revenue, profit, contract, production, increased cost of working or business interruption) arising from any such damage or interruption which is not reasonably foreseeable.

• (3) The fact that any act or thing may have been done by Exolum on behalf of the undertaker or in accordance with a plan approved by Exolum or in accordance with any requirement of Exolum or under its supervision shall not, subject to sub-paragraph ‎(4), excuse the undertaker from liability under the provisions of sub-paragraph ‎(1).

• (4) Nothing in sub-paragraph ‎(1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the negligent act, neglect or default of Exolum, its officers, servants, contractors or agents.

• (5) The undertaker and Exolum shall at all times take reasonable steps to prevent and mitigate any loss, damage, liability, claim, cost or expense (whether indemnified or not) which either suffers in connection with this Part of this Schedule.

• (6) The undertaker warrants that it will use reasonable endeavours to ensure—

• (a) the information it or any of its employees, agents or contractors provide to Exolum about the plans or the authorised development and on which Exolum relies in the design of and carrying out of any works is accurate; and

• (b) the undertaker or any of its employees, agents or contractors have exercised all the reasonable skill, care and diligence to be expected of a qualified and experienced member of their respective profession.

• (7) Exolum must give the undertaker reasonable notice of any such claim or demand to which sub-paragraph ‎(2) applies.

Insurance

209

• (1) The undertaker must not carry out any restrictive works unless and until Exolum has confirmed to the undertaker in writing that it is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker (or its contractor) has procured acceptable professional indemnity insurance and public liability insurance with minimum cover of £25 million per event, with respect to the carrying out of the works.

• (2) The undertaker shall maintain such insurance for the construction period of the authorised development from the proposed date of commencement of the authorised development unless otherwise agreed in writing with Exolum.

Co-operation and reasonableness

210

• (1) Where apparatus is required to be protected, altered, diverted or removed under this Part of this Schedule, the undertaker must use all reasonable endeavours to co-ordinate the execution of any works under this Part of this Schedule—

• (a) in the interests of safety;

• (b) in the interest of the efficient and economic execution of both Exolum’s works and the authorised development; and

• (c) taking into account the need to ensure the safe and efficient operation of the apparatus and carrying out of Exolum’s functions.

• (2) Exolum must use its reasonable endeavours to co-operate with the undertaker for the purposes outlined in sub-paragraph ‎(1).

• (3) The undertaker and Exolum will act reasonably in respect of any given term of this Part of this Schedule and, in particular (without prejudice to generality), where any approval, consent or expression of satisfaction is required by this Part of this Schedule it must not be unreasonably withheld or delayed.

Emergency circumstances

211

• (1) The undertaker acknowledges that Exolum provides services to His Majesty’s Government, using the apparatus, which may affect any works to be carried under this Part of this Schedule and the authorised development.

• (2) In the following circumstances, Exolum may on written notice to the undertaker immediately suspend all works that necessitate the stopping or suspending of the supply of product through any apparatus under this Part of this Schedule and Exolum shall not be in breach of its obligations under this Part of this Schedule—

• (a) circumstances in which, in the determination of His Majesty’s Government, there subsists a material threat to national security, or a threat or state of hostility or war or other crisis or national emergency (whether or not involving hostility or war); or

• (b) circumstances in which a request has been received, and a decision to act upon such request has been taken, by His Majesty’s Government for assistance in relation to the occurrence or anticipated occurrence of a major accident, crisis or natural disaster; or

• (c) circumstances in which a request has been received from or on behalf of NATO, the EU, the UN, the International Energy Agency (or any successor agency thereof) or the government of any other state for support or assistance pursuant to the United Kingdom’s international obligations and a decision to act upon such request has been taken by His Majesty’s Government; or

• (d) any circumstances identified as such by the COBRA committee of His Majesty’s Government (or any successor committee thereof); or

• (e) any situation in connection with which His Majesty’s Government requires fuel capacity, including where the United Kingdom is engaged in any planned or unplanned military operations within the United Kingdom or overseas.

• (3) The parties agree to act in good faith and in all reasonableness to agree any revisions to any schedule, programme or costs estimate (which shall include costs of demobilising and remobilising any workforce, and any costs to protect the apparatus “mid-works”) to account for the suspension.

• (4) Exolum shall not be liable for any costs, expenses, losses or liabilities the undertaker incurs as a result of the suspension of any activities under paragraphs to or delays caused by it.

Dispute Resolution

212

• (1) The undertaker and Exolum must use their reasonable endeavours to secure the amicable resolution of any dispute or difference arising between them out of or in connection with this Part of this Schedule in accordance with the following provisions.

• (2) The undertaker and Exolum must each nominate a representative who will meet to try to resolve the matter. If the matter is not resolved at that level within ten working days of either the undertaker or Exolum requesting such a meeting (or such longer period as may be agreed between the undertaker and Exolum) the matter may at the request of either the undertaker or Exolum be referred for discussion at a meeting to be attended by a senior executive from each party.

• (3) If the meeting between senior executives fails to result in a settlement within 20 working days of the date of the request for such a meeting (or if it is not possible to convene a meeting within this period) then, unless otherwise agreed in writing between the undertaker and Exolum, the dispute or difference will be determined by arbitration in accordance with article ‎42 (arbitration).

Miscellaneous

213

No failure or delay by a party to exercise any right or remedy provided under this Part of this Schedule or by law will constitute a waiver of that or any other right or remedy, nor will it prevent or restrict the further exercise of that or any other right or remedy. No single or partial exercise of such right or remedy will prevent or restrict the further exercise of that or any other right or remedy.

PART 16 — FOR THE PROTECTION OF LINCOLNSHIRE FIRE & RESCUE SERVICE

214

For the protection of Lincolnshire Fire and Rescue as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and Lincolnshire Fire and Rescue.

Interpretation

215

In this Part of this Schedule—

• “index” means the consumer price index;

• “index linked” means an increase in the sums payable on an annual basis or pro rata per diem from the first day following the first year of operation of the authorised development, to the date of payment, based upon the relevant index last published before the first day following the first year of operation of the authorised development; and

• “Lincolnshire Fire and Rescue” means Lincolnshire County Council in its capacity as a fire and rescue authority pursuant to section 1(2)(a) of the Fire and Rescue Services Act 2004.

Site visits

216

• (1) The undertaker must, prior to the date of final commissioning of the part of the authorised development that includes Work No. 2, use reasonable endeavours to facilitate a site familiarisation exercise in connection with Work No. 2 of the authorised development for Lincolnshire Fire and Rescue for the purposes of providing the necessary assurance to Lincolnshire Fire and Rescue that all the required systems and measures are in place in accordance with the battery storage safety management plan.

• (2) Following the anniversary of the date of final commissioning of the part of the authorised development that includes Work No. 2, the undertaker must use reasonable endeavours to facilitate an annual review of the site by Lincolnshire Fire and Rescue at the reasonable request of Lincolnshire Fire and Rescue, up until the date of decommissioning of the part of the authorised development that includes Work No. 2.

Costs

217

• (1) Pursuant to the provisions set out at paragraph ‎216, the undertaker must pay to Lincolnshire Fire and Rescue—

• (a) £16,665 in the first year of operation of the authorised development for, or in connection with, Lincolnshire Fire and Rescue’s attendance at the site familiarisation exercise facilitated by the undertaker pursuant to paragraph ‎216(1), such sum to be paid on a date mutually agreed between the parties (“the Payment Date”); and

• (b) £1,530 in each subsequent year of operation of the authorised development until the date of decommissioning of the part of the authorised development that includes Work No. 2, payable on the anniversary of the Payment Date, if in that year an annual review has taken place pursuant to paragraph ‎216(2).

• (2) The costs payable under sub-paragraph ‎(1)(b) are to be index linked.

Arbitration

218

Any difference or dispute arising between the undertaker and Lincolnshire Fire and Rescue under this Part of this Schedule must be determined by arbitration in accordance with article ‎42 (arbitration).

PART 17 — FOR THE PROTECTION OF TILLBRIDGE SOLAR PROJECT LIMITED

219

The provisions of this Part apply for the protection of Tillbridge unless otherwise agreed in writing between the undertaker and Tillbridge.

220

In this Part—

• “apparatus” means the cables, structures or other infrastructure owned, occupied or maintained by Tillbridge or its successor in title within the Tillbridge Work No. 4E;

• “construction” includes execution, placing, altering, replacing, reconstruction, relaying, maintenance, extensions, enlargement and removal; and “construct” and “constructed” must be construed accordingly;

• “plans” includes sections, drawings, specifications, designs, design data, software, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of the Tillbridge Work No. 4E; and

• “specified works” means so much of any works of operations authorised by this Order (or authorised by any planning permission intended to operate in conjunction with this Order) as is—within the Tillbridge Work No. 4E;in, on, under, over or within 25 metres of the Tillbridge Work No. 4E or any apparatus; ormay in any way adversely affect any apparatus.

• “Tillbridge” means an undertaker with the benefit of all or part of the Tillbridge Solar Order for the time being;

• “ Tillbridge Work No. 4E ” means the area for Work No. 4E authorised in the Tillbridge Solar Order;

221

The consent of Tillbridge under this Part is not required where the Tillbridge Solar Order has expired without the authorised development having been commenced pursuant to the Tillbridge Solar Order.

222

Where conditions are included in any consent granted by Tillbridge pursuant to this Part, the undertaker must comply with the conditions if it chooses to implement or rely on the consent, unless the conditions are waived or varied in writing by Tillbridge.

223

The undertaker must not under the powers of this Order acquire, extinguish, suspend, override or interfere with any rights that Tillbridge has in respect of any apparatus or has in respect of the Tillbridge Work No. 4E without the consent of Tillbridge, which must not be unreasonably withheld or delayed but which may be made subject to reasonable conditions.

224

• (1) The undertaker must not under the powers of this Order carry out any specified works without the consent of Tillbridge, which must not be unreasonably withheld or delayed but which may be made subject to reasonable conditions and if Tillbridge does not respond within 28 days of the undertaker’s request for consent, then consent is deemed to be given.

• (2) Subject to obtaining consent pursuant to sub-paragraph ‎(1) and before beginning to construct any specified works, the undertaker must submit plans of the specified works to Tillbridge and must submit any such further particulars available to it that Tillbridge may reasonably require.

• (3) Any specified works must be constructed without unreasonable delay in accordance with the plans approved in writing by Tillbridge.

• (4) Any approval of Tillbridge required under this paragraph may be made subject to such reasonable conditions as may be required for the protection or alteration of any apparatus (including proposed apparatus) in the Tillbridge Work No. 4E or for securing access to such apparatus or the Tillbridge Work No. 4E.

• (5) Where Tillbridge requires any protective works to be carried out either by themselves or by the undertaker (whether of a temporary or permanent nature) such protective works must be carried out to Tillbridge’s reasonable satisfaction.

• (6) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any specified works, new plans instead of the plans previously submitted, and the provisions of this paragraph shall apply to and in respect of the new plans.

225

• (1) The undertaker must give to Tillbridge not less than 28 days’ written notice of its intention to commence the construction of the specified works and, not more than 14 days after completion of their construction, must give to Tillbridge written notice of the completion.

• (2) The undertaker is not required to comply with paragraph ‎224 or sub-paragraph ‎(1) in a case of emergency, but in that case it must give to Tillbridge notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with paragraph ‎224 in so far as is reasonably practicable in the circumstances.

226

The undertaker must at all reasonable times during construction of the specified works allow Tillbridge and its servants and agents access to the specified works and all reasonable facilities for inspection of the specified works.

227

• (1) After the purpose of any temporary works has been accomplished, the undertaker must with all reasonable dispatch, or after a reasonable period of notice in writing from Tillbridge requiring the undertaker to do so, remove the temporary works in, on, under, over or within the Tillbridge Work No. 4E.

• (2) If the undertaker fails to remove the temporary works within a reasonable period of receipt of a notice pursuant to sub-paragraph ‎(1), Tillbridge may remove the temporary works and may recover the reasonable costs of doing so from the undertaker.

228

If in consequence of the exercise of the powers conferred by this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative means of access to such apparatus as will enable Tillbridge to maintain or use the apparatus no less effectively than was possible before the obstruction.

229

The undertaker must not exercise the powers conferred by this Order to prevent or interfere with the access by Tillbridge to the Tillbridge Work No. 4E.

230

To ensure its compliance with this Part, the undertaker must before carrying out any works or operations pursuant to this Order within Tillbridge Work No. 4E request up-to-date written confirmation from Tillbridge of the location of any apparatus or proposed apparatus.

231

The undertaker and Tillbridge must each act in good faith and use reasonable endeavours to co-operate with and provide assistance to each other as may be required to give effect to the provisions of this Part.

232

The undertaker must pay to Tillbridge the reasonable expenses incurred by Tillbridge in connection with the approval of plans, inspection of any specified works or the alteration or protection of any apparatus or the Tillbridge Work No. 4E.

233

• (1) Subject to sub-paragraphs ‎(2) and ‎(3), if by reason or in consequence of the construction of any specified works, any damage is caused to any apparatus or there is any interruption in any service provided, or in the supply of any goods, by Tillbridge, or Tillbridge becomes liable to pay any amount to any third party, the undertaker must—

• (a) bear and pay the cost reasonably incurred by Tillbridge in making good such damage or restoring the service or supply; and

• (b) compensate Tillbridge for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from Tillbridge, by reason or in consequence of any such damage or interruption or Tillbridge becoming liable to any third party as aforesaid.

• (2) Nothing in sub-paragraph ‎(1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of Tillbridge, its officers, servants, contractors or agents.

• (3) Tillbridge must give to the undertaker reasonable notice of any such claim or demand and no settlement or compromise shall be made, unless payment is required in connection with a statutory compensation scheme without first consulting the undertaker and considering its representations.

• (4) Tillbridge must use its reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies. If requested to do so by the undertaker, Tillbridge shall provide an explanation of how the claim has been minimised. The undertaker shall only be liable under this paragraph for claims reasonably incurred by Tillbridge.

• (5) The fact that any work or thing has been executed or done with the consent of Tillbridge and in accordance with any conditions or restrictions prescribed by Tillbridge or in accordance with any plans approved by Tillbridge or to its satisfaction or in accordance with any directions or award of any arbitrator does not relieve the undertaker from any liability under this Part.

234

Any dispute arising between the undertaker and Tillbridge under this Part must be determined by arbitration under article ‎42 (arbitration).

PART 18 — FOR THE PROTECTION OF EDF ENERGY (THERMAL GENERATION) LIMITED

Application

235

• (1) For the protection of EDF as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and EDF.

• (2) Subject to sub-paragraph ‎(3) or to the extent otherwise agreed in writing between the undertaker and EDF, where the benefit of this Order is transferred or granted to another person under article ‎35 (consent to transfer the benefit of the Order)—

• (a) any agreement of the type mentioned in sub-paragraph ‎(1) has effect as if it had been made between EDF and the transferee or grantee (as the case may be); and

• (b) written notice of the transfer or grant must be given to EDF on or before the date of that transfer or grant.

• (3) Sub-paragraph ‎(2) does not apply where the benefit of the Order is transferred or granted to EDF (but without prejudice to ‎245(3)(b).

Interpretation

236

In this Part of this Schedule—

• “acceptable credit provider” means a bank or financial institution with a credit rating that is not lower than—“A-” if the rating is assigned by Standard & Poor’s Ratings Group or Fitch Ratings; and“A3” if the rating is assigned by Moody’s Investors Services Inc;

• “acceptable insurance” means a third party liability insurance policy effected and maintained by the undertaker or its contractor with a combined property damage and bodily injury limit of indemnity of not less than £50,000,000 (fifty million pounds) per occurrence or series of occurrences arising out of one event or such lower amount as may be approved by EDF. Such insurance shall be maintained (a) during the construction period of the authorised development and (b) after the construction period of the authorised development in respect of any maintenance works to the authorised development by or on behalf of the undertaker which constitute specified works and arranged with an insurer whose security/credit rating meets the same requirements as an “acceptable credit provider”, such insurance must include (without limitation)—a waiver of subrogation and an indemnity to principal clause in favour of EDF; andpollution liability for third party property damage and third party bodily damage arising from any pollution/contamination event with a (sub)limit of indemnity of not less than £10,000,000 (ten million pounds) per occurrence or series of occurrences arising out of one event or £20,000,000 (twenty million pounds) in aggregate;

• “acceptable security” means either—a parent company guarantee from a parent company in favour of EDF to cover the undertaker’s liability to EDF to a total liability cap of £50,000,000 (fifty million pounds) or such lower amount as may be approved by EDF (granted by an entity and in a form reasonably satisfactory to EDF and where required by EDF, accompanied with a legal opinion confirming the due capacity and authorisation of the parent company to enter into and be bound by the terms of such guarantee); ora bank bond or letter of credit from an acceptable credit provider in favour of EDF to cover the undertaker’s liability to EDF for an amount of not less than £10,000,000 (ten million pounds) per asset per event up to a total liability cap of £50,000,000 (fifty million pounds) or such lower amount as may be approved by EDF (in a form reasonably satisfactory to EDF);

• “alternative apparatus” means appropriate alternative apparatus to the satisfaction of EDF to enable EDF to fulfil its statutory functions in a manner no less efficient than previously;

• “apparatus” means any electric lines or electrical plant as defined in the 1989 Act, or other apparatus as defined in article ‎2 of this Order, belonging to or maintained by EDF together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of EDF and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

• “authorised development” has the same meaning in article ‎2(1) of this Order and for the purposes of this Part of this Schedule includes the use, maintenance and decommissioning of the authorised development and construction of any works authorised by this Schedule;

• “commence” and “commencement” has the same meaning as in article ‎2(1) of this Order, except in this Part of this Schedule it includes any below ground surveys, below ground monitoring, ground work operations or the receipt and erection of construction plant and equipment;

• “deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;

• “EDF” means EDF Energy (Thermal Generation) Limited (company number 04267569) whose registered office is at 90 Whitfield Street, London, England, W1T 4EZ or any successor as a licence holder within the meaning of Part 1 of the 1989 Act;

• “functions” includes powers and duties;

• “ground mitigation scheme” means a scheme approved by EDF (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;

• “ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, is to require the undertaker to submit for EDF’s approval a ground mitigation scheme;

• “ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme;

• “in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

• “maintain” and “maintenance” include the ability and right to do any of the following in relation to any apparatus or alternative apparatus of EDF: construct, use, repair, alter, inspect, renew or remove (including decommission) the apparatus;

• “plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;

• “parent company” means a parent company of the undertaker acceptable to and which shall have been approved by EDF acting reasonably; and

• “specified works” means any of the authorised development or activities undertaken in association with the authorised development which—will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph ‎241(2) or otherwise; ormay in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph ‎241(2) or otherwise.

On street apparatus

237

Except for paragraphs ‎238 (apparatus of EDF in stopped up streets), ‎243 (retained apparatus: protection), ‎244 (expenses) and ‎245 (indemnity) of this Part of this Schedule which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of EDF, the other provisions of this Part of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and EDF are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus of EDF in stopped up streets

238

Notwithstanding the temporary prohibition or restriction of any street or public right of way under the powers of article ‎11 (temporary prohibition or restriction of use of streets and public rights of way), EDF is at liberty at all times to take all necessary access across any such street or public right of way and to execute and do all such works and things in, upon or under any such street or public right of way as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the temporary prohibition or restriction was in that street or public right of way.

Protective works to buildings

239

The undertaker, in the case of the powers conferred by article 17 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus without the written consent of EDF.

Acquisition of land

240

• (1) Regardless of any provision in this Order or anything shown on the land plan or contained in a book of reference to the Order, the undertaker may not (a) appropriate or acquire or take temporary possession of or entry to any land or apparatus or (b) appropriate, acquire, extinguish, interfere with or override any easement, other interest or right or apparatus of EDF otherwise than by agreement such agreement not to be unreasonably withheld.

• (2) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised development (or in such other time frame as may be agreed between EDF and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of EDF or affect the provisions of any enactment or agreement regulating the relations between EDF and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as EDF reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between EDF and the undertaker acting reasonably and which must be no less favourable on the whole to EDF unless otherwise agreed by EDF, and the undertaker will use reasonable endeavours to procure or secure (or both) the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised development.

• (3) Save where otherwise agreed in writing between EDF and the undertaker, the undertaker and EDF agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation or removal of apparatus (including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by EDF or other enactments relied upon by EDF as of right or other use in relation to the apparatus, then the provisions in this Part of this Schedule will prevail.

• (4) As a condition of an agreement between the parties in sub-paragraph (1) which relates to taking temporary access rights during construction over EDF’s land, EDF may ensure that it retains flexibility to alter any construction routes (within the order limits) or limit access for certain time periods, and may require the undertaker to pay any reasonable security and maintenance costs involved in the grant of any such rights.

• (5) Any agreement or consent granted by EDF under paragraph 9 or any other paragraph of this Part of this Schedule, are not to be taken to constitute an agreement under sub paragraph (1).

Removal of apparatus

241

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of EDF to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of EDF in accordance with sub-paragraphs ‎(2) to ‎(5) inclusive.

• (2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to EDF advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order EDF reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph ‎(3), secure any necessary consents for the alternative apparatus and afford to EDF to its satisfaction (taking into account paragraph ‎242(1)) the necessary facilities and rights—

• (a) for the construction of alternative apparatus in other land of or land secured by the undertaker; and

• (b) subsequently for the maintenance, operation and decommissioning of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph ‎(2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, EDF may in its sole discretion, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances to assist the undertaker to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation does not extend to the requirement for EDF to use its compulsory purchase powers to this end unless it elects to so do.

• (4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between EDF and the undertaker.

• (5) EDF must, after the alternative apparatus to be provided or constructed has been agreed, and subject to a written diversion agreement having been entered into between the parties and the grant to EDF of any such facilities and rights as are referred to in sub-paragraph ‎(2) or ‎(3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Facilities and rights for alternative apparatus

242

• (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for EDF facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and EDF and must be no less favourable on the whole to EDF than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by EDF.

• (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to EDF than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject the matter may be referred to arbitration in accordance with paragraph ‎249 (arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to EDF as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus: protection

243

• (1) Not less than 56 days before the commencement of any specified works the undertaker must submit to EDF a plan of the works to be executed and request from EDF details of the underground extent of their assets which EDF must provide to the undertaker as soon as reasonably practicable and within 36 days of the submission of such request.

• (2) In relation to specified works the plan to be submitted to EDF under sub-paragraph ‎(1) must include a method statement and describe—

• (a) the exact position of the works;

• (b) the level at which these are proposed to be constructed or renewed;

• (c) the manner of their construction or renewal including details of excavation, positioning of plant;

• (d) the position of all apparatus;

• (e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;

• (f) any intended maintenance regimes; and

• (g) a ground monitoring scheme, where required.

• (3) The undertaker must not commence any works to which sub-paragraph ‎(2) applies until EDF has given written approval of the plan so submitted.

• (4) Any approval of EDF required under sub-paragraph ‎(3)—

• (a) may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs ‎(5) or ‎(7); and

• (b) must not be unreasonably withheld and must be provided within 42 days of the date of submission of the plan under sub-paragraph ‎(1).

• (5) In relation to any work to which sub-paragraph ‎(2) applies, EDF may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage, for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus.

• (6) Works executed under sub-paragraph ‎(2) must be executed in accordance with the plan, submitted under sub-paragraph ‎(1) or as relevant sub-paragraph ‎(5), as approved or as amended from time to time by agreement between the undertaker and EDF and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs ‎(5) or ‎(7) by EDF for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and EDF will be entitled to watch and inspect the execution of those works.

• (7) Where EDF requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to EDF’s satisfaction prior to the commencement of any specified works (or any relevant part thereof) for which protective works are required and EDF must give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency).

• (8) If EDF in accordance with sub-paragraphs ‎(5) or ‎(7) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement within 42 days of the date of submission of a plan pursuant to this paragraph, paragraphs ‎235 to ‎237 and ‎240 to ‎242 apply as if the removal of the apparatus had been required by the undertaker under paragraph ‎241(2).

• (9) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan.

• (10) The undertaker will not be required to comply with sub-paragraph ‎(1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to EDF notice as soon as is reasonably practicable and a plan of those works and must comply with sub-paragraphs ‎(5), ‎(6) and ‎(7) insofar as is reasonably practicable in the circumstances and comply with sub-paragraph ‎(11) at all times.

• (11) At all times when carrying out any works authorised under the Order, the undertaker must comply with EDF’s HSEQ Requirement for Contractors (document reference DD_STND_HAS_001) and any document that replaces or supersedes it.

Expenses

244

• (1) Save where otherwise agreed in writing between EDF and the undertaker and subject to the following provisions of this paragraph, the undertaker must pay to EDF within 30 days of receipt of an itemised invoice or claim from EDF all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by EDF in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised development including without limitation—

• (a) any costs reasonably incurred by or compensation properly paid by EDF in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by EDF as a consequence of EDF;

• (b) using its own compulsory purchase powers to acquire any necessary rights under paragraph ‎241(3); or

• (c) exercising any compulsory purchase powers in the Order transferred to or benefitting EDF;

• (d) in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place;

• (e) the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

• (f) the approval of plans;

• (g) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

• (h) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule.

• (2) There will be deducted from any sum payable under sub-paragraph ‎(1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

• (3) If in accordance with the provisions of this Part of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph ‎249 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to EDF by virtue of sub-paragraph ‎(1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.

• (4) For the purposes of sub-paragraph ‎(3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.

• (5) Any amount which apart from this sub-paragraph would be payable to EDF in respect of works by virtue of sub-paragraph ‎(1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on EDF any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

• (6) Any sums paid by the undertaker to EDF under sub-paragraph ‎(1) relating to anticipated costs and expenses will be returned on demand (in whole or in part as applicable) by EDF to the undertaker if not incurred.

Indemnity

245

• (1) Subject to sub-paragraphs ‎(2) and ‎(3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, use, maintenance or failure of any of the authorised development by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by them) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised development) or property of EDF, or there is any interruption in any service provided, or in the supply of any goods, by EDF, or EDF becomes liable to pay any amount to any third party, the undertaker will—

• (a) bear and pay on demand accompanied by an invoice or claim from EDF the cost reasonably and properly incurred by EDF in making good such damage or restoring the supply; and

• (b) indemnify EDF for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from EDF, by reason or in consequence of any such damage or interruption or EDF becoming liable to any third party other than arising from any default or negligence of EDF.

• (2) The fact that any act or thing may have been done by EDF on behalf of the undertaker or in accordance with a plan approved by EDF or in accordance with any requirement of EDF or under its supervision will not (unless sub-paragraph ‎(3) applies), excuse the undertaker from liability under the provisions of this sub-paragraph ‎(1) unless EDF fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan or as otherwise agreed between the undertaker and EDF.

• (3) Nothing in sub-paragraph ‎(1) is to impose any liability on the undertaker in respect of—

• (a) any damage or interruption to the extent that it is attributable to the neglect or default of EDF, its officers, servants, contractors or agents; or

• (b) any authorised development or any other works authorised by this Part of this Schedule carried out by EDF as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 of the 2008 Act or article ‎35 (consent to transfer the benefit of the Order) subject to the proviso that once such works become apparatus (“new apparatus”), any authorised development yet to be executed and not falling within this paragraph ‎(b) will be subject to the full terms of this Part of this Schedule including this paragraph ‎245; or

• (c) any consequential loss of any third party (including but not limited to loss of use, revenue, profit, contract, production, increased cost of working or business interruption) arising from any such damage or interruption, which is not reasonably foreseeable.

• (4) EDF must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

• (5) EDF must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds.

• (6) EDF must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within EDF’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of EDF’s control and if reasonably requested to do so by the undertaker EDF must provide an explanation of how the claim has been minimised, where relevant.

• (7) Not to commence construction (and not to permit the commencement of such construction) of the authorised development on any land owned by EDF or in respect of which EDF has an easement or wayleave for its apparatus or any other interest or to carry out any works within 20 metres of EDF’s apparatus until the following conditions are satisfied provided that the following conditions do not apply in relation to any specified works that are undertaken by EDF—

• (a) unless and until EDF is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has first provided the acceptable security (and unless otherwise agreed with EDF (acting reasonably) provided evidence that it shall maintain such acceptable security for the construction period of the authorised development from the proposed date of commencement of construction of the authorised development) and EDF has confirmed the same to the undertaker in writing; and

• (b) unless and until EDF is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has procured acceptable insurance (and unless otherwise agreed with EDF (acting reasonably) provided evidence to EDF that it shall maintain such acceptable insurance for the construction period of the authorised development from the proposed date of commencement of construction of the authorised development) and EDF has confirmed the same in writing to the undertaker.

• (8) In the event that the undertaker fails to comply with sub-paragraph ‎(7), nothing in this Part of this Schedule will prevent EDF from seeking injunctive relief (or any other equitable remedy) in any court of competent jurisdiction.

Enactments and agreements

246

Save to the extent provided for to the contrary elsewhere in this Part of this Schedule or by agreement in writing between EDF and the undertaker, nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and EDF in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Co-operation

247

• (1) Where in consequence of the proposed construction of any part of the authorised development, the undertaker or EDF requires the removal of apparatus under paragraph ‎241(2) or EDF makes requirements for the protection or alteration of apparatus under paragraph ‎243, the undertaker shall use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of EDF’s undertaking and EDF shall use its best endeavours to co-operate with the undertaker for that purpose.

• (2) For the avoidance of doubt whenever EDF’s consent, agreement or approval is required in relation to plans, documents or other information submitted by the undertaker or the taking of action by the undertaker, it must not be unreasonably withheld or delayed.

Access

248

If in consequence of an agreement or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative means of access to such apparatus as will enable EDF to maintain or use the apparatus no less effectively than was possible before such obstruction.

Arbitration

249

Any difference or dispute arising between the undertaker and EDF under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and EDF, be determined by arbitration in accordance with article ‎42 (arbitration).

Notices

250

Notwithstanding article 44 (service of notices), any plans submitted to EDF by the undertaker pursuant to paragraph ‎244 must be submitted to EDF addressed to the company secretary and copied to the land and estates team and sent to 90 Whitfield Street, London, England, W1T 4EZ or to such other address as EDF may from time to time appoint instead for that purpose and notify to the undertaker in writing.

PART 19 — FOR THE PROTECTION OF THE UK ATOMIC ENERGY AUTHORITY

Application

251

• (1) Subject to sub-paragraph ‎(2), for the protection of UKAEA as referred to in this Part of this Schedule, the following provisions have effect unless otherwise agreed in writing between the undertaker and UKAEA.

• (2) Unless otherwise agreed in writing between the undertaker and UKAEA, paragraphs ‎256 and ‎257 will apply for the protection of UKAEA from the point that UKAEA is the owner of the UKAEA Land.

Interpretation

252

In this Part of this Schedule—

• “acceptable credit provider” means a bank or financial institution with a credit rating that is not lower than—“A-“ if the rating is assigned by Standard & Poor’s Ratings Group or Fitch Ratings; and“A3” if the rating is assigned by Moody’s Investors Services Inc.;

• “acceptable insurance” means a third party liability insurance policy effected and maintained by the undertaker or its contractor with a combined property damage ang bodily injury limit of not less than £20,000,000 (twenty million pounds) per occurrence or series of occurrences arising out of one event or such lower amount as may be approved by UKAEA. Such insurance shall be maintained during the construction period of the authorised development and arranged with an insurer whose security/credit rating meets the same requirements as an acceptable credit provider, such insurance shall include (without limitation)—a waiver of subrogation and an indemnity to principal clause in favour of UKAEA; andpollution liability for third party property damage and third party bodily damage arising from any pollution/contamination event with a (sub)limit of indemnity of not less than £10,000,000.00 (ten million pounds) per occurrence or series of occurrences arising out of one event or £20,000,000.00 (twenty million pounds) in aggregate;

• “authorised development” has the same meaning in article 2(1) of this Order and for the purposes of this Part of this Schedule includes the use, maintenance and decommissioning of the authorised development and construction of any works authorised by this Part of this Schedule;

• “commence” and “commencement” has the same meaning as in article 2(1) of this Order, except in this Part of this Schedule it includes any below ground surveys, below ground monitoring and ground work operations;

• “functions” includes powers and duties;

• “plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;

• “specified works” means any of the authorised development or activities undertaken in association with the authorised development within the West Burton Power Station;

• “undertaker” means the undertaker as defined in article 2(1) of this Order;

• “UKAEA” means the United Kingdom Atomic Energy Authority, or any successor in its functions;

• “UKAEA land” means the land within plots 10-183, 10-183a, 10-183b, 10-183c, 10-183d, 10-184, 10-185 and 10-194a as shown on the Land plan and described in the book of reference;

• “West Burton Power Station” means the land shown outlined in red on the West Burton Power Station plan; and

• “the West Burton Power Station plan” means the plan of that name identified in the table at Schedule 13 (documents and plans to be certified) and which is certified by the Secretary of State as the West Burton Power Station plan for the purposes of this Order.

Streets subject to temporary prohibition or restriction of use and public rights of way

253

Notwithstanding the temporary prohibition or restriction of use or diversion of a street or public right of way under the powers of article 11 (temporary prohibition or restriction of use of streets and public rights of way), UKAEA is at liberty at all times to take all necessary access across any such street or public right of way and to execute and do all such works and things in, upon or under any such street or public right of way as may be reasonably necessary or desirable to enable it to access the West Burton Power Station in the same way as it was able to prior to the prohibition or restriction of use or diversion of that street or public right of way.

Protective works to buildings

254

The undertaker, in the case of the powers conferred by article 17 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any buildings without the written consent of UKAEA.

Acquisition of land

255

Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order, the undertaker may not—

• (a) appropriate or acquire or take temporary possession of or entry to the West Burton Power Station; or

• (b) appropriate, acquire, extinguish, interfere with or override any easement, other interest or right or apparatus of UKAEA,

otherwise than by agreement.

Specified works

256

• (1) Not less than 56 days before the commencement of any specified works the undertaker must submit to UKAEA a plan of the works to be executed and request from UKAEA details of the underground extent of any apparatus or assets belonging to UKAEA which UKAEA must provide to the undertaker as soon as reasonably practicable and within 36 days of the submission of such request.

• (2) In relation to specified works the plan to be submitted to UKAEA under sub-paragraph (1) must include a method statement and describe—

• (a) the exact position of the works;

• (b) the level at which these are proposed to be constructed or renewed;

• (c) the manner of their construction or renewal including details of excavation and positioning of plant;

• (d) the position of any assets and apparatus belonging to UKAEA;

• (e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus or assets; and

• (f) any intended maintenance regimes.

• (3) The undertaker must not commence any works to which sub-paragraph ‎(2) applies until UKAEA has given written approval of the plan so submitted.

• (4) Any approval of UKAEA required under sub-paragraph ‎(3)—

• (a) may be given subject to reasonable conditions for any purpose mentioned in ‎(5) or ‎(7); and,

• (b) must not be unreasonably withheld and must be provided within 42 days of submission of the plan under sub-paragraph ‎(1).