The Gatwick Airport (Northern Runway Project) Development Consent Order 2025

PART 2 — TRAFFIC REGULATION MEASURES (CLEARWAYS, HEIGHT RESTRICTIONS AND PROHIBITIONS)

PART 3 — REVOCATIONS AND VARIATIONS OF EXISTING TRAFFIC REGULATION ORDERS

SCHEDULE 7 — LAND IN WHICH ONLY NEW RIGHTS ETC. MAY BE ACQUIRED

SCHEDULE 8 — MODIFICATION OF COMPENSATION AND COMPULSORY PURCHASE ENACTMENTS FOR CREATION OF NEW RIGHTS AND IMPOSITION OF RESTRICTIVE COVENANTS

Compensation enactments

1

The enactments for the time being in force with respect to compensation for the compulsory purchase of land apply in the case of a compulsory acquisition under this Order of a right by the creation of a new right or the imposition of a restrictive covenant as they apply in respect of compensation on the compulsory purchase of land and interests in land, subject to the modifications set out in this Schedule.

2

• (1) Without limiting paragraph (1), the Land Compensation Act 1973[^f00109] has effect subject to the modifications set out in sub-paragraphs (2).

• (2) In section 44(1) (compensation for injurious affection), as it applies to compensation for injurious affection under section 7 of the 1965 Act as substituted by paragraph 5(3)—

• (a) for “land is acquired or taken from” substitute “a right or restrictive covenant over land is purchased from or imposed on”; and

• (b) for “acquired or taken from him” substitute “over which the right is exercisable or the restrictive covenant enforceable”.

3

• (1) Without limiting paragraph 1, the 1961 Act has effect subject to the modification set out in sub-paragraph (2).

• (2) For section 5A(5A) (relevant valuation date) of the 1961 Act, substitute—

(5A) If— (a) the acquiring authority enters on land for the purpose of exercising a right in pursuance of a notice of entry under section 11(1) (powers of entry) of the 1965 Act (as modified by paragraph 5(5) of Schedule 8 to the Gatwick Airport (Northern Runway Project) Development Consent Order 2025); (b) the acquiring authority is subsequently required by a determination under paragraph 13 of Schedule 2A to the 1965 Act (as substituted by paragraph 5(8) of Schedule 8 to the Gatwick Airport (Northern Runway Project) Development Consent Order 2025) to acquire an interest in the land; and (c) the acquiring authority enters on and takes possession of that land, the authority is deemed for the purposes of subsection (3)(a) to have entered on that land where it entered on that land for the purpose of exercising that right.

Application of Part 1 of the 1965 Act

4

Part 1 of the 1965 Act, as applied by section 125 (application of compulsory acquisition provisions) of the 2008 Act (and modified by article 32 (modification of Part 1 of the 1965 Act)) to the acquisition of land under article 27 (compulsory acquisition of land), applies to the compulsory acquisition of a right by the creation of a new right, or to the imposition of a restrictive covenant under article 28 (compulsory acquisition of rights and the imposition of restrictive covenants)—

• (a) with the modifications specified in paragraph 5; or

• (b) with such other modifications as may be necessary.

5

• (1) The modifications referred to in paragraph 4(a) are as follows.

• (2) References in the 1965 Act to land are, in the appropriate contexts, to be read (according to the requirements of the particular context) as referring to, or as including references to—

• (a) the right acquired or to be acquired, or the restrictive covenant impose or to be imposed; or

• (b) the land over which the right is or is to be exercisable, or the restrictive covenant is or is to be enforceable.

• (3) For section 7 (measure of compensation in case of severance) of the 1965 Act substitute—

(7) In assessing the compensation to be paid by the acquiring authority under this Act, regard must be had not only to the extent (if any) to which the value of the land over which the right is to be acquired or the restrictive covenant is to be imposed is depreciated by the acquisition of the right or the imposition of the covenant but also to the damage (if any) to be sustained by the owner of the land by reason of its severance from other land of the owner, or injuriously affecting that other land by the exercise of the powers conferred by this or the special Act.

• (4) The following provisions of the 1965 Act (which state the effect of a deed poll executed in various circumstances where there is no conveyance by persons with interests in the land), that is to say—

• (a) section 9(4) (failure by owners to convey);

• (b) paragraph 10(3) of Schedule 1 (owners under incapacity);

• (c) paragraph 2(3) of Schedule 2 (absent and untraced owners); and

• (d) paragraphs 2(3) and 7(2) of Schedule 4 (common land),

are modified so as to secure that, as against persons with interests in the land which are expressed to be overridden by the deed, the right which is to be compulsorily acquired or the restrictive covenant which is to be imposed is vested absolutely in the acquiring authority.

• (5) Section 11[^f00110] (powers of entry) of the 1965 Act is modified so as to secure that, where the acquiring authority has served notice to treat in respect of any right or restrictive covenant, as well as the notice of entry required by subsection (1) of that section (as applies to a compulsory acquisition under article 27), it has power, exercisable in equivalent circumstances and subject to equivalent conditions, to enter for the purpose of exercising that right or enforcing that restrictive covenant; and sections 11A[^f00111] (powers of entry: further notices of entry), 12[^f00112] (penalty for unauthorised entry) and 13[^f00113] (refusal to give possession to acquiring authority) of the 1965 Act are modified correspondingly.

• (6) Section 20[^f00114] (tenants at will, etc.) of the 1965 Act applies with the modifications necessary to secure that persons with such interests in land as are mentioned in that section are compensated in a manner corresponding to that in which they would be compensated on a compulsory acquisition under this Order of that land, but taking into account only the extent (if any) of such interference with such an interest as is actually caused, or likely to be caused, by the exercise of the right or the enforcement of the restrictive covenant in question.

• (7) Section 22 (interests omitted from purchase) of the 1965 Act as modified by article 32(4) is modified so as to enable the acquiring authority in circumstances corresponding to those referred to in that section, to continue to be entitled to exercise the right acquired, subject to compliance with that section as respects compensation.

• (8) For Schedule 2A of the 1965 Act substitute—

SCHEDULE2A (1) This Schedule applies where an acquiring authority serves a notice to treat in respect of a right over, or restrictive covenant affecting, the whole or part of a house, building or factory and has not executed a general vesting declaration under section 4 of the Compulsory Purchase (Vesting Declarations) Act 1981 as applied by article 33 (application of the 1981 Act) of the Gatwick Airport (Northern Runway Project) Development Consent Order 2025) in respect of the land to which the notice to treat relates. (2) In this Schedule, “house” includes any park or garden belonging to a house. (3) A person who is able to sell the house, building or factory (“the owner”) may serve a counter-notice requiring the acquiring authority to purchase the owner’s interest in the house, building or factory. (4) A counter-notice under paragraph 3 must be served within the period of 28 days beginning with the day on which the notice to treat was served. (5) On receiving a counter-notice, the acquiring authority must decide whether to— (a) withdraw the notice to treat, (b) accept the counter-notice, or (c) refer the counter-notice to the Upper Tribunal. (6) The acquiring authority must serve notice of their decision on the owner within the period of 3 months beginning with the day on which the counter-notice is served (“the decision period”). (7) If the acquiring authority decides to refer the counter-notice to the Upper Tribunal it must do so within the decision period. (8) If the acquiring authority does not serve notice of a decision within the decision period it is to be treated as if it had served notice of a decision to withdraw the notice to treat at the end of that period. (9) If the acquiring authority serves notice of a decision to accept the counter-notice, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in the house, building or factory. (10) On a referral under paragraph 7, the Upper Tribunal must determine whether the acquisition of the right or the imposition of the restrictive covenant would— (a) in the case of a house, building or factory, cause material detriment to the house, building or factory, or (b) in the case of a park or garden, seriously affect the amenity or convenience of the house to which the park or garden belongs. (11) In making its determination, the Upper Tribunal must take into account— (a) the effect of the acquisition of the right or the imposition of the covenant, (b) the use to be made of the right or covenant proposed to be acquired or imposed, and (c) if the right or covenant is proposed to be acquired or imposed for works or other purposes extending to other land, the effect of the whole of the works and the use of the other land. (12) If the Upper Tribunal determines that the acquisition of the right or the imposition of the covenant would have either of the consequences described in paragraph 10, it must determine how much of the house, building or factory the acquiring authority ought to be required to take. (13) If the Upper Tribunal determines that the acquiring authority ought to be required to take some or all of the house, building or factory, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in that land. (14) (1) If the Upper Tribunal determines that the acquiring authority ought to be required to take some or all of the house, building or factory, the acquiring authority may at any time within the period of 6 weeks beginning with the day on which the Upper Tribunal makes its determination withdraw the notice to treat in relation to that land. (2) If the acquiring authority withdraws the notice to treat under this paragraph it must pay the person on whom the notice was served compensation for any loss or expense caused by the giving and withdrawal of the notice. (3) Any dispute as to the compensation is to be determined by the Upper Tribunal.

SCHEDULE 9 — PROTECTIVE PROVISIONS

PART 1 — FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWAGE UNDERTAKERS

1

For the protection of the utility undertakers referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertaker concerned.

2

In this Part of this Schedule—

• “alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;

• “apparatus” means— in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989[^f00115]), belonging to or maintained by that undertaker; in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter within the meaning of Part 1 (gas supply) of the Gas Act 1986[^f00116] for the purposes of gas supply; in the case of a water undertaker, mains, pipes or other apparatus belonging to or maintained by that undertaker for the purposes of water supply; and in the case of a sewerage undertaker— any drain or works vested in the undertaker under the Water Industry Act 1991[^f00117]; and any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4)[^f00118] (adoption of sewers and disposal of works) of that Act or an agreement to adopt made under section 104[^f00119] (agreements to adopt sewer, drain or sewage disposal works, at a future date) of that Act, and includes a sludge main, disposal main (within the meaning of section 219 (general interpretation) of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

• “functions” includes powers and duties;

• “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

• “plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed; and

• “utility undertaker” means— any licence holder within the meaning of Part 1 of the Electricity Act 1989; a gas transporter within the meaning of Part 1 (gas supply) of the Gas Act 1986; a water undertaker within the meaning of the Water Industry Act 1991; and a sewerage undertaker within the meaning of Part 1 (preliminary) of the Water Industry Act 1991, for the area of the authorised development, and in relation to any apparatus, means the undertaker to whom it belongs or by whom it is maintained.

On street apparatus

3

This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.

Apparatus in stopped up public rights of way

4

• (1) Where any public right of way is stopped up under article 15 (public rights of way – creation, diversion and stopping up), any utility undertaker whose apparatus is in the land in which the public right of way subsists has the same powers and rights in respect of that apparatus in the land in which the public right of way subsists as it enjoyed immediately before the stopping up and the undertaker must grant to the utility undertaker legal easements reasonably satisfactory to the utility undertaker in respect of such apparatus and access to it, but nothing in this paragraph affects any right of the undertaker or of the utility undertaker to require the removal of that apparatus under paragraph 7 or the power of the undertaker to carry out works under paragraph 9.

• (2) Regardless of the temporary alteration, diversion or restriction of any street under the powers conferred by article 14 (temporary closure of streets), a utility undertaker is at liberty at all times to take all necessary access across any such stopped up street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that street.

Protective works to buildings

5

The undertaker, in the case of the powers conferred by article 23 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus.

Acquisition of land

6

Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Removal of apparatus

7

• (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land must not be extinguished, until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (6).

• (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

• (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed the utility undertaker must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

• (4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 52 (arbitration).

• (5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 52 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

• (6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that the undertaker desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

• (7) If the utility undertaker fails either reasonably to approve, or to provide reasons for its failure to approve along with an indication of what would be required to make acceptable, any proposed details relating to required removal works under sub-paragraph (2) within 28 days of receiving a notice of the required works from the undertaker, then such details are deemed to have been approved, provided that the undertaker has first taken all reasonable steps to contact the relevant representatives of the utility undertaker in order to elicit such a response.

• (8) Any deemed approval under sub-paragraph (7) does not extend to the actual undertaking of the removal works, which remains the sole responsibility of the utility undertaker or its contractors.

Facilities and rights for alternative apparatus

8

• (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance by the utility undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker or in default of agreement settled by arbitration in accordance with article 52 (arbitration).

• (2) In settling those terms and conditions in respect of alternative apparatus to be constructed in the land of the undertaker, the arbitrator will—

• (a) give effect to all reasonable requirements of the undertaker for ensuring the safety and efficient operation of the authorised development and for securing any subsequent alterations or adaptions of the alternative apparatus which may be required to prevent interference with the proposed works of the undertaker; and

• (b) so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed in or on the land for which the alternative apparatus is to be substituted.

• (3) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus

9

• (1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 7(2), the undertaker must submit to the utility undertaker in question a plan of the works to be executed.

• (2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.

• (3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it.

• (4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 7(2).

• (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works (unless otherwise agreed with the utility undertaker), a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

• (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances.

Expenses and costs

10

• (1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker all expenses reasonably incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 7(2).

• (2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule that value being calculated after removal.

• (3) If in accordance with the provisions of this Part of this Schedule—

• (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

• (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 52 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

• (4) For the purposes of sub-paragraph (3)—

• (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

• (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

• (5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

11

• (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 5 or 7(2), or by reason of any subsidence resulting from such development or works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—

• (a) bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

• (b) make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the undertaker,

by reason or in consequence of any such damage or interruption.

• (2) The fact that any act or thing may have been done by a utility undertaker on behalf of the undertaker or in accordance with a plan approved by a utility undertaker or in accordance with any requirement of a utility undertaker or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1) unless a utility undertaker fails to carry out and execute the works properly with due care and attention and in a skilful and professional like manner or in a manner that does not accord with the approved plan.

• (3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

• (4) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Cooperation

12

Where in consequence of the proposed construction of any of the authorised development, the undertaker or a utility undertaker requires the removal of apparatus under paragraph 7(2) or a utility undertaker makes requirements for the protection or alteration of apparatus under paragraph 9, the undertaker must use best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of the utility undertaker’s undertaking and each utility undertaker must use its best endeavours to co-operate with the undertaker for that purpose.

13

Where, under this Part, the utility undertaker is required to give its consent or approval in respect of any matter, that consent or approval must not be unreasonably withheld or delayed.

14

Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 2 — FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

15

For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.

16

In this Part of this Schedule—

• “the 2003 Act” means the Communications Act 2003[^f00120];

• “electronic communications apparatus” has the same meaning as in the electronic communications code;

• “the electronic communications code” has the same meaning as in Chapter 1 (electronic communications networks and services) of Part 2 (networks, services and the radio spectrum) of the 2003 Act[^f00121];

• “electronic communications code network” means— so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 (application of the electronic communications code) of the 2003 Act; and an electronic communications network which the undertaker is providing or proposing to provide;

• “electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 (application of the electronic communications code) of the 2003 Act; and

• “operator” means the operator of an electronic communications code network.

17

The exercise of the powers conferred by article 40 (statutory undertakers) is subject to Part 10 (undertaker’s works affecting electronic communications apparatus) of the electronic communications code.

18

• (1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—

• (a) any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

• (b) there is any interruption in the supply of the service provided by an operator,

the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.

• (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

• (3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

• (4) Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 52 (arbitration).

• (5) This Part of this Schedule does not apply to—

• (a) any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act; or

• (b) any damages, or any interruptions, caused by electro-magnetic interference arising from the construction or use of the authorised development.

• (6) In respect of the acquisition of rights under or over or use of the operator’s property, the operator must co-operate with the undertaker with a view to avoiding undue delay.

• (7) Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 3 — FOR THE PROTECTION OF NATIONAL HIGHWAYS

Application etc.

19

• (1) The provisions of this Part of this Schedule apply for the protection of National Highways and have effect unless otherwise agreed in writing between the undertaker and National Highways.

• (2) Except where expressly amended by the Order the operation of the powers and duties of National Highways or the Secretary of State under the 1980 Act, the 1984 Act, the 1991 Act, the Transport Act 2000 and the 2015 Regulations shall continue to apply in respect of the exercise of all of National Highways’ statutory functions.

Interpretation

20

• (1) Where the terms defined in article 2 (interpretation) of this Order are inconsistent with sub-paragraph (2) the latter prevail.

• (2) In this Part of this Schedule—

• “as built information” means one electronic copy of the following information— as constructed drawings in both PDF and AutoCAD DWG formats for anything designed by the undertaker; in compliance with DMRB GG 184 (Specification for the use of Computer Aided Design) or any successor document; list of suppliers and materials used, as well as any relevant test results and CCTV surveys (if required to comply with DMRB standards); product data sheets and technical specifications for all materials used; as constructed information for any utilities discovered or moved during the works; method statements for the works carried out; in relation to road lighting, signs, and traffic signals any information required by Series 1300 and 1400 of the Specification for Highway Works or any replacement or modification of it; organisation and methods manuals for all products used; as constructed programme; test results and records as required by the detailed design information and during construction phase of the project; a stage 3 road safety audit subject to any exceptions to the road safety audit standard as agreed by the undertaker and National Highways; the health and safety file; and such other information as is required by National Highways to be used to update all relevant databases and to ensure compliance with National Highway’s Asset Data Management Manual as is in operation at the relevant time.

• “the bond sum” means the sum equal to 200% of the cost of the carrying out the specified works (to include all costs plus any commuted sum) or such other sum agreed between the undertaker and National Highways;

• “the cash surety” means the sum agreed between the undertaker and National Highways;

• “commuted sum” means such sum calculated as provided for in paragraph 34 (commuted sum) of this Part of this Schedule to be used to fund the future cost of maintaining any new National Highways assets or structures or apparatus provided under the Order;

• “condition survey” means a survey of the condition of National Highways structures and assets within the Order limits that may be affected by the specified works;

• “contractor” means any contractor or subcontractor appointed by the undertaker to carry out the specified works;

• “defects period” means the period from the date of the provisional certificate to the date of the final certificate which shall be no less than 12 months from the date of the provisional certificate;

• “detailed design information” means such of the following drawings specifications and calculations as are relevant to the development— site clearance details; boundary, environmental and mitigation fencing; road restraints systems and supporting road restraint risk appraisal process assessment; drainage and ducting as required by DMRB CD 535 (Drainage asset data and risk management) and DMRB CS 551 (Drainage surveys – standards for Highways); earthworks including supporting geotechnical assessments required by DMRB CD 622 (Managing geotechnical risk) and any required strengthened earthworks appraisal form certification; pavement, pavement foundations, kerbs, footways and paved areas; traffic signs and road markings; traffic signal equipment and associated signal phasing and timing detail; road lighting (including columns and brackets); regime of California Bearing Ratio testing; electrical work for road lighting, traffic signs and signals; motorway communications as required by DMRB; highway structures and any required structural approval in principle; landscaping; proposed departures from DMRB standards; walking, cycling and horse riding assessment and review report; stage 1 and stage 2 road safety audits and exceptions agreed; utilities diversions; topographical survey; maintenance and repair strategy in accordance with DMRB GD 304 (Designing health and safety into maintenance) or any replacement or modification of it; health and safety information including any asbestos survey required by DMRB GG 105 (Asbestos management) or any successor document; and other such information that may be required by National Highways to be used to inform the detailed design of the specified works;

• “DBFO contract” means the contract between National Highways and the highway operations and maintenance contractor for the maintenance and operation of parts of the strategic road network which are within the Order limits or any successor or replacement contract that may be current at the relevant time;

• “DMRB” means the Design Manual for Roads and Bridges or any replacement or modification of it;

• “final certificate” means the certificate relating to those aspects of the specified works that have resulted in any alteration to the strategic road network to be issued by National Highways pursuant to paragraph 32;